MODIFICATION
Z -- NON-SKID SURFACE
- Notice Date
- 4/21/2004
- Notice Type
- Modification
- NAICS
- 238990
— All Other Specialty Trade Contractors
- Contracting Office
- Department of the Navy, Naval Air Systems Command, Naval Air Warfare Center Aircraft Division Pax River, Building 441 21983 Bundy Road Unit 7, Patuxent River, MD, 20670
- ZIP Code
- 20670
- Solicitation Number
- N00421-04-T-0131
- Response Due
- 5/4/2004
- Archive Date
- 6/15/2004
- Point of Contact
- Mary Roland, Contract Specialist, Phone (301) 757-9709, Fax (301) 757-0200, - Thomas Stann, Contracting Officer, Phone (301) 757-9714, Fax (301) 757-0200,
- E-Mail Address
-
mary.roland@navy.mil, thomas.stann@navy.mil
- Small Business Set-Aside
- Total Small Business
- Description
- N00421-04-T-0131 Amendment 0001 The purpose of this posting is to amend combined synopsis/solicitation N00421-04-T-0131 to remove and replace the existing non-skid surface at the MK-7 Arresting Gear site onboard the Naval Air Warfare Center Aircraft Division, Patuxent River, Maryland. See, original posting of 16 April 2004. This amendment 0001 is to answer questions received on the original posting, as follows: QUESTION 1 (paraphrased): I ask that you require the contractor to be qualified to SSPC (Society for Protective Coatings, formerly Steel Structures Painting Council) QP-1. This requirement was a joint effort by NAVSEA and NAVAIR effective 1 October 2003. ANSWER 1: The work statement for CLIN 0001 is changed to ADD the certification requirement, as follows: All offerors shall be certified per the SSPC-QP1 program and remain certified for the duration of the project. The contractor shall immediately notify the Contracting Officer of any change in its certification status. Information on the SSPC certification program is available at www.sspc.org. No other certification will be considered. QUESTION 2: It would also be nice if you set this aside for Total HubZone. ANSWER 2: Types of set-asides were considered prior to release of the combined synopsis/solicitation. A Total HubZone set-aside was not deemed in the Government?s best interest for this requirement. QUESTION 3: The synopsis/solicitation states award is anticipated by 1 May 2004, but later states proposals are due by 4 May 2004. Please verify/clarify the dates. ANSWER 3: The anticipated date of award is corrected to read 10 May 2004. There is no change to the proposal due time/date of 3:00 p.m. (EDT) on 4 May 2004. All other terms and conditions remain the same. QUESTON 4: Will a faxed quotation be acceptable? ANSWER 4: A faxed quotation will be acceptable. Offerors are reminded, however, that they are responsible for ensuring that the appropriate Government official receives the complete proposal in a timely manner for it to be considered for award. --End of Amendment? This is a combined synopsis/solicitation announcement issued as a Request for Quotations (RFQ) prepared in accordance with the format in Federal Acquisition Regulation (FAR) Subparts 12.603 and 13.5, as supplemented with the additional information included in this notice. This announcement constitutes the only solicitation; an RFQ proposal is being requested. A WRITTEN SOLICITATION WILL NOT BE ISSUED. This solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular No. 22 (as of 5 April 2004). The requirement is issued as a 100% set aside for small businesses, as set forth herein. Award is anticipated on or before 1 May 2004. The appropriate NAICS Code is 238990, size standard $12.0 million. Proposals are due no later than 3:00 p.m. (EDT) on 4 May 2004 to NAVAIR/AD Contracts (AIR-2.5.1), Building 588, Suite 2, Code 251711 (Mary Roland), Naval Air Warfare Center Aircraft Division, 47253 Whalen Road, Unit 588, Patuxent River, Maryland 20670-1463. The quote shall reference solicitation N00421-04-T-0131. REQUIREMENT: The MK-7 Arresting Gear site, Naval Air Warfare Center Aircraft Division, Patuxent River, Maryland, has a requirement for the necessary labor, equipment, and materials to remove and replace the existing non-skid at the MK-7 Arresting Gear site using the WATER JET method on Runway 32 (CLIN 0001) The non-skid material shall be applied in accordance with SSPC SP-12/NAEC 5 and the Non-skid Quality Assurance Inspection 634. The total square footage to be covered is approximately 12,000 square feet. The Government shall provide a water source and electrical power source. All hazardous material from the water jet method will be disposed of by the Government facilities, and be processed without delay or disrupting the non-skid evolution. Contractor will be responsible for disposal of non-hazardous materials. The required completion date is 1 June 2004 to ensure availability to meet aircraft testing and evaluation projects that dictate that the Launch and Recovery equipment is available for repairs and overhauls. GENERAL INFORMATION FOR THE PROPOSALS: The quote shall address all requirements. The requirement is proposed as a FIRM FIXED PRICE contract and shall be quoted on an ALL OR NONE basis. The quote shall contain ? as a minimum ? the following information: (1) the name, telephone number, address, point of contact, email address and contract number (if any, or other identifying information) of at least three current references (within the past two years) that can be contacted for past performance information to verify/confirm the submitter?s ability/willingness to meet performance/schedule requirements and industry reputation as well as information on the submitter?s proposed product and start date to meet the required completion date of 1 June 2004. (2) information to verify the price offered (e.g., a copy of a current catalog or established price list; three invoices for the same or similar services, etc.); and (3) the completed Representations and Certifications required by FAR 52.212-3 and DFARS 252.212-7000. These representations and certifications are provided on the NAVAIRSYCOM Home Page for solicitations shown herein. Any changes to this RFQ will be sent electronically to the FEDBIZOPS as amendments. DELIVERY: The required completion date is 1 June 2004. APPLICABLE CLAUSES: This RFQ may incorporate one or more clauses or provisions by reference, with the same force and effect as if they were provided in full text. The full text of referenced provisions and/or clauses may be accessed electronically at the following cites, among others: http://www.arnet.gov/far/ OR http://farsite.hill.af.mil/. The following provisions and/or clauses are incorporated and apply to this RFQ: FAR 52.212-1, ?Instructions to Offerors ? Commercial Items (OCT 2000)? is incorporated by reference. FAR 52.212-2, ?Evaluation ? Commercial Items (JAN 1999),? is incorporated in full text, as follows: Evaluation-Commercial Items (Jan 1999) (a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers: _Price_________________________________________ __Past Performance__________________________ [Contracting Officer shall insert the significant evaluation factors, such as (i) technical capability of the item offered to meet the Government requirement; (ii) price; (iii) past performance (see FAR 15.304); (iv) small disadvantaged business participation; and include them in the relative order of importance of the evaluation factors, such as in descending order of importance.] Past performance is of equal importance when compared to price. [Contracting Officer state, in accordance with FAR 15.304, the relative importance of all other evaluation factors, when combined, when compared to price.] (b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s). NOT APPLICABLE. (c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award. (End of provision) FAR 52.212-3, ?Offeror Representations and Certifications ? Commercial Items (JAN 2004)? is incorporated by reference. The full text of this clause is posted on the NAVAIRSYSCOM Home Page for solicitations, as shown above. Offerors shall submit a completed copy of the representations and certifications at FAR 52.2123 with their proposal. FAR 52.212-4, ?Contract Terms and Conditions ? Commercial Items (OCT 2003),? is incorporated by reference. The following clauses are incorporated by reference as an addendum to FAR 52.212-4: DFARS 252.204-7004 Alternate A ? ?Required Central Contractor Registration (NOV 2003)? FAR 52.247-34 ? ?F.O.B. Destination (NOV 1991)? FAR 52.212-5, ?Contract Terms and Conditions Required to Implement Statutes or Executive Orders ? Commercial Items (APR 2004)? is incorporated in full text, as follows: Contract Terms and Conditions Required to Implement Statutes or Executive Orders-Commercial Items (Apr 2004) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clause, which is incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: 52.233-3, Protest after Award (Aug 1996) (31 U.S.C. 3553). (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] NOTE: For space limitation purposes, this clause has been modified to identify only the applicable clauses. _X_ (5)(i) 52.219-6, Notice of Total Small Business Set-Aside (June 2003) (15 U.S.C. 644). _X_ (13) 52.222-3, Convict Labor (June 2003) (E.O. 11755). _X_ (14) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jan 2004) (E.O. 13126). _X_ (15) 52.222-21, Prohibition of Segregated Facilities (Feb 1999). _X_ (16) 52.222-26, Equal Opportunity (Apr 2002) (E.O. 11246). _X_ (17) 52.222-35, Equal Opportunity for Special Disabled Veterans, Veterans of the Vietnam Era, and Other Eligible Veterans (Dec 2001) (38 U.S.C. 4212). _X_ (18) 52.222-36, Affirmative Action for Workers with Disabilities (Jun 1998) (29 U.S.C. 793). _X_ (19) 52.222-37, Employment Reports on Special Disabled Veterans, Veterans of the Vietnam Era, and Other Eligible Veterans (Dec 2001) (38 U.S.C. 4212). _X_ (24) 52.225-13, Restrictions on Certain Foreign Purchases (Dec 2003) (E.o.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). _X_ (29) 52.232-33, Payment by Electronic Funds Transfer-Central Contractor Registration (Oct 2003) (31 U.S.C. 3332). (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] _X_ (1) 52.222-41, Service Contract Act of 1965, as Amended (May 1989) (41 U.S.C. 351, et seq.). (d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records-Negotiation. (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract. (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. (e)(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in paragraphs (i) through (vi) of this paragraph in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (i) 52.219-8, Utilization of Small Business Concerns (Oct 2000) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $500,000 ($1,000,000 for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (ii) 52.222-26, Equal Opportunity (Apr 2002) (E.O. 11246). (iii) 52.222-35, Equal Opportunity for Special Disabled Veterans, Veterans of the Vietnam Era, and Other Eligible Veterans (Dec 2001) (38 U.S.C. 4212). (iv) 52.222-36, Affirmative Action for Workers with Disabilities (June 1998) (29 U.S.C. 793). (v) 52.222-41, Service Contract Act of 1965, as Amended (May 1989), flow down required for all subcontracts subject to the Service Contract Act of 1965 (41 U.S.C. 351, et seq.). (vi) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Apr 2003) (46 U.S.C. Appx 1241 and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. (2) While not required, the contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations. (End of clause) DFARS 252.212-7000, ?Offeror Representations and Certifications ? Commercial Items (NOV 1995),? is incorporated by reference. The full text of this clause is posted on the NAVAIRSYSCOM Home Page for solicitations, as shown above. Offerors shall submit a completed copy of the representations and certifications at DFARS 252.2127000 with their proposal. DFARS 252.212-7001, ?Contract Terms and Conditions Required to Implement Statutes or Executive Orders Applicable to Defense Acquisitions of Commercial Items (JAN 2004),? is incorporated in full text, as follows: CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS APPLICABLE TO DEFENSE ACQUISITIONS OF COMMERCIAL ITEMS (JAN 2004) (a) The Contractor agrees to comply with the following Federal Acquisition Regulation (FAR) clause which, if checked, is included in this contract by reference to implement a provision of law applicable to acquisitions of commercial items or components. _____ 52.203-3 Gratuities (APR 1984) (10 U.S.C. 2207) (b) The Contractor agrees to comply with any clause that is checked on the following list of Defense FAR Supplement clauses which, if checked, is included in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items or components. NOTE: For space limitation purposes, this clause has been modified to identify only the applicable clauses: X 252.225-7001 Buy American Act and Balance of Payments Program (APR 2003) (41 U.S.C. 10a-10d, E.O. 10582). __X___ 252.225-7021 Trade Agreements (JAN 2004) (19 U.S.C. 2501-2518 and 19 U.S.C. 3301 note). __X___ 252.225-7036 Buy American Act--Free Trade Agreements--Balance of Payments Program (JAN 2004) (___ Alternate I) (JAN 2004) (41 U.S.C. 10a-10d and 19 U.S.C. 3301 note). (c) In addition to the clauses listed in paragraph (e) of the Contract Terms and Conditions Required to Implement Statutes or Executive Orders--Commercial Items clause of this contract (FAR 52.212-5), the Contractor shall include the terms of the following clauses, if applicable, in subcontracts for commercial items or commercial components, awarded at any tier under this contract: 252.225-7014 Preference for Domestic Specialty Metals, Alternate I (APR 2003) (10 U.S.C. 2533a). 252.247-7023 Transportation of Supplies by Sea (MAY 2002) (10 U.S.C. 2631). 252.247-7024 Notification of Transportation of Supplies by Sea (MAR 2000) (10 U.S.C. 2631). (End of clause) FAR 52.247-34, ?F.O.B. Destination (NOV 1991),? is incorporated by reference. FAR 52.242-17, ?Government Delay of Work (APR 1984),? is incorporated by reference. FAR 52.237-2, ?Protection of Government Buildings, Equipment, and Vegetation (APR 1984),? is incorporated by reference. The Naval Air Systems Command clause 5252.211-9052, ?Government Installation Work Schedule,? is incorporated in full text, as follows: GOVERNMENT INSTALLATION WORK SCHEDULE (OCT 1994) (a) The Holidays applicable to this contract are: New Year?s Day, Martin Luther King?s Birthday, President?s Birthday, Memorial Day, Independence Day, Labor Day, Columbus Day, Veteran?s Day, Thanksgiving Day, and Christmas Day. (b) In the event that the contractor is prevented from performance as the result of an Executive Order or an administrative leave determination that applies to the using activity, such time may be charged to the contract as a direct cost provided such charges are consistent with the contractor?s accounting practices. In the event that any of the above holidays occur on a Saturday or Sunday, then such holiday shall be observed by the assigned Government employees at the using activity. (End of clause) QUESTIONS: Questions regarding this commercial RFQ may be emailed to Ms. Mary Roland, Contract Specialist, at mary.roland@navy.mil no later than 28 April 2004. NO QUESTONS SUBMITTED BY TELEPHONE OR FACSIMILE WILL BE ACCEPTED OR RESPONDED TO. All responses will be posted to the FEDBIZOPS as an amendment. CENTRAL CONTRACTOR REGISTRATION (CCR): To be eligible for contract award or payment by any DOD activity, offerors must be registered in the CCR database. Information on registering and annual certification requirements may be obtained by accessing the CCR database at https://www.ccr.dlis.dla.mil/ccr/scripts/index.html. RESPONSE DEADLINE: Proposals are due no later than 3:00 p.m. (EDT) on 4 May 2004 to NAVAIR/AD Contracts (AIR-2.5.1), Building 588, Suite 2, Code 251711 (Mary Roland), Naval Air Warfare Center Aircraft Division, 47253 Whalen Road, Unit 588, Patuxent River, Maryland 20670-1463. Quotes shall reference solicitation N00421-04-T-0131.
- Place of Performance
- Address: AIRCRAFT LAUNCH AND RECOVERY FACILITY, PATUXENT RIVER MARYLAND
- Zip Code: 20670
- Country: USA
- Zip Code: 20670
- Record
- SN00570385-W 20040423/040421212442 (fbodaily.com)
- Source
-
FedBizOpps.gov Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |