SOLICITATION NOTICE
C -- Indefinite Delivery Indefinite Quantity Contract for Architect-Engineer Services for Preparation of Plans and Specifications for Structural Projects Various NAVFAC Hawaii Areas
- Notice Date
- 10/3/2007
- Notice Type
- Solicitation Notice
- NAICS
- 541330
— Engineering Services
- Contracting Office
- Department of the Navy, Naval Facilities Engineering Command, NAVFAC Hawaii, Acquisition 400 Marshall Road, Pearl Harbor, HI, 96860-3139, UNITED STATES
- ZIP Code
- 00000
- Solicitation Number
- N62478-08-R-5001
- Response Due
- 11/2/2007
- Archive Date
- 11/16/2007
- Point of Contact
- Kimberlee Fujimoto, Contracting Officer, Phone (808) 474-9392, Fax (808) 474-1543, - Curtis Ogawa, Contracting Officer, Phone (808) 474-6322, Fax (808) 474-3398
- E-Mail Address
-
kimberlee.fujimoto@navy.mil, curtis.ogawa@navy.mil
- Small Business Set-Aside
- Total Small Business
- Description
- This solicitation is a 100% set-aside for small business concerns. The small business size standard classification is NAICS 541330 ($4.5 M in annual receipts). Services include, but are not limited to design and engineering services for various structural projects with associated multi-discipline architect-engineering support services. The services may include, but not limited to engineering studies; preparation of plans, specification, cost estimates, and parametric cost estimates; as-built drawings; and post construction services. Projects may involve new construction, alteration, repair, and installation of structural facilities and systems. If asbestos or hazardous materials exist, the Architect-Engineer (A-E) contractor shall identify and provide for their disposal in the required documents in accordance with applicable rules and regulations pertaining to such hazardous materials. The selected A-E may be required to participate in a pre-fee meeting within seven days of notification and provide a fee proposal within ten days of the meeting. The contract will be of the Indefinite Quantity type where the work will be required on an as needed basis during the life of the contract providing the government and contractor agree on the amount. Each project contract will be a firm fixed price A-E Contract. The Government will determine the delivery order amount by using rates negotiated and negotiate the effort required to perform the particular project. The contract term will be a base year and two one-year option years. The Government reserves the right to exercise the option years to extend the contract term. The maximum value for the contract inclusive of all options shall not exceed $5,000,000. The Government guarantees a minimum of $10,000. There will be no future synopsis in the event the options included in the contract are exercised. Estimated construction cost of project is between $25,000 and $25,000,000. Estimated date of contract award is April 2008. Proposals may be subject to an advisory audit performed by the Defense Contract Audit Agency. The following selection evaluation criteria, in order of importance, will be used in the evaluation of A-E firms: (1) Professional qualifications of firm and staff proposed for the design of the repair, alteration, maintenance and structural engineering investigation of buildings, structures, bridges, and waterfront facilities (piers and wharves) including underwater inspections and geotechnical investigations in tropical environments similar to Hawaii; (2) Specialized recent experience and technical competence of firm or particular staff members proposed for the design of the repair, alteration, maintenance and structural engineering investigation of buildings, structures, bridges, and waterfront facilities (piers and wharves) including underwater inspections and geotechnical investigations in tropical environments similar to Hawaii; (3) Past performance on contracts with Government agencies and private industry in terms of cost control, quality of work, and compliance with performance schedules; (4) Capacity to accomplish the work in the required time; (5) Knowledge and demonstrated experience in applying sustainability concepts and principles to facilities and infrastructure problems through an integrated design approach; (6) A-Es quality control program experience; (7) Location in the general geographical area of the project and knowledge of the locality of the project; provided, that application of this criterion leaves an appropriate number of qualified firms, given the nature and size of the project; (8) Volume of work previously awarded to the firm by the Department of Defense shall also be considered, with the object of effecting an equitable distribution of Department of Defense A-E contracts among qualified A-E firms and firms that have not had Department of Defense contracts. Include a summary of qualifications in narrative discussion addressing each of the above selection evaluation criteria on the SF 330, Part 1, Section H. If necessary, continue on plain bond paper. For selection criteria (3) the government will also evaluate each firms past performance and performance rating(s) from the Architect-Engineer Contract Administration Support System (ACASS) during the evaluation process, which can affect the selection outcome. The offerors are reminded that in order to receive proposal evaluation benefit as SDB or HUBZone SB either as prime or subconsultant, proposed SDBs and HUBZoneSBs must be certified by the Small Business Administration. Prime contractors may determine whether a prospective subconsultant is a certified SDB or HUBZone by accessing the Central Contractor Registration (CCR) at www.ccr.gov. The Federal Acquisitions Regulations (FAR) will require the use of On-Line Representations and Certifications Application (ORCA) in Federal solicitations as part of the proposal submission process. Offerors are required to complete the ORCA on-line via website http://orca.bpn.gov. Refer to FAR Clauses 52.204-7 Central Contractor Registration (Jul 2006) and 52.204-8 Annual Representations and Certifications (Jan 2006). The selected firm, its subsidiaries or affiliates that design or prepare specifications for a construction contract cannot provide the construction services for the same contract. This includes concept design, which includes preparation of project programming documents (DD1391), facility sitting studies, environmental assessments, or other activities that result in identification of project scope and cost. The prime firm and consultants for this contract will be required to perform throughout the contract term. A-E firms meeting the requirements described in this announcement are invited to submit a completed Standard Form 330, Architect Engineer Qualifications. The submittal/delivery address is Commander, NAVFAC HAWAII (Code OPHACQ2), 400 Marshall Road, Building A-13, Pearl Harbor, HI 96860-3139, (A-E Solicitation No. N62478-08-R-5001). This address is for all deliveries, including US Mail, courier service and/or personal delivery services; no other address is acceptable. The delivery address is inside a military installation, therefore, strict securities measures are in force; anticipate delays. Interested firms must allow sufficient time for receipt of submission. Consultants to the prime A-E firm are required to submit only Part II of the SF 330. Two copies of your SF 330 are required: One paper copy and one electronic copy on a CD. This solicitation requires all interested firms to have an email address. Notifications will be via email, therefore, email address must be shown on the SF 330, Part 1, Section B8. Firms responding to this announcement by Friday, November 2, 2007 will be considered. Firms must submit forms by 2:00 p.m. Hawaiian Standard Time (HST). This is not a request for a proposal. Point of Contact is Kimberlee Fujimoto, Contracting Officer, Phone (808) 474-9392, Fax (808) 474-3398, email kimberlee.fujimoto@navy.mil
- Place of Performance
- Address: Various Locations in All Areas Under the Cognizance of NAVFAC HAWAII
- Zip Code: 96860
- Country: UNITED STATES
- Zip Code: 96860
- Record
- SN01428003-W 20071005/071003223832 (fbodaily.com)
- Source
-
FedBizOpps Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |