Loren Data's SAM Daily™

FBO DAILY - FEDBIZOPPS ISSUE OF MARCH 17, 2013 FBO #4131
DOCUMENT

C -- Renovate and Expand Emergency Department AE Design Project 632-353 - Attachment

Notice Date

3/15/2013
 

Notice Type

Attachment
 

NAICS

541310 — Architectural Services
 

Contracting Office

Department of Veterans Affairs;Network Contracting Office (10N3\NCO);James J. Peters VA Medical Center;130 West Kingsbridge Road;Bronx NY 10468-3904
 

ZIP Code

10468-3904
 

Solicitation Number

VA24313I0744
 

Response Due

4/30/2013
 

Archive Date

8/7/2013
 

Point of Contact

Patricia Cordero
 

E-Mail Address

ia.cordero@va.gov<br
 

Small Business Set-Aside

N/A
 

Description

THIS ANNOUNCEMENT IS NOT A REQUEST FOR PROPOSAL. THE GOVERNMENT WILL NOT PAY NOR REIMBURSE ANY COSTS ASSOCIATED WITH RESPONDING TO THIS REQUEST. THE GOVERNMENT IS UNDER NO OBLIGATION TO AWARD A CONTRACT AS A RESULT OF THIS ANNOUNCEMENT. The Department of Veterans Affairs is seeking a qualified Architect-Engineering (AE) firm to provide Schematics, Design Development, Construction Documents, Technical Specifications, Construction Period Services, Site Visits, Cost Estimates, As-Built Documentation, and all other related information for Project 632-353 Renovate and Expand Emergency Department. This Project will renovate the existing Emergency Department at Building 200 at the Northport VA Medical Center, 79 Middleville Road, Northport, NY 11768. This procurement is restricted to Veteran Owned Small Business (VOSB) and (SDVOSB) firms within 100 mile radius of the facility. This requirement is being procured in accordance with the Brooks Act as implemented in FAR Subpart 36.6. Applicable NAICS code is 541310 and small business size standard of $7 Million. Magnitude of Construction is between $5,000,000.00 and $10,000,000.00. This is a 100% Veteran-Owned Small Business Set Aside. The anticipated award date of the proposed A-E Contract is on or before September 30, 2013. Potential contractors must be registered in SAM (www.sam.gov) and visible/certified in Vet Biz (www.vetbiz.gov) at time of submission of their qualifications in order to be considered for an award. As a prospective offeror or bidder for this Veteran-Owned Small Business (VOSB) set aside, you are verifying your company meets the status requirements of a VOSB concern as established by 38 CFR Part 74. NOTE - Offerors are referred to VAAR Clause 852.219-11(c)(1): "Services (except construction) at least 50 percent of personnel for contract performance will be spent for employees of the concern or employees of other eligible service-disabled veteran-owned small business concerns". In order to assure compliance with this clause, all firms submitting a SF 330 for this Sources Sought Notice are required to indicate what percentage of the cost of contract performance will be expended by the concerns employees and in which discipline(s) and percentage of cost of contract performance to be expended (and in what disciplines) by any other subcontracted or otherwise used small or large business entity(s). Any subcontracted or otherwise business entity(s) used must be identified by name, office location and size/type of business (i.e. SDVOSB, VOSB, 8(a), large, etc). LOCATION This Project will Renovate and Expand the Emergency Department at Building 200 of the Northport VA Medical Center, 79 Middleville Road, Northport, NY 11768. SCOPE OF SERVICE REQUIRED PROJECT NO. 632-353, RENOVATE AND EXPAND EMERGENCY DEPARTMENT. This Project will renovate and modernize the Emergency Department at Bldg. No. 200 at the Northport VA Medical Center, 79 Middleville Road, Northport, NY 11768. The Project includes renovation of approximately 5,400 square feet of existing space located at the first floor of the main hospital building and construction of approximately 3,000 square feet of new space to be added to the building. Technical disciplines include but are not limited to site development, architectural, fire protection, interior design, structural, plumbing, sanitary, HVAC, electrical, equipment, automatic transport, asbestos abatement, space planning, critical path method, and estimating. The Project will comply with VA-adopted codes and standards including VA Directives, Design Manuals, Master Construction Specifications, Design Criteria and other Guidance on the Technical Information Library (http://www.cfm.va.gov/til/). I. SCHEMATICS. General Scope. The Architect-Engineer (A/E) shall review the program materials furnished by VA to ascertain the requirements of this phase of the work and shall prepare Schematic Documents illustrating the scale and relationship of Project components for review and approval of VA as further described in Supplement B, which details the minimum requirements for various A/E submissions. Services under this phase shall include but not be limited to all requirements as defined in Supplement B. II. DESIGN DEVELOPMENT DOCUMENTS. General Scope. The A/E shall review the program materials furnished by VA and all prior submissions to ascertain the requirements of this phase of the work and shall prepare Design Development Documents illustrating the scale and relationship of Project components for review and approval of VA as further described in Supplement B. Services under this phase shall include, but not be limited to the following: (1) Site Design; (2) Architectural Design including facility floor and roof plans, sections, elevations, preliminary selection of building systems and materials, development of dimensions, net program areas, gross areas and facility volumes; (3) Structural Design including materials and structural systems; (4) Mechanical and Electrical Design including heating, ventilating, air conditioning, refrigeration, plumbing, fire protection, and electrical design with economic and energy analyses and all critical systems; (5) Transport systems including recommendations for type, cost and location of all transport modes and terminals; (6) Space Planning; (7) Cost Estimate(s); (8) Energy Impact Studies; (9) Phasing Plans for Construction including making recommendations concerning construction contract arrangements and scheduling that will be advantageous to VA in terms of cost and timing; and (10) Presentations and Review Submissions. III. CONSTRUCTION DOCUMENTS. (a) General Scope. Based upon the approved Schematics and Design Development Documents, equipment layouts, other program materials furnished by VA, and any further adjustments in the design scope or quality of the Project, the A/E shall ascertain the requirements of this phase of the work and shall prepare, for approval by VA, Construction Documents and other documents setting forth in detail the requirements for bidding and contracting for the construction of the Project and as further described in Supplement B. Services under this phase shall include: (1) Site Design Documents setting forth in detail the site construction requirements; (2) Architectural Design Documents setting forth in detail the architectural construction requirements including complete floor and roof plans, elevations, sections, details, schedules, material and color selection, discipline coordination and fire safety systems and controls; (3) Structural Design Documents setting forth in detail the structural construction requirements including all structural plans, elevations, sections, details, schedules, and calculations sizing all columns, beams, slabs and coordinating the work with all other design disciplines; (4) Mechanical Design Documents setting forth in detail the mechanical construction requirements including all mechanical plans, elevations, sections, details, and schedules for heating, ventilating, air conditioning, refrigeration, plumbing, and fire protection; (5) Electrical Design Documents setting forth in detail the electrical construction requirements including all electrical plans, elevations, sections, details, diagrams and schedules showing transformers, vaults, electrical and telephone closets, power distribution systems, auxiliary power systems, switchgear, generator, lighting fixtures, switching power outlets, and signal system; (6) Cost Estimate(s) setting forth in detail quantities of materials, labor, profit, overhead, insurance, taxes, etc.; (7) Specifications for all sections of the work utilizing the VA Master Specification system setting forth in detail all requirements for the construction fully coordinated with the drawings and other Construction Documents; and (8) Presentations and Review Submissions. (b) Project Phasing (CPM). The A/E shall assist the Contracting Officer in coordinating the development of a CPM (Critical Path Method) network for the construction of the Project. The CPM network shall provide a phasing schedule which will promote a proper and efficient organization and sequence of construction. The A/E shall, when directed by the Contracting Officer, serve as an advisor to the Contracting Officer on all phasing matters. Construction Documents shall be packaged for bidding and construction in accordance with the CPM network. IV. SITE SURVEYS, SUBSURFACE AND OTHER INVESTIGATIONS. The A/E shall arrange for and oversee the performance of topographic surveys, test borings, test pits, soil tests, subsurface exploration and other such investigations as he determines are required for the proper design of the Project. V. PROJECT FIRE PROTECTION ENGINEER. The A/E shall retain the services of a fire protection engineer (FPE). The FPE shall have qualifications as further described in Supplement B. The FPE shall remain on the A/E's project staff throughout Project design and construction. The FPE must be directly involved in the design of fire protection systems or in responsible charge of: the design of fire protection features; review of fire protection equipment submittals and shop drawings; and participation in preliminary inspection and final testing of fire protection systems. The FPE shall provide to the A/E all services as further described in Supplement B. VI. PROJECT INDUSTRIAL HYGIENIST. The A/E shall retain the services of an industrial hygienist (IH). The A/E or the IH have the option of preparing the asbestos drawings. The IH consultant shall have