SOURCES SOUGHT
Y -- Sources Sought: Dam Feeder Cable Replacement, Lock and Dam 2, Hastings, MN
- Notice Date
- 10/6/2014
- Notice Type
- Sources Sought
- NAICS
- 238210
— Electrical Contractors and Other Wiring Installation Contractors
- Contracting Office
- Department of the Army, U.S. Army Corps of Engineers, USACE District, St. Paul, Attn: CEMVP-CT, 180 East Fifth Street, St. Paul, Minnesota, 55101-1678, United States
- ZIP Code
- 55101-1678
- Solicitation Number
- W912ES-15-SS-0001
- Archive Date
- 10/11/2014
- Point of Contact
- Lisa A. Draves, Phone: 6512905614
- E-Mail Address
-
lisa.a.draves@usace.army.mil
(lisa.a.draves@usace.army.mil)
- Small Business Set-Aside
- N/A
- Description
- The U.S. Army Corps of Engineers - St. Paul District is seeking capability statements from all firms interested in a proposed project to replace dam feeder cables at Lock and Dam no. 2, located near Hastings, MN. The scope of the proposed project will involve the removal and replacement of Dam Feeder No. 1 (DF1A & DF1B) and Dam Feeder No. 2 (DF2A and DF2B) parallel cables. Work will include, but will not be limited to, removing and replacing sections of the approximate 5,000 linear feet of armored cables between the Central Control Station to the transfer switch on the dam. Work will also involve dewatering the landward lock crossover ductbank; excavation of sediment to install cable in crossover between landward and riverward lock; excavation of sediment for wet installation of the cables within the riverward lock by divers; and conducting operational/performance tests. No lock and dam operations shall be impacted by the Contractor's operations during the course of construction. The work will involve close coordination with the Lock and Dam staff. The tentative required completion date is June 2015. The project magnitude in terms of estimated price is between $250,000 and $500,000. The appropriate NAICS code for the proposed project is 238210 (Electrical Contractors and Other Wiring Installation Contractors) with a small business size standard of $15.0 million. All interested parties are invited to submit capability statements for acquisition planning purposes. The following outline is recommended (5-page limit): 1) Company name, address, and primary point of contact information 2) A statement of capability 3) Recent and relevant past performance information 4) Business Ownership and Self‐Certification information (i.e. Small Business, Women‐Owned Small Business, Veteran Owned, Service Disabled Veteran Owned) 5) Current Government Certifications (i.e. 8(a) certified, 8(a) joint venture, Small Disadvantaged Business HUBZone Certified) 6) List Pertinent Codes: NAICS Codes (numbers only), DUNS number, and CAGE code 7) Bonding capacity The St. Paul District Corps of Engineers reserves the right to determine if a small business set-aside is appropriate based upon the capability information provided in response to this notice, and other pertinent information gathered by the contracting officer. Respondents should ensure the information provided is detailed, current, accurate, and complete. Please submit capability statements by email to Lisa Draves, Contract Specialist, lisa.a.draves@usace.army.mil no later than Friday, October 10, 2014. This notice does not constitute a solicitation. This invitation for capability statements is for planning purposes only. The acquisition strategy for this proposed project has not yet been determined. Response to this notice is strictly voluntary. The Government will not reimburse any party for its participation in this effort. Information submitted in response to this notice is subject to disclosure under the Freedom of Information Act. Respondents are advised that the Government is under no obligation to acknowledge or provide feedback with respect to any information submitted under this notice.
- Web Link
-
FBO.gov Permalink
(https://www.fbo.gov/spg/USA/COE/DACA37/W912ES-15-SS-0001/listing.html)
- Place of Performance
- Address: Lock and Dam 2, 1350 Dam Rd., Hastings, Minnesota, 55033, United States
- Zip Code: 55033
- Zip Code: 55033
- Record
- SN03543700-W 20141008/141006234451-1a429a0ea7cb699782f9422fd3d37db2 (fbodaily.com)
- Source
-
FedBizOpps Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |