Loren Data's SAM Daily™

FBO DAILY ISSUE OF OCTOBER 06, 2002 FBO #0308
MODIFICATION

Y -- Remodel courtyards

Notice Date

7/25/2002
 

Notice Type

Modification
 

Contracting Office

Department of the Treasury, Internal Revenue Service (IRS), I.R.S. Western Procurement Branch (A:P:F:W), 333 Market Street, Suite 1400, San Francisco, CA, 94103
 

ZIP Code

94105-2115
 

Solicitation Number

TIRWR-02-B-00001
 

Response Due

8/15/2002
 

Point of Contact

Jerry Herrera, Contracting Officer, Phone 415.848.4722, Fax 415.48.7412, - Danny Levels, Contract Specialist, Phone 415-848-4724, Fax 415 848-4712,
 

E-Mail Address

gerard.herrera@irs.gov, danny.levels@irs.gov
 

Small Business Set-Aside

Total HUB-Zone
 

Description

a. Amendment 0005 is issued to solicitation TIRWR-02-B-00001 for the purpose of providing FAR clause 52.211-12 in full text. The original solicitation contained this clause by reference. 52.211-12 Liquidated Damages-Construction. Liquidated Damages-Construction (Sept 2000) (a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $91.45 for each calendar day of delay until the work is completed or accepted. (b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause. (End of clause) b. As a result of this amendment, the bid opening shall not be extended. The bid opening shall remain on 21 Aug 2002 at 2:00 P.M. c. All Contractors shall acknowledge receipt of amendment by either signing item 19. on the reverse side of Standard Form 1442 or by including signature on Standard Form 30 along with your bid. NOTE: THIS NOTICE WAS NOT POSTED TO FEDBIZOPPS.GOV ON THE DATE INDICATED IN THE NOTICE ITSELF (25-JUL-2002). IT ACTUALLY FIRST APPEARED ON THE FEDBIZOPPS SYSTEM ON 04-OCT-2002. PLEASE CONTACT fbo.support@gsa.gov REGARDING THIS ISSUE.
 

Web Link

Link to FedBizOpps document.
(http://www.eps.gov/spg/TREAS/IRS/IRSWPBAPFWR/TIRWR-02-B-00001/listing.html)
 

Place of Performance

Address: IRS Fresno Service Center 5045 Butler Ave. Fresno, CA

Zip Code: 93703

Country: USA
 

Record

SN00183226-F 20021006/021004223337 (fbodaily.com)
 

Source

FedBizOpps.gov Link to This Notice
(may not be valid after Archive Date)

---

| FSG Index  |  This Issue's Index  |  Today's FBO Daily Index Page |