qualifications as further described in Supplement B. The IH consultant shall provide to the A/E all services as further described in Supplement B. The services include all A/E IH services associated with asbestos for the Schematics, Design Development and the Construction Documents stages of the VA design process and the Construction Period Services of the Project. The A/E shall be responsible for providing all design documents for the Project. The IH consultant shall coordinate with the A/E to ensure that fully coordinated drawings are provided for all asbestos abatement and related restoration work. VII. BID ALTERNATES. Throughout the design phases, the A/E shall identify alternatives for a minimum of 20 percent of construction costs that can be taken as potential bid deducts in the event construction bids received are higher than anticipated. The alternates shall be designed so that, if required to award the bid within the approved total project cost, the Project remains a stand-alone project and can be activated according to its intended function upon completion. VIII. SERVICES DURING BIDDING PERIOD. The A/E shall provide all services required for advertising for and securing construction bids. The A/E shall attend authorized conferences, including Pre-Bid Conference and Pre-Construction Conference, as directed by the Contracting Officer. The A/E shall provide representatives of the following professional registered disciplines for each conference: Architectural Design, Structural Design, Mechanical Design, and Electrical Design. IX. SERVICES DURING THE CONSTRUCTION PERIOD. The A/E shall act in an advisory and consultant capacity to the Contracting Officer. The A/E, when requested, shall assist the Contracting Officer and his Resident Engineer to interpret the construction documents and shall: (1) recommend any action(s) he deems suitable for the satisfactory prosecution of the construction work; (2) prepare any supplemental drawings, specifications or other documents that may be required to clarify or supplement the construction documents; and (3) assess the preparation of Construction Contract Modifications initiated by or through VA to be executed in accordance with the Construction Documents. The A/E shall review all Government initiated and/or the Construction Contractor's cost proposals for construction modifications when requested by the Resident Engineer. The A/E's reply regarding his review of cost proposals and his recommendations shall include an independent breakdown of costs in detail with quantities and unit prices and shall cover both additions and deductions of labor, materials and equipment. The A/E shall check Government furnished and/or the Construction Contractor's shop drawings, detail drawings, schedules, descriptive literature and samples, testing laboratory reports, field test data and review the color, texture and suitability of materials for conformity with the design concept and construction documents. The A/E shall recommend approval, disapproval, or other suitable disposition. The A/E shall notify the Resident Engineer in writing of any and all deviations from the requirements of the construction documents that he has found in the Construction Contractor's submittals. During the Construction Period, the A/E shall make visits to the Project site. The A/E shall observe the construction and advise the Resident Engineer of any deviations or deficiencies. The A/E shall provide registered architects and engineers who are familiar with the design work of the Project to act as observers and advisers to the VA team conducting intermediate inspections, partial final and/or final inspection(s) of the Project. X. POST-CONSTRUCTION SERVICES. For a period of one (1) year after final payment, the A/E shall be obligated to furnish advisory or consulting services which are normal to such a professional contract and necessary to assure the proper functioning of elements of the A/E design. The Construction Contractor shall furnish to the A/E a marked-up set of prints showing all changes made during the construction period. The A/E shall incorporate into the drawings all significant changes marked-up by the Construction Contractor and, any significant changes made by solicitation amendments and construction contract modifications. The A/E shall prepare record drawings by making changes on the original contract drawings. Submission shall be subject to the approval of the Contracting Officer as to quality and completeness. XI. LOCATION. The A/E must have an existing active design production office within a 100-mile radius of the Northport VA Medical Center. XII. CONTRACT SECURITY. This contract does not involve VA sensitive information and contractor personnel do not require access to VA systems. Information made available to the contractor or subcontractor by VA for the performance or administration of this contract or information developed by the contractor/subcontractor in performance or administration of the contract shall be used only for those purposes and shall not be used in any other way without the prior written agreement of VA. COST RANGE Estimated Construction Cost Range: Between $5,000,000 and $10,000,000. TYPE OF CONTRACT CONTEMPLATED The Department of Veterans Affairs is contemplating awarding a Firm Fixed Price contract. ESTIMATED START AND COMPLETION DATES The Department of Veterans Affairs requires design and contract support services. The estimated start and end dates for the design and start and end dates for the construction are as follows: ITEMDATE Receive Notice to Proceed from (NTP)TBD Deliver Schematic Review Material 60 calendar days from NTP Review Schematic Review Material 90 calendar days from NTP Deliver Revised Schematic Review Material115 calendar days from NTP Review Revised Schematic Review Material 130 calendar days from NTP Deliver Design Development Review Material 175 calendar days from NTP Review Design Development Review Material 200 calendar days from NTP Deliver Revised Design Development Review Material230 calendar days from NTP Review Revised Design Development Review Material 245 calendar days from NTP Deliver Construction Document Review Material 300 calendar days from NTP Review Construction Document Review Material 330 calendar days from NTP Deliver Revised Construction Document Review Material 350 calendar days from NTP Review Revised Construction Document Review Material 370 calendar days from NTP Deliver Final Bid Documents 395 calendar days from NTP Bid Opening Date (Estimated)675 calendar days from NTP Construction Contract Award (Estimated)700 calendar days from NTP Construction Completion (Estimated)1400 calendar days from NTP Construction: Number of calendar days to complete construction is to be determined by the AE firm after the design is complete. SELECTION CRITERIA The Department of Veterans Affairs shall evaluate each potential contractor in terms of its (1) Professional qualifications necessary for satisfactory performance of required services; (2) Specialized experience and technical competence in the type of work required, including, where appropriate, experience in energy conservation, pollution prevention, waste reduction, and the use of recovered materials; (3) Capacity to accomplish the work in the required time; (4) Past performance on contracts with Government agencies and private industry in terms of cost control, quality of work, and compliance with performance schedules; (5) Location in the general geographical area of the project and knowledge of the locality of the project; provided, that application of this criterion leaves an appropriate number of qualified firms, given the nature and size of the project; and (6) Acceptability under other appropriate evaluation criteria. SELECTION CRITERIA DESCRIPTIONS The selection criteria descriptions are provided below. I - TEAM PROPOSED FOR THIS PROJECT Background of the personnel A. Project Manager B. Other key personnel C. Consultants II - PROPOSED MANAGEMENT PLAN Team organization A. Design Phase B. Construction Phase III- PREVIOUS EXPERIENCE OF PROPOSED TEAM Project Experience with applicable descriptions IV - LOCATION AND FACILITIES OF WORKING OFFICES A. Prime firm B. Consultants V - PROPOSED DESIGN APPROACH FOR THIS PROJECT A. Proposed design philosophy B. Anticipated problems and potential solutions C. Possible Energy Applications D. Innovative Approaches in production and design approach VI - PROJECT CONTROL A. Techniques planned to control the schedule and costs B. Personnel responsible for schedule and cost control C. Review of recent projects to demonstrate ability to meet project cost target And any additional construction costs caused by design deficiencies and NOT Changes. VII - ESTIMATING EFFECTIVENESS Ten most recently bid projects VIII- SCHEDULE CONTROL A.What techniques are planned to assure that schedule will be met? B.Who will be responsible to assure schedules are met? C.Review of recent projects to meet project schedules. VIII - SUSTAINABLE DESIGN Team design philosophy and method of implementing IX- MISCELLANEOUS EXPERIENCE & CAPABILITIES A. Value Engineering B. Life Cycle Cost Analysis (LCCA) C. Critical Path Method D. Fast Track Construction E. Energy Conservation F. New Energy Resources G. Environmental Assessment H. Specialized Experience I. Computer Aided Design and Drafting J. Other Computer Applications X - AWARDS A. Awards received for design excellence XI - INSURANCE AND LITIGATION A. Type and amount of liability insurance carried B. Litigation involvement over the last 5 years & its outcome LIMITATIONS: VA NOTICE OF TOTAL VETERAN-OWNED SMALL BUSINESS SET-ASIDE (DEC 2009) (a) Definition. For the Department of Veterans Affairs, "Veteran-owned small business concern"- (1) Means a small business concern- (i) Not less than 51 percent of which is owned by one or more veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; (ii) The management and daily business operations of which are controlled by one or more veterans; (iii) The business meets Federal small business size standards for the applicable North American Industry Classification System (NAICS) code identified in the solicitation document; and (iv) The business has been verified for ownership and control and is so listed in the Vendor Information Pages database, (http://www.VetBiz.gov). (2) "Veteran" is defined in 38 U.S.C. 101(2). (b) General. (1) Offers are solicited only from veteran-owned small business concerns. All service-disabled veteran-owned small businesses are also determined to be veteran owned small businesses if they meet the criteria identified in paragraph (a)(1) of this section. Offers received from concerns that are not veteran-owned small business concerns shall not be considered. (2) Any award resulting from this solicitation shall be made to a veteran-owned small business concern. (c) Agreement. A veteran-owned small business concern agrees that in the performance of the contract, in the case of a contract for- (1) Services (except construction), at least 50 percent of the cost of personnel for contract performance will be spent for employees of the concern or employees of other eligible veteran-owned small business concerns; (2) Supplies (other than acquisition from a non-manufacturer of the supplies), at least 50 percent of the cost of manufacturing, excluding the cost of materials, will be performed by the concern or other eligible veteran-owned small business concerns; (3) General construction, at least 15 percent of the cost of the contract performance incurred for personnel will be spent on the concern's employees or the employees of other eligible veteran-owned small business concerns; or (4) Construction by special trade contractors, at least 25 percent of the cost of the contract performance incurred for personnel will be spent on the concern's employees or the employees of other eligible veteran-owned small business concerns. (d) A joint venture may be considered a veteran-owned small business concern if: (1) At least one member of the joint venture is a veteran-owned small business concern, and makes the following representations: That it is a veteran-owned small business concern, and that it is a small business concern under the NAICS code assigned to the procurement; (2) Each other concern is small under the size standard corresponding to the NAICS code assigned to the procurement; (3) The joint venture meets the requirements of paragraph 7 of the explanation of Affiliates in 19.101 of the Federal Acquisition Regulation; and (4) The joint venture meets the requirements of 13 CFR 125.15(b), except that the principal company may be a veteran-owned small business concern or a service-disabled veteran-owned small business concern. (e) Any veteran-owned small business concern (non-manufacturer) must meet the requirements in 19.102(f) of the Federal Acquisition Regulation to receive a benefit under this program. SUBMISSION REQUIREMENTS Qualified Veteran Owned Small Business firms are required to submit Three (3) hard copies of the SF 330 (which can be downloaded from www.gsa.gov/forms ) and one (1) Compact Disc (CD) which contains digital copies of the SF 330. All packages shall be submitted no later than 3:00 PM, EST on April 17, 2013, including Past Performance Questionnaires (attachment 1). April 3, 2013 shall be the deadline for all questions. All submittals must be sent to the attention of Patricia Cordero (10N3NCO), James J. Peters VA Medical Center, 130 West Kingsbridge Road, Room GC-125, Bronx, NY 10468-3904. The submission must include an insert detailing the following information: 1.Dun & Bradstreet Number; 2.Tax ID Number; 3.The e-mail address and phone number of the Primary Point of Contact and; 4.A copy of the firms CVE verification as a Veteran Owned Small Business. The Contracting Officer is not responsible for not receiving submissions due to the offeror misaddressing the package or illegibility of the information. NOTE: Any request for assistance with submission or other procedural matters shall be submitted via email only, to Patricia Cordero at (patricia.cordero@va.gov). Please note that telephone inquiries will not be honored. THIS ANNOUNCEMENT IS NOT A REQUEST FOR PROPOSAL. THE GOVERNMENT WILL NOT PAY NOR REIMBURSE ANY COSTS ASSOCIATED WITH RESPONDING TO THIS REQUEST. THE GOVERNMENT IS UNDER NO OBLIGATION TO AWARD A CONTRACT AS A RESULT OF THIS ANNOUNCEMENT.
 

Web Link

FBO.gov Permalink
(https://www.fbo.gov/spg/VA/BroVANAP/VAMD/VA24313I0744/listing.html)
 

Document(s)

Attachment
 

File Name: VA243-13-I-0744 VA243-13-I-0744_1.docx (https://www.vendorportal.ecms.va.gov/FBODocumentServer/DocumentServer.aspx?DocumentId=661001&FileName=VA243-13-I-0744-001.docx)

Link: https://www.vendorportal.ecms.va.gov/FBODocumentServer/DocumentServer.aspx?DocumentId=661001&FileName=VA243-13-I-0744-001.docx

 

Note: If links are broken, refer to Point of Contact above or contact the FBO Help Desk at 877-472-3779.
 

Place of Performance

Address: Northport VA Medical Center;79 Middleville Road;Northport, NY

Zip Code: 11768
 

Record

SN03013010-W 20130317/130315234421-c3728e8fadba5aa3638d511e4407b01f (fbodaily.com)
 

Source

FedBizOpps Link to This Notice
(may not be valid after Archive Date)

---

| FSG Index  |  This Issue's Index  |  Today's FBO Daily Index Page |