SOLICITATION NOTICE
Z -- The project consists of furnishing all plant, labor, equipment, materials, and transportation and performing all required work in accordance with the plans and specifications for replacement of asphalt shingle roofs.
- Notice Date
- 5/30/2012
- Notice Type
- Combined Synopsis/Solicitation
- NAICS
- 238160
— Roofing Contractors
- Contracting Office
- MICC - Fort Riley, 1792 12th Street, Fort Riley, KS 66442
- ZIP Code
- 66442
- Solicitation Number
- W911RX-12-T-0048
- Response Due
- 6/6/2012
- Archive Date
- 8/5/2012
- Point of Contact
- Julie A Roberts, 785-240-3193
- E-Mail Address
-
MICC - Fort Riley
(julie.a.roberts75.civ@mail.mil)
- Small Business Set-Aside
- Total Small Business
- Description
- This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; proposals are being requested and a written solicitation will not be issued. This is a combined synopsis/solicitation for SAP Construction prepared in accordance with the format in Subpart 13.005, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; proposals are being requested and a written solicitation will not be issued. General Information Document Type: Combine Synopsis Solicitation Solicitation Number: W911RX-12-T-00048 Posted Date: 30 May 2012 Response Date: 06 June 2012; 2:00pm (CST) Industry Questions shall be addressed to the Julie Roberts via email no later than 4 June 2012: 3:00pm (CST) Class Code: Z Set Aside: Total Small Business Contracting Office Address Mission Installation Contracting Command Attn: Julie A. Roberts, Contract Specialist 1792 12th Street Fort Riley, Kansas 66442 785-240-3193 Julie.a.roberts75.civ@mail.mil Description: This is a combined synopsis/solicitation for SAP Construction prepared in accordance with the format in Subpart 13.005, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; proposals are being requested and a written solicitation will not be issued. We have a requirement to Replace Asphalt Shingle Roofs on Buildings on Fort Riley. Project completion will be in accordance with FAR Clause 52. 211-10. The anticipated contract will have Contract Line Item Number (CLIN)0001. A site visit will not be required. The Contractor shall be required to complete Technical Exhibit (TE) #4 Pricing Schedule Matrix for Buildings 376, 405, 406, 408, and 748 in accordance with TE #1 Scope of Work and submit with its quote. TE #1 - Scope of Work TE #2 - Maps, Plans and Drawings (Each Building) TE #3 - Davis Bacon Wage Determination KS8, Building, 04202012 TE #4 - Pricing Schedule Matrix TE #5 - WAWF Invoice and Delivery Instructions CLAUSES INCORPORATED BY REFERENCE 52.202-1 Definitions JAN 2012 52.204-7 Central Contractor Registration FEB 2012 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-6 Davis Bacon Act JUL 2005 52.222-7 Withholding of Funds FEB 1988 52.222-8 Payrolls and Basic Records JUN 2010 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) JUL 2005 52.222-12 Contract Termination-Debarment FEB 1988 52.222-13 Compliance with Davis-Bacon and Related Act Regulations. FEB 1988 52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility FEB 1988 52.222-22 Previous Contracts And Compliance Reports FEB 1999 52.222-27 Affirmative Action Compliance Requirements for Construction FEB 1999 52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997 52.223-6 Drug-Free Workplace MAY 2001 52.228-2 Additional Bond Security OCT 1997 52.228-3 Worker's Compensation Insurance (Defense Base Act) APR 1984 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.232-5 Payments under Fixed-Price Construction Contracts SEP 2002 52.232-17 Interest OCT 2010 52.232-23 Alt I Assignment of Claims (Jan 1986) - Alternate I APR 1984 52.232-27 Prompt Payment for Construction Contracts OCT 2008 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements APR 1984 52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-16 Quantity Surveys APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-14 Suspension of Work APR 1984 52.243-5 Changes and Changed Conditions APR 1984 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.249-10 Default (Fixed-Price Construction) APR 1984 252.201-7000 Contracting Officer's Representative DEC 1991 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7004 Alt A Central Contractor Registration Alternate A SEP 2007 252.211-7003 Alt I Item Identification and Valuation (Jun 2011) Alternate I DEC 2011 252.223-7006 Prohibition On Storage And Disposal Of Toxic And Hazardous Materials APR 2012 252.225-7001 Buy American Act And Balance Of Payments Program OCT 2011 252.227-7033 Rights in Shop Drawings APR 1966 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports MAR 2008 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment MAR 1998 252.246-7000 Material Inspection And Receiving Report MAR 2008 252.247-7023 Transportation of Supplies by Sea MAY 2002 252.247-7024 Notification Of Transportation Of Supplies By Sea MAR 2000 CLAUSES INCORPORATED BY FULL TEXT 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 120 days. The time stated for completion shall include final cleanup of the premises. (End of clause) 52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000) (a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $155.72 for each calendar day of delay until the work is completed or accepted. (b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause. (End of clause) 52.213-4 TERMS AND CONDITIONS--SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL ITEMS) (MAR 2012) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are incorporated by reference: (1) The clauses listed below implement provisions of law or Executive order: (i) 52.222-3, Convict Labor (June 2003) (E.O. 11755). (ii) 52.222-21, Prohibition of Segregated Facilities (Feb 1999) (E.O. 11246). (iii) 52.222-26, Equal Opportunity (MAR 2007) (E.O. 11246). (iv) 52.222-50, Combating Trafficking in Persons (FEB 2009) (22 U.S.C. 7104(g)). (v) 52.225-13, Restrictions on Certain Foreign Purchases (FEB 2006) (E.o.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). (vi) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553). (vii) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78). (2) Listed below are additional clauses that apply: (i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (FEB 2012) (ii) 52.232-1, Payments (Apr 1984). (iii) 52.232-8, Discounts for Prompt Payment (Feb 2002). (iv) 52.232-11, Extras (Apr 1984). (v) 52.232-25, Prompt Payment (OCT 2008). (vi) 52.233-1, Disputes (JUN 2008). (vii)52.244-6, Subcontracts for Commercial Items (JAN 2011). (viii) 52.253-1, Computer Generated Forms (Jan 1991). (b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply: (1) The clauses listed below implement provisions of law or Executive order: (i) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (MAR 2012) (E.O. 13126). (Applies to contracts for supplies exceeding the micro-purchase threshold.) (ii) 52.222-20, Walsh-Healey Public Contracts Act (OCT 2010) (41 U.S.C. 35-45) (Applies to supply contracts over $15,000 in the United States, Puerto Rico, or the U.S. Virgin Islands). (iii) 52.222-35, Equal Opportunity for Veterans (SEP 2010) (38 U.S.C. 4212) (applies to contracts of $100,000 or more). (iv) 52.222-36, Affirmative Action for Workers with Disabilities (OCT 2010) (29 U.S.C. 793). (Applies to contracts over $15,000, unless the work is to be performed outside the United States by employees recruited outside the United States.) (For purposes of this clause, United States includes the 50 States, the District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, and Wake Island.) (v) 52.222-37, Employment Reports on Veterans (SEP 2010) (38 U.S.C. 4212) (applies to contracts of $100,000 or more). (vi) 52.222-41, Service Contract Act of 1965 (Nov 2007) (41 U.S.C. 351, et seq.) (Applies to service contracts over $2,500 that are subject to the Service Contract Act and will be performed in the United States, District of Columbia, Puerto Rico, the Northern Mariana Islands, American Samoa, Guam, the U.S. Virgin Islands, Johnston Island, Wake Island, or the outer continental shelf lands.). (vii) 52.223-5, Pollution Prevention and Right-to-Know Information (May 2011) (E.O. 13423) (Applies to services performed on Federal facilities). (viii) 52.223-15, Energy Efficiency in Energy-Consuming Products (DEC 2007) (42 U.S.C. 8259b) (Unless exempt pursuant to 23.204, applies to contracts when energy-consuming products listed in the ENERGY STAR Program or Federal Energy Management Program (FEMP) will be-- (A) Delivered; (B) Acquired by the Contractor for use in performing services at a Federally-controlled facility; (C) Furnished by the Contractor for use by the Government; or (D) Specified in the design of a building or work, or incorporated during its construction, renovation, or maintenance.) (ix) 52.225-1, Buy American Act--Supplies (FEB 2009) (41 U.S.C. 10a-10d) (Applies to contracts for supplies, and to contracts for services involving the furnishing of supplies, for use in the United States or its outlying areas, if the value of the supply contract or supply portion of a service contract exceeds the micro-purchase threshold and the acquisition-- (A) Is set aside for small business concerns; or (B) Cannot be set aside for small business concerns (see 19.502-2), and does not exceed $25,000.) (x) 52.232-33, Payment by Electronic Funds Transfer--Central Contractor Registration (May 1999). (Applies when the payment will be made by electronic funds transfer (EFT) and the payment office uses the Central Contractor Registration (CCR) database as its source of EFT information.) (xi) 52.232-34, Payment by Electronic Funds Transfer--Other than Central Contractor Registration (Oct 2003). (Applies when the payment will be made by EFT and the payment office does not use the CCR database as its source of EFT information.) (xii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C. Appx 1241). (Applies to supplies transported by ocean vessels (except for the types of subcontracts listed at 47.504(d).) (2) Listed below are additional clauses that may apply: (i) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (DEC 2010) (Applies to contracts over $30,000). (ii) 52.211-17, Delivery of Excess Quantities (SEPT 1989) (Applies to fixed-price supplies). (iii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (MAR 2009) (Pub. L. 110-247) (Applies to contracts greater than $25,000 that provide for the provision, the service, or the sale of food in the United States.) (iv) 52.247-29, F.o.b. Origin (FEB 2006) (Applies to supplies if delivery is f.o.b. origin). (v) 52.247-34, F.o.b. Destination (NOV 1991) (Applies to supplies if delivery is f.o.b. destination). (c) FAR 52.252-2, Clauses Incorporated by Reference (FEB 1998). This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): http://farsite.hill.af.mil/vffara.htm (d) Inspection/Acceptance. The Contractor shall tender for acceptance only those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. The Government must exercise its postacceptance rights-- (1) Within a reasonable period of time after the defect was discovered or should have been discovered; and (2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item. (e) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence, such as acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence. (f) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges that the Contractor can demonstrate to the satisfaction of the Government, using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred that reasonably could have been avoided. (g) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience. (h) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract. (End of clause) 52.219-1 SMALL BUSINESS PROGRAM REPRESENTATIONS (APR 2012) (a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238160 (2) The small business size standard is $14.0 (3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees. (b) Representations. (1) The offeror represents as part of its offer that it ( ) is, ( ) is not a small business concern. (2) (Complete only if the offeror represented itself as a small business concern in paragraph (b)(1) of this provision.) The offeror represents, for general statistical purposes, that it ( ) is, ( ) is not a small disadvantaged business concern as defined in 13 CFR 124.1002. (3) (Complete only if the offeror represented itself as a small business concern in paragraph (b)(1) of this provision.) The offeror represents as part of its offer that it ( ) is, ( ) is not a women-owned small business concern. (4) Women-owned small business (WOSB) concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (b)(3) of this provision.] The offeror represents as part of its offer that-- (i) It ( ) is, ( ) is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and (ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (b)(4)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ----------.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation. (5) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a women-owned small business concern eligible under the WOSB Program in (b)(4) of this provision.] The offeror represents as part of its offer that-- (i) It ( ) is, ( ) is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and (ii) It [ ] is, [ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (b)(5)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: ----------.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation. (6) (Complete only if the offeror represented itself as a small business concern in paragraph (b)(1) of this provision.) The offeror represents as part of its offer that it ( ) is, ( ) is not a veteran-owned small business concern. (7) (Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (b)(6) of this provision.) The offeror represents as part of its offer that it ( ) is, ( ) is not a service-disabled veteran-owned small business concern. (8) (Complete only if the offeror represented itself as a small business concern in paragraph (b)(1) of this provision.) The offeror represents, as part of its offer, that-- (i) It [squ] is, [squ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and (ii) It [squ] is, [squ] is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (b)(8)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: --------.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation. (c) Definitions. As used in this provision-- "Economically disadvantaged women-owned small business (EDWOSB) concern" means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business concern eligible under the WOSB Program. Service-disabled veteran-owned small business concern-- (1) Means a small business concern-- (i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and (ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran. (2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16). "Small business concern," means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and the size standard in paragraph (a) of this provision. Veteran-owned small business concern means a small business concern-- (1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and (2) The management and daily business operations of which are controlled by one or more veterans. "Women-owned small business concern," means a small business concern -- (1) That is at least 51 percent owned by one or more women; in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and (2) Whose management and daily business operations are controlled by one or more women. "Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127)", means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States. (d) Notice. (1) If this solicitation is for supplies and has been set aside, in whole or in part, for small business concerns, then the clause in this solicitation providing notice of the set-aside contains restrictions on the source of the end items to be furnished. (2) Under 15 U.S.C. 645(d), any person who misrepresents a firm's status as a business concern that is small, HUBZone small, small disadvantaged, service-disabled veteran-owned small, economically disadvantaged women-owned small, or women-owned small eligible under the WOSB Program in order to obtain a contract to be awarded under the preference programs established pursuant to section 8, 9, 15, 31, and 36 of the Small Business Act or any other provision of Federal law that specifically references section 8(d) for a definition of program eligibility, shall- (i) Be punished by imposition of fine, imprisonment, or both; (ii) Be subject to administrative remedies, including suspension and debarment; and (iii) Be ineligible for participation in programs conducted under the authority of the Act. (End of provision) 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999) (a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation. (b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows: Goals for minority participation for each tradeGoals for female participation for each trade 6.5%6.9% These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office. (c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed. (d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the -- (1) Name, address, and telephone number of the subcontractor; (2) Employer's identification number of the subcontractor; (3) Estimated dollar amount of the subcontract; (4) Estimated starting and completion dates of the subcontract; and (5) Geographical area in which the subcontract is to be performed. (e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Fort Riley of Riley County, Kansas (End of provision) 52.225-9 BUY AMERICAN ACT-CONSTRUCTION MATERIALS (SEP 2010) (a) Definitions. As used in this clause-- Commercially available off-the-shelf (COTS) item- (1) Means any item of supply (including construction material) that is-- (i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101); (ii) Sold in substantial quantities in the commercial marketplace; and (iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and (2) Does not include bulk cargo, as defined in section 3 of the Shipping Act of 1984 (46 U.S.C. App. 1702), such as agricultural products and petroleum products. Component means an article, material, or supply incorporated directly into a construction material. Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material. Cost of components means-- (1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or (2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material. Domestic construction material means-- (1) An unmanufactured construction material mined or produced in the United States; (2) A construction material manufactured in the United States, if-- (i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or (ii) The construction material is a COTS item. Foreign construction material means a construction material other than a domestic construction material. United States means the 50 States, the District of Columbia, and outlying areas. (b) Domestic preference. (1) This clause implements the Buy American Act (41 U.S.C. 10a-10d) by providing a preference for domestic construction material. In accordance with 41 U.S.C. 431, the component test of the Buy American Act is waived for construction material that is a COTS item (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause. (2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows: (3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that (i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent; (ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or (iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality. (c) Request for determination of inapplicability of the Buy American Act. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including-- (A) A description of the foreign and domestic construction materials; (B) Unit of measure; (C) Quantity; (D) Price; (E) Time of delivery or availability; (F) Location of the construction project; (G) Name and address of the proposed supplier; and (H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause. (ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause. (iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued). (iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination. (2) If the Government determines after contract award that an exception to the Buy American Act applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause. (3) Unless the Government determines that an exception to the Buy American Act applies, use of foreign construction material is noncompliant with the Buy American Act. (d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers: Foreign and Domestic Construction Materials Price Comparison ---------------------------------------------------------------------------------------------------------------- Construction material description Unit of measure Quantity Price (dollars) \1\ ---------------------------------------------------------------------------------------------------------------- Item 1 Foreign construction material......................................................................... Domestic construction material........................................................................ Item 2 Foreign construction material......................................................................... Domestic construction material........................................................................ ---------------------------------------------------------------------------------------------------------------- Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued). List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary. Include other applicable supporting information. (End of clause) 52.228-13 ALTERNATIVE PAYMENT PROTECTIONS (JULY 2000) (a) The Contractor shall submit one of the following payment protections: (i) A payment bond. (ii) An irrevocable letter of credit (ILC). (b) The amount of the payment protection shall be 100 percent of the contract price. (c) The submission of the payment protection is required within ___10___ days of contract award. (d) The payment protection shall provide protection for the full contract performance period plus a one-year period. (e) Except for escrow agreements and payment bonds, which provide their own protection procedures, the Contracting Officer is authorized to access funds under the payment protection when it has been alleged in writing by a supplier of labor or material that a nonpayment has occurred, and to withhold such funds pending resolution by administrative or judicial proceedings or mutual agreement of the parties. (f) When a tripartite escrow agreement is used, the Contractor shall utilize only suppliers of labor and material that signed the escrow agreement. (End of clause) 52.228-14 IRREVOCABLE LETTER OF CREDIT (DEC 1999) (a) "Irrevocable letter of credit" (ILC), as used in this clause, means a written commitment by a federally insured financial institution to pay all or part of a stated amount of money, until the expiration date of the letter, upon presentation by the Government (the beneficiary) of a written demand therefor. Neither the financial institution nor the offeror/Contractor can revoke or condition the letter of credit. (b) If the offeror intends to use an ILC in lieu of a bid bond, or to secure other types of bonds such as performance and payment bonds, the letter of credit and letter of confirmation formats in paragraphs (e) and (f) of this clause shall be used. (c) The letter of credit shall be irrevocable, shall require presentation of no document other than a written demand and the ILC (including confirming letter, if any), shall be issued/confirmed by an acceptable federally insured financial institution as provided in paragraph (d) of this clause, and-- (1) If used as a bid guarantee, the ILC shall expire no earlier than 60 days after the close of the bid acceptance period; (2) If used as an alternative to corporate or individual sureties as security for a performance or payment bond, the offeror/Contractor may submit an ILC with an initial expiration date estimated to cover the entire period for which financial security is required or may submit an ILC with an initial expiration date that is a minimum period of one year from the date of issuance. The ILC shall provide that, unless the issuer provides the beneficiary written notice of non-renewal at least 60 days in advance of the current expiration date, the ILC is automatically extended without amendment for one year from the expiration date, or any future expiration date, until the period of required coverage is completed and the Contracting Officer provides the financial institution with a written statement waiving the right to payment. The period of required coverage shall be: (i) For contracts subject to the Miller Act, the later of-- (A) One year following the expected date of final payment; (B) For performance bonds only, until completion of any warranty period; or (C) For payment bonds only, until resolution of all claims filed against the payment bond during the one-year period following final payment. (ii) For contracts not subject to the Miller Act, the later of-- (A) 90 days following final payment; or (B) For performance bonds only, until completion of any warranty period. (d) Only federally insured financial institutions rated investment grade or higher shall issue or confirm the ILC. The offeror/Contractor shall provide the Contracting Officer a credit rating that indicates the financial institution has the required rating(s) as of the date of issuance of the ILC. Unless the financial institution issuing the ILC had letter of credit business of less than $25 million in the past year, ILCs over $5 million must be confirmed by another acceptable financial institution that had letter of credit business of less than $25 million in the past year. (e) The following format shall be used by the issuing financial institution to create an ILC: _______________________________________________ [Issuing Financial Institution's Letterhead or Name and Address] Issue Date ____________ IRREVOCABLE LETTER OF CREDIT NO. __________ Account party's name _____________________________ Account party's address ___________________________ For Solicitation No. _______________(for reference only) TO: [U.S. Government agency] [U.S. Government agency's address] 1. We hereby establish this irrevocable and transferable Letter of Credit in your favor for one or more drawings up to United States $________. This Letter of Credit is payable at [issuing financial institution's and, if any, confirming financial institution's] office at [issuing financial institution's address and, if any, confirming financial institution's address] and expires with our close of business on ________, or any automatically extended expiration date. 2. We hereby undertake to honor your or the transferee's sight draft(s) drawn on the issuing or, if any, the confirming financial institution, for all or any part of this credit if presented with this Letter of Credit and confirmation, if any, at the office specified in paragraph 1 of this Letter of Credit on or before the expiration date or any automatically extended expiration date. 3. [This paragraph is omitted if used as a bid guarantee, and subsequent paragraphs are renumbered.] It is a condition of this Letter of Credit that it is deemed to be automatically extended without amendment for one year from the expiration date hereof, or any future expiration date, unless at least 60 days prior to any expiration date, we notify you or the transferee by registered mail, or other receipted means of delivery, that we elect not to consider this Letter of Credit renewed for any such additional period. At the time we notify you, we also agree to notify the account party (and confirming financial institution, if any) by the same means of delivery. 4. This Letter of Credit is transferable. Transfers and assignments of proceeds are to be effected without charge to either the beneficiary or the transferee/assignee of proceeds. Such transfer or assignment shall be only at the written direction of the Government (the beneficiary) in a form satisfactory to the issuing financial institution and the confirming financial institution, if any. 5. This Letter of Credit is subject to the Uniform Customs and Practice (UCP) for Documentary Credits, 1993 Revision, International Chamber of Commerce Publication No. 500, and to the extent not inconsistent therewith, to the laws of _____________________ [state of confirming financial institution, if any, otherwise state of issuing financial institution]. 6. If this credit expires during an interruption of business of this financial institution as described in Article 17 of the UCP, the financial institution specifically agrees to effect payment if this credit is drawn against within 30 days after the resumption of our business. Sincerely, _______________________ [Issuing financial institution] (f) The following format shall be used by the financial institution to confirm an ILC: _______________________________________________ [Confirming Financial Institution's Letterhead or Name and Address] (Date) __________________ Our Letter of Credit Advice Number _________________ Beneficiary: ______________ [U.S. Government agency] Issuing Financial Institution: _______________________ Issuing Financial Institution's LC No.: _______________ Gentlemen: 1. We hereby confirm the above indicated Letter of Credit, the original of which is attached, issued by __________ [name of issuing financial institution] for drawings of up to United States dollars ___________/U.S. $_______ and expiring with our close of business on _____________ [the expiration date], or any automatically extended expiration date. 2. Draft(s) drawn under the Letter of Credit and this Confirmation are payable at our office located at ___________________. 3. We hereby undertake to honor sight draft(s) drawn under and presented with the Letter of Credit and this Confirmation at our offices as specified herein. 4. [This paragraph is omitted if used as a bid guarantee, and subsequent paragraphs are renumbered.] It is a condition of this confirmation that it be deemed automatically extended without amendment for one year from the expiration date hereof, or any automatically extended expiration date, unless: (a) At least 60 days prior to any such expiration date, we shall notify the Contracting Officer, or the transferee and the issuing financial institution, by registered mail or other receipted means of delivery, that we elect not to consider this confirmation extended for any such additional period; or (b) The issuing financial institution shall have exercised its right to notify you or the transferee, the account party, and ourselves, of its election not to extend the expiration date of the Letter of Credit. 5. This confirmation is subject to the Uniform Customs and Practice (UCP) for Documentary Credits, 1993 Revision, International Chamber of Commerce Publication No. 500, and to the extent not inconsistent therewith, to the laws of ________ [state of confirming financial institution]. 6. If this confirmation expires during an interruption of business of this financial institution as described in Article 17 of the UCP, we specifically agree to effect payment if this credit is drawn against within 30 days after the resumption of our business. Sincerely, ___________________________ [Confirming financial institution] (g) The following format shall be used by the Contracting Officer for a sight draft to draw on the Letter of Credit: SIGHT DRAFT __________________________ [City, State] (Date) _____________________ [Name and address of financial institution] Pay to the order of ______________ [Beneficiary Agency] ___________ the sum of United States $____________. This draft is drawn under Irrevocable Letter of Credit No. ___________________________________________. _______________________ [Beneficiary Agency] By: ___________________ (End of clause) 252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000) (a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer. (b) The Contractor shall-- (1) Check all drawings furnished immediately upon receipt; (2) Compare all drawings and verify the figures before laying out the work; (3) Promptly notify the Contracting Officer of any discrepancies; (4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and (5) Reproduce and print contract drawings and specifications as needed. (c) In general-- (1) Large-scale drawings shall govern small-scale drawings; and (2) The Contractor shall follow figures marked on drawings in preference to scale measurements. (d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications. (e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings: Title File Drawing No. (End of clause) ALTERNATIVE DISPUTE RESOLUTION (ADR) 5152.233-4000AMC-Level Protest Program (Sep 2011) (Local Clause) If you have complaints about this procurement, it is preferable that you first attempt to resolve those concerns with the responsible Contracting Officer. However, you can also protest to Headquarters (HQ) Army Materiel Command (AMC). The HQ AMC Level Protest Program is intended to encourage interested parties to seek resolution of their concerns within HQ AMC as an Alternative Dispute Resolution (ADR) form, rather than filing a protest with the Government Accountability Office (GAO) or other external form. Contract Award or performance is suspended during this protest to the same extent, and within the same time periods as if filed at the GAO. The HQ AMC protest decision goal is to resolve protests within 20 working days from filing. To be timely, protests must be filed within the periods specified in accordance with FAR Part 33.103. If you want to file a protest under the HQ AMC Level Protest Program, the protest must request resolution under that program and be sent to the address below. All other agency-level protests should be sent to the Contracting Officer for resolution. Packages sent by facsimile (Fax) should be addressed to: Headquarters (HQ) U.S. Army Material Command (AMC) Office of Command Counsel 4400 Martin Road Room: A6SE040.001 Redstone Arsenal, AL 35895-5000 FAX: (256) 450-8840 Packages sent by FedEx or UPS should be addressed to: Headquarters (HQ) U.S. Army Material Command (AMC) Office of Command Counsel 4400 Martin Road Room: A6SE040.001 Redstone Arsenal, AL 35895-5000 HQ AMC Level Protest procedures are found @ http://www.amc.army.mil/pa/COMMANDCOUNSEL.asp If Internet access is not available, contact the Contracting Officer or HQ AMC to obtain the HQ AMC Level Protest Procedures.
- Web Link
-
FBO.gov Permalink
(https://www.fbo.gov/notices/0c6f68ecf2ae2766b886dbf283b90db1)
- Place of Performance
- Address: MICC - Fort Riley 1792 12th Street, Fort Riley KS
- Zip Code: 66442
- Zip Code: 66442
- Record
- SN02761198-W 20120601/120530235635-0c6f68ecf2ae2766b886dbf283b90db1 (fbodaily.com)
- Source
-
FedBizOpps Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |