SOLICITATION NOTICE
38 -- AE 150S Asphalt Emulsion
- Notice Date
- 7/9/2005
- Notice Type
- Solicitation Notice
- Contracting Office
- MWR - Black Hills Contracting - Mt Rushmore National Memorial 13000 Hwy 244, Bldg. 31, Suite 1 Keystone SD 57751
- ZIP Code
- 57751
- Solicitation Number
- Q1505050133
- Response Due
- 8/1/2005
- Archive Date
- 7/8/2006
- Small Business Set-Aside
- Total Small Business
- Description
- AE 150S Asphalt Emulsion. Must meet SDDOT 2004 Standard Specifications for Roads and Bridges, Division III, Section 890.2E. Temperature of material when delivered shall be between 160 and 180 degrees F. Material shall be delivered to Wind Cave NP by tanker for transer into the park's distributor during a chip seal project on US Hwy 385 within the park and also to Jewel Cave NM during a chip seal project on various park roads. The project at Wind Cave NP is scheduled for the week of 8/15/05 and at Jewel Cave NM for the week of 8/22/05, but could be delayed due to weather. Actual delivery date and times for each tanker load shall be as directed by the Contracting Officer's Representative during the implementation of the project. Contractor shall have sufficient drivers and equipment available as to not cause a delay in the progress of the project. Contractor shall provide a hose suitable to transfer the material to the park's distributor. Quantity is estimated. Actual quantity awarded will depend on unit price and availability of funds. Measurement will be the actual number of tons, to the nearest hundredth of a ton, verified by weight tickets, schduled and deliverd to the jobsite. Payment will be made at the contract unit price. Demurrage. Measurement will be the number of hours to the nearest quarter hour that tanker driver waits to unload. Time wiil start two hours after the scheduled arrrival time or two hours after the actual arrival time, whichever is later, and extend until tanker load is empty or to the time that project work ends for the day, whichever is sooner. Estimated price range for this project is between $25,000 and $100,000. Product and Service code: 5610, NAICS code: 324121, small business size standard is 500 employees. This solicitation will be available only on the Department of the Interior (DOI) website at http://ideasec.nbc.gov O/A July 15, 2005 and will close on August 1, 2005 at 04:30 pm MST, unless extensions are issued in an amendment. Paper copies will not be available. Interested parties must be registered in the Central Contractor Registration (CCR), www.ccr.gov, to download and/or submit a quote electronically on this solicitation.
- Web Link
-
Please click here to view more details.
(http://ideasec.nbc.gov/j2ee/announcementdetail.jsp?serverId=NP144302&objId=1860665)
- Place of Performance
- Address: Wind Cave National Park 26611 US Hwy 385 Hot Springs, SD 57747-9430 and Jewel Cave National Monument RR 1, Box 60AA Custer, SD 57730-9608
- Zip Code: 57751
- Country: USA
- Zip Code: 57751
- Record
- SN00844155-W 20050711/050709211628 (fbodaily.com)
- Source
-
FedBizOpps.gov Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |