FBODaily.com | FedBizOpps: PRESOL | J | Repair Hydorgraphic Survey Equipment - Price Schedule

FBO DAILY - FEDBIZOPPS ISSUE OF MARCH 26, 2017 FBO #5602
SOLICITATION NOTICE

J -- Repair Hydorgraphic Survey Equipment - Price Schedule

Notice Date: 3/24/2017
Notice Type: Combined Synopsis/Solicitation
NAICS: 811219 — Other Electronic and Precision Equipment Repair and Maintenance
Contracting Office: Department of the Army, U.S. Army Corps of Engineers, USACE District, Jacksonville, P.O. Box 4970, Jacksonville, Florida, 32232-0019, United States
ZIP Code: 32232-0019
Solicitation Number: W912EP-17-T-0002
Archive Date: 4/22/2017
Point of Contact: Jesus Lugo, Phone: 9042321051, Carla A. Echols, Phone: 902322180
E-Mail Address: jesse.lugo@usace.army.mil, Carla.a.echols@usace.army.mil
(jesse.lugo@usace.army.mil, Carla.a.echols@usace.army.mil)
Small Business Set-Aside: Total Small Business
Description: Price Schedule COMBINED SYNOPSIS/SOLICITATION This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in the Federal Acquisition Regulation (FAR) Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; offers are being requested and a written solicitation will not be issued. The solicitation number for this acquisition is W912EP-17-T-0002 and it is being issued as a Request for Offer. The solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular 2005-87. This requirement is being offered as a Small Business Set-Aside. The NAICS code is 811219. The small business size standard is $20.5 million. The U.S. Army Corps of Engineers, Jacksonville, FL District has a need for Hydrographic Survey Equipment Repair. The Jacksonville District intends to award up to five (5) Blanket Purchase Agreements (BPA) from this combined synopsis/solicitation to the responsible offeror(s) whose offer represent the best value after evaluation in accordance with the factors and their relative importance in this solicitation. The total ordering capacity under each BPA shall not exceed $1,500,000.00 and no call issued under any of the BPAs shall exceed $50,000.00. T h e B PA shall be valid for a period of five (5) years or when the total dollar amount of all calls issued under the BPA reaches $1,500,000.00, whichever comes first. &emsp; (i) Description of Requirements: 1. GENERAL: This is a non-personal service contract to rent hydrographic surveying equipment, to obtain on-site support for hydrographic surveying equipment, and to have hydrographic surveying equipment repaired. The Government shall not exercise any supervision or control over the contract service providers performing the services herein. Such contract service providers shall be accountable solely to the Contractor who, in turn is responsible to the Government. 1.1 Description of Services/Introduction: The Contractor shall provide all personnel, equipment, supplies, facilities, transportation, tools, materials, supervision, and other items and non-personal services necessary to provide rental, support and repair of hydrographic surveying equipment as defined in this Performance Work Statement except for those items specified as government furnished property and services. The Contractor shall perform to the standards in this contract. 1.2 Background: CESAJ-OD-H comprises of a multifaceted team of staff members with varying strengths from individuals with a Bachelor of Science in Geomatics to those with 25 or more years of hydrographic surveying experience. The Contractor sought shall have a dedicated team of equivalent education, knowledge of cutting edge surveying technology, and versatility. The contractor shall furnish a list of staff biographies upon request by the COR. The majority of the items listed in Technical Exhibit 3 are currently owned and in active use by CESAJ-OD-H. 1.3 Objectives: The objective is to obtain rental, support, and repair service for hydrographic surveying equipment for use on coastal and navigation projects. 1.4 Scope: The Contractor shall rent the equipment at a daily rate. The rental equipment shall be delivered to the Government in turn-key condition and in ready to operate status 24 hours a day, seven (7) days a week, and 365 days a year. The Contractor shall be a full-service vendor that is both qualified and has the resources to perform all services stated in Part 5 of this Performance Work Statement (PWS) within the timeframes as stated in this PWS. The Contractor shall repair the hydrographic surveying equipment indicated in this PWS. The Contractor shall provide support for the hydrographic surveying equipment indicated in this PWS. 1.5 Period of Performance: The period of performance for the Blanket Purchase Agreement (BPA) shall be for five (5) years from the date of Award. 1.6 General Information 1.6.1 Quality Control: The Contractor shall develop and maintain an effective quality control program to ensure services are performed in accordance with this PWS. The Contractor shall develop and implement procedures to identify, prevent, and ensure non-recurrence of defective services. The Contractor's quality control program is the means by which he assures himself that his work complies with the requirement of the contract. The Quality Control Plan (QCP shall be submitted with the Contractor's proposal. After acceptance of the quality control plan the Contractor shall receive the contracting officer's acceptance in writing of any proposed change to his QC system. 1.6.2 Quality Assurance: The government shall evaluate the Contractor's performance under this contract in accordance with the Quality Assurance Surveillance Plan. This plan is primarily focused on what the Government must do to ensure that the Contractor has performed in accordance with the performance standards. It defines how the performance standards will be applied, the frequency of surveillance, and the minimum acceptable defect rate(s). 1.6.3 Recognized Holidays: The Contractor may be required to perform services on holidays. New Year's Day Labor Day Martin Luther King Jr.'s Birthday Columbus Day President's Day Veteran's Day Memorial Day Thanksgiving Day Independence Day Christmas Day 1.6.4 Hours of Operation: The Contractor is responsible for conducting business, between the hours of 0800 - 1700 Monday through Sunday (EST), except when the Government facility is closed due to local or national emergencies, administrative closings, or similar Government directed facility closings. For other than firm fixed price contracts, the Contractor will not be reimbursed when the government facility is closed for the above reasons. The Contractor must at all times maintain an adequate workforce for the uninterrupted performance of all tasks defined within this PWS when the Government facility is not closed for the above reasons. When hiring personnel, the Contractor shall keep in mind that the stability and continuity of the workforce are essential. 1.6.5 Place of Performance: The work to be performed under this contract will be performed on location throughout the USACE Jacksonville District's Area of Responsibility (AOR). The Jacksonville District's Area of Responsibility for Civil Works consists of part of the peninsular portion of the State of Florida, a small part of the State of Georgia, the Commonwealth of Puerto Rico, and the Territory of the U. S. Virgin Islands. These geographical areas are vulnerable to flooding, wind and other damage associated with tropical storms and hurricanes. It should be noted that work is predominately located with the State of Florida. Work in the State of Georgia and the Commonwealth of Puerto Rico is infrequent. Work in the Territory of the U.S. Virgin Islands is only performed in response to emergency operations associated with severe weather. 1.6.6 Type of Contract: The government will award a Blanket Purchase Agreement (BPA). 1.6.7 Security Requirements: Reserved. 1.6.7.1 PHYSICAL Security: The Contractor shall be responsible for safeguarding all government equipment, information and property provided for Contractor use. 1.6.7.2 Key Control: Reserved. 1.6.7.3 Lock Combinations: Reserved. 1.6.8 Special Qualifications: The Contractor must specialize in renting, leasing, and having a sophisticated understanding of the interoperability of marine hydrographic and land surveying equipment. Due to the need to interoperate the desired equipment with the Trimble GNSS equipment currently owned and in use by the Government, the Contractor's staff shall include have a Trimble Navigation certified representative. The Contractor must have at least two years of experience managing the interoperability of commercial grade sonar systems, positioning hardware, inertial motion reference unit (IMU), and advanced computer with data collection software. The Contractor must be able to demonstrate the ability to install systems using a RTK/DGPS system integrated with Applanix POS MV320 with PosPac MMS, Applanix Wavemaster with PosPac MMS, Trimble SPS 851/ 551H heading bundle, Ross Smart Sounder Model 835 Dual Frequency (200 kHz and 28 kHz), R2 Sonic Multibeam, Reson Multibeam, Marine Magnetics Seaspy Magnetometer, Trimble R7 GNSS, Trimble R8 GNSS, Trimble 5700 GPS, Hypack survey software, and TSS Heave compensation system. 1.6.9 Post Award Conference/Periodic Progress Meetings: The Contractor agrees to attend any post award conference convened by the contracting activity or contract administration office in accordance with Federal Acquisition Regulation Subpart 42.5. The contracting officer, Contracting Officers Representative (COR), and other Government personnel, as appropriate, may meet periodically with the Contractor to review the Contractor's performance. At these meetings, the contracting officer will apprise the Contractor of how the government views the Contractor's performance and the Contractor will apprise the Government of problems, if any, being experienced. Appropriate action shall be taken to resolve outstanding issues. These meetings shall be at no additional cost to the government. 1.6.10 Contracting Officer Representative (COR): The (COR) will be identified by separate letter. The COR monitors all technical aspects of the contract and assists in contract administration The COR is authorized to perform the following functions: assure that the Contractor performs the technical requirements of the contract: perform inspections necessary in connection with contract performance: maintain written and oral communications with the Contractor concerning technical aspects of the contract: issue written interpretations of technical requirements, including Government drawings, designs, specifications: monitor Contractor's performance and notifies both the Contracting Officer and Contractor of any deficiencies; coordinate availability of government furnished property, and provide site entry of Contractor personnel. A letter of designation issued to the COR, a copy of which is sent to the Contractor, states the responsibilities and limitations of the COR, especially with regard to changes in cost or price, estimates or changes in delivery dates. The COR is not authorized to change any of the terms and conditions of the resulting order. 1.6.11 Key Personnel: The following personnel are considered key personnel by the government: contract manager, alternate contract manager, and safety officer. The Contractor shall provide a contract manager who shall be responsible for the performance of the work. The name of this person and an alternate who shall act for the Contractor when the manager is absent shall be designated in writing to the contracting officer. The contract manager or alternate shall have full authority to act for the Contractor on all contract matters relating to daily operation of this contract. The contract manager or alternate shall be available between 0800 - 1700 Monday through Sunday (EST), except when the government facility is closed for administrative reasons. The contract manager cannot also serve as the safety officer. Qualifications for all key personnel are listed below: The Contract Manager shall have a Bachelor of Science or Master's Degree in Geomatics or Surveying and have at least five years working for a company that specializes in hydrographic surveying. The alternate contract manager shall have a Bachelor of Science in Geomatics or Surveying and at least three years working for a company that specializes in hydrographic surveying. The safety officer shall have a Bachelor of Science in Geomatics or Surveying and have at least two years working for a company that specializes in hydrographic surveying. The staff biography for the contract manager, alternate contract manager, and safety officer shall be submitted upon request by the COR. 1.6.12 Identification of Contractor Employees: All contract personnel attending meetings, answering Government telephones, and working in other situations where their Contractor status is not obvious to third parties are required to identify themselves as such to avoid creating an impression in the minds of members of the public that they are Government officials. They must also ensure that all documents or reports produced by Contractors are suitably marked as Contractor products or that Contractor participation is appropriately disclosed. 1.6.13 Contractor Travel: Contractor will be required to travel throughout the State of Florida, a small part of the State of Georgia, the Commonwealth of Puerto Rico, and the Territory of the U. S. Virgin Islands during the performance of this contract in the event of equipment connectivity dysfunction or failure. The Contractor may be required to travel to on-site locations in support of this PWS. The Contractor shall be required to report, equipped with servicing tools and replacement parts, to the on-site support location to perform diagnostics within 24 hours of notification by the COR. Contractor will be authorized travel expenses consistent with the substantive provisions of the Joint Travel Regulation (JTR) and the limitation of funds specified in this contract. All travel requires Government approval/authorization and notification to the COR. Travel costs shall be reimbursed by the Government, but shall not exceed an annual amount of $5,000. Any additional cost shall be the responsibility of the Contractor. The Government cannot predict when system failure will occur; subsequently, the Government cannot predict when on-site support will be requested. However, travel may be anticipated at any of the following Federal projects throughout the State of Florida, a small part of the State of Georgia, the Commonwealth of Puerto Rico, and the Territory of the U. S. Virgin Islands: Alafia Rivera, Anclote River, Arecibo Harbor, Atlantic Intercostal Waterway, Intercostal Waterway, Canaveral Harbor, Cedar Island / Keaton Beach, Cedar Keys Harbor, Charlotte Harbor, Boca Grande Pass, Clearwater Pass, Courteney Channel, Crystal Rivera, Daytona Beach, Everglades Harbor, Fernandina Harbor, Fort Myers Beach, Ft. Pierce Harbor, Gulf Intercostal Waterway, Hernando Beach, Hillsborough River, Homosassa River, Horseshoe Cove, Jacksonville Harbor, Johns Pass, Key West Harbor, Key West Northwest Channel, Kings Bay Entrance Channel, Kings Bay Inner Channel, Lake Crescent, Dunns Creek, Longboat Pass, Manatee Harbor, Manatee River, Mayaquez, Mayport Harbor, Melbourne Harbor, Miami Harbor, Miami River, Mill Cove, Naples to Big Marco Pass, Naples to Gordon Pass, New Pass, New River, Okeechobee Waterway, Palm Beach Harbor, Pass-a-grille Pass, Pithlachascotee River, Ponce de Leon Inlet, Ponce Harbor, Port Everglades Harbor, St. Augustine Inlet, St. Johns River, St. Lucie Inlet, St. Petersburg Harbor, San Juan Harbor, Steinhatchee River, Suwannee River, Tampa Harbor Upper Hillsborough Bay, Seddon Channel, Tampa Harbor, USMC Blount Island, Venice Inlet, Withlacoochee, and all beaches in the State of Florida. Contractor shall submit copies of actual travel receipts for any airfare, lodging, etc. to the COR for approval for reimbursement. Actual mileage will be paid based on the current JTR POV mileage allowance from the Contractor's registered physical business address to the on-site support location. 1.6.14 Other Direct Costs This category includes travel (outlined in 1.6.13). 1.6.15 Data Rights: The Government has unlimited rights to all documents/material produced under this contract. All documents and materials, to include the source codes of any software, produced under this contract shall be Government owned and are the property of the Government with all rights and privileges of ownership/copyright belonging exclusively to the Government. These documents and materials may not be used or sold by the Contractor without written permission from the Contracting Officer. All materials supplied to the Government shall be the sole property of the Government and may not be used for any other purpose. This right does not abrogate any other Government rights. 1.6.16 Organizational Conflict of Interest: Contractor and subcontractor personnel performing work under this contract may receive, have access to or participate in the development of proprietary or source selection information (e.g., cost or pricing information, budget information or analyses, specifications or work statements, etc.) or perform evaluation services which may create a current or subsequent Organizational Conflict of Interests (OCI) as defined in FAR Subpart 9.5. The Contractor shall notify the Contracting Officer immediately whenever it becomes aware that such access or participation may result in any actual or potential OCI and shall promptly submit a plan to the Contracting Officer to avoid or mitigate any such OCI. The Contractor's mitigation plan will be determined to be acceptable solely at the discretion of the Contracting Officer and in the event the Contracting Officer unilaterally determines that any such OCI cannot be satisfactorily avoided or mitigated, the Contracting Officer may affect other remedies as he or she deems necessary, including prohibiting the Contractor from participation in subsequent contracted requirements which may be affected by the OCI. 1.6.17 PHASE IN /PHASE OUT PERIOD: Reserved. Specific Tasks: 5.1 Basic Services. The Contractor shall provide rental, support, and repair of hydrographic surveying equipment and surveying equipment for coastal projects. Rental prices shall be provided at a daily rate and shall include shipping fees. Reference Technical Exhibit 3 for a list of equipment. The Contractor shall submit a daily rate for each item listed in Technical Exhibit 3. 5.2 Task: Perform diagnostic services within 24 hours of notification by COR. 5.2.1 Standard: The contractor performed all tasks under 5.2 satisfactorily. 5.3 Task: The Contractor shall provide on-site support in the event that the Contractor needs to resolve connectivity or syncing problems between the rented equipment and other hydrographic surveying hardware in place on the survey vessel, survey boat, or beach survey equipment. The Contractor shall provide on-site support to perform troubleshooting and repairs on Government owned equipment with the purpose of making the surveying system as a whole fully operable as a hydrographic surveying system for multibeam, single-beam, sidescan, magnetometer, sub-bottom, and interferometer sonar use. On-site support shall be performed by the Contractor's in-house personnel. See Contractor Travel for information regarding payment related to Contractor travel expenses. The Contractor shall report to the on-site support location within 24 hours of notification by an authorized Government individual. 5.3.1 Standard: The contractor performed all tasks under 5.3 satisfactorily. 5.4 Task: The Contractor warrants all equipment to be in good working condition upon delivery. The Contractor shall test the equipment at the Contractor's business location prior to delivery and submit documentation recording the name of the Contractor's employee whom tested and packaged the equipment. Rental equipment shall be delivered to the Government within 24 hours of notification by an authorized Government individual. 5.4.1 Standard: The Contractor performed all the tasks under item 5.4 satisfactorily. 5.5 Task: All equipment shall be set-up to operate in accordance with current FCC regulations. The Contractor shall install rental equipment upon request by authorized Government individuals within 24 hours of notification. After installation is complete, the Contractor shall verify that each piece of equipment is recording data within the tolerance permitted by EM 1110-2-1003 (current version). 5.5.1 Standard: The Contractor performed all the tasks under item 5.5 satisfactorily. 5.6 Task: The intended radius of the operations is the District Area of Responsibility. See Contractor Travel for additional information. 5.6.1 Standard: The Contractor performed all the tasks under item 5.6 satisfactorily. 5.7 Task: Upon request by the COR, The Contractor shall concurrently provide replacement equipment that is identical to the Government owned equipment under repair while performing repair work on the Government owned equipment. Replacement equipment shall be delivered to the address specified by the Government within 24 hours of notification by an authorized Government individual. The delivery address will be within District Area of Responsibility. 5.7.1. Standard. The Contractor performed all the tasks under item 5.7 satisfactorily. 5.8 Task: The Contractor shall provide office support including report generation or hardware/software configuration and other office services. Office support shall be available during normal hours of operation. 5.8.1 Standard. The Contractor performed all the tasks under item 5.8 satisfactorily. 5.9 Task: The contractor shall repair Government owned equipment using OEM parts from the manufacturer. Manufacturer's warranty shall apply to repair work. 5.9.1 Standard. The contractor performed all tasks under 5.9 satisfactorily. 5.8 CONTRACTOR MANAGEMENT REPORTING (CMR). Reserved. 6. APPLICABLE PUBLICATIONS (CURRENT EDITIONS): 6.1. The Contractor must abide by all applicable regulations, publications, manuals, and local policies and procedures. EM 1110-2-1003 Hydrographic Surveying (1 Jan 2002), EM 1110-1-1003 NAVSTAR Global Positioning System (1 Jul 2003), EM 385-1-1 (Safety and Health Requirements Manual) excluding Personal Protection Equipment and plans that require submittals. All EM's are available for download at http://publications.usace.army.mil/publications/eng-manuals/. 7. Attachment/Technical Exhibit List: 7.1. Technical Exhibit 1 - Performance Requirements Summary 7.2. Technical Exhibit 2 - Deliverables Schedule TECHNICAL EXHIBIT 1 Performance Requirements Summary Performance Objective Standard Performance Threshold Method of Surveillance PRS # 1 The Contractor shall install rental equipment upon request. After installation is complete, the Contractor shall verify that each piece of surveying equipment is recording data within the tolerance permitted by EM 1110-2-1003. The Contractor installed equipment and verified that the interconnected surveying equipment functions within the tolerance permitted by EM 1110-2-1003. Zero deviation from standard. 100% by COR or assigned QAR. PRS # 2 The Contractor shall provide rental equipment within 24 hours of notification by COR. The Contractor provided rental equipment within 24 hours of written notification by COR. Zero deviation from standard. 100% by COR or assigned QAR. PRS # 3 The Contractor shall provide on-site support for connectivity, interoperability, or syncing problems within 24 hours of notification. The Contractor provided on-site support for connectivity or syncing problems within 24 hours of notification by authorized Government individual. Zero deviation from standard. 100% by COR or assigned QAR. PRS # 5 The Contractor shall provide equipment that is in good working condition upon delivery. The Contractor provided equipment in good working condition upon delivery. Zero deviation from standard. 100% by COR or assigned QAR. PRS # 6 The Contractor shall repair equipment. The Contractor repaired equipment in a timely manner. Zero deviation from standard. 100% by COR or assigned QAR. PRS # 7 The Contractor shall provide office support for work including report generation or hardware/software configuration and other office services. The Contractor provided office support in a timely manner. Zero deviation from standard. 100% by COR or assigned QAR. TECHNICAL EXHIBIT 2 DELIVERABLES SCHEDULE Deliverable Frequency No. of Copies Medium/Format Submit To The Contractor shall furnish proof of key personnel qualifications. By Contracting Officer's request. One Electronic (pdf, bmp, or jpeg). COR The Contractor shall provide documentation stating the name of the employee who checked and packaged the rental equipment. To accompany shipped items. One Hardcopy (may be hand written). COR The Contractor shall provide a Travel Request document that includes the total cost for mobilizing, travel expenses, and demobilizing staff for Government requested on-site support. Upon request by COR. One Electronic (word document or pdf) COR The Contractor shall provide a Shipping Request document that includes the total cost for shipment associated with incident or event. Upon request by COR. One Electronic (word document or pdf) COR The Contractor shall provide a specification document of the proposed rental equipment. Prior to delivery or installation. One Electronic (word document or pdf) COR The Contractor shall provide a daily rate for each item listed in Technical Exhibit 3. With Proposal One Electronic (pdf, bmp, or jpeg). COR &emsp; (ii) FAR Clauses CLAUSES INCORPORATED BY FULL TEXT 52.212-4 CONTRACT TERMS AND CONDITIONS-- COMMERCIAL ITEMS (JAN 2017) (a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or re-performance of nonconforming services at no increase in contract price. If repair/replacement or re-performance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights (1) within a reasonable time after the defect was discovered or should have been discovered; and (2) before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item. (b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C. 3727). However, when a third party makes payment (e.g., use of the Government wide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract. (c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties. (d) Disputes. This contract is subject to 41 U.S.C., Chapter 71, Contract Disputes'', as amended (41 U.S.C. 601-613). Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at FAR 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract. (e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference. (f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement or any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence. (g) Invoice. (1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include-- (i) Name and address of the Contractor; (ii) Invoice date and number; (iii) Contract number, line item number and, if applicable, the order number; (iv) Description, quantity, unit of measure, unit price and extended price of the items delivered; (v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading; (vi) Terms of any discount for prompt payment offered; (vii) Name and address of official to whom payment is to be sent; (viii) Name, title, and phone number of person to notify in event of defective invoice; and (ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract. (x) Electronic funds transfer (EFT) banking information. (A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract. (B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer-System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer--Other Than System for Award Management), or applicable agency procedures. (C) EFT banking information is not required if the Government waived the requirement to pay by EFT. (2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C. 3903) and Office of Management and Budget (OMB) prompt paymentregulations at 5 CFR part 1315. (h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings. (i) Payment.-- (1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract. (2) Prompt payment. The Government will make payment in accordance with the Prompt Payment Act (31 U.S.C. 3903) and prompt payment regulations at 5 CFR part 1315. (3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5(b) for the appropriate EFT clause. (4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made. (5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall-- (i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the-- (A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment); (B) Affected contract number and delivery order number, if applicable; (C) Affected line item or subline item, if applicable; and (D) Contractor point of contact. (ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer. (6) Interest. (i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid. (ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract. (iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if-- (A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days; (B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or (C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2). (iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment. (v) Amounts shall be due at the earliest of the following dates: (A) The date fixed under this contract. (B) The date of the first written demand for payment, including any demand for payment resulting from a default termination. (vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on-- (A) The date on which the designated office receives payment from the Contractor; (B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or (C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor. (vii) The interest charge made under this clause may be reduced under the procedures prescribed in 32.608-2 of the Federal Acquisition Regulation in effect on the date of this contract. (j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon: (1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or (2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination. (k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties. (l) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided. (m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience. (n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession. (o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract. (p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items. (q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract. (r) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C. 431 relating to officials not to benefit; 40 U.S.C. chapter 37, Contract Work Hours and Safety Standards; 41 U.S.C. chapter 87, Kickbacks; 41 U.S.C. 4712 and 10 U.S.C. 2409 relating to whistleblower protections; 49 U.S.C. 40118, Fly American; and 41 U.S.C. chapter 21 relating to procurement integrity. (s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order: (1) the schedule of supplies/services; (2) The Assignments, Disputes, Payments, Invoice, Other Compliances, Compliance with Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause; (3) the clause at 52.212-5; (4) addenda to this solicitation or contract, including any license agreements for computer software; (5) solicitation provisions if this is a solicitation; (6) other paragraphs of this clause; (7) the Standard Form 1449; (8) other documents, exhibits, and attachments; and (9) the specification. (t) System for Award Management (SAM). (1) Unless exempted by an addendum to this contract, the Contractor is responsible during performance and through final payment of any contract for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. (2)(i) If a Contractor has legally changed its business name, "doing business as" name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in FAR subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to (A) change the name in the SAM database; (B) comply with the requirements of subpart 42.12; and (C) agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide with the notification sufficient documentation to support the legally changed name. (ii) If the Contractor fails to comply with the requirements of paragraph (t)(2)(i) of this clause, or fails to perform the agreement at paragraph (t)(2)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract. (3) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims (see Subpart 32.8, Assignment of Claims). Assignees shall be separately registered in the SAM database. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the "Suspension of payment" paragraph of the EFT clause of this contract. (4) Offerors and Contractors may obtain information on registration and annual confirmation requirements via SAM accessed through https://www.acquisition.gov. (u) Unauthorized Obligations. (1) Except as stated in paragraph (u)(2) of this clause, when any supply or service acquired under this contract is subject to any End User License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern: (i) Any such clause is unenforceable against the Government. (ii) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an ``I agree'' click box or other comparable mechanism (e.g., ``click-wrap'' or ``browse-wrap'' agreements), execution does not bind the Government or any Government authorized end user to such clause. (iii) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement. (2) Paragraph (u)(1) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures. (v) Incorporation by reference. The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract. (End of Clause) CLAUSES INCORPORATED BY FULL TEXT LIMITATIONS ON SUBSTITUTIONS FOR CERTAIN POSITIONS AND/OR SUBCONTRACTORS The award decision for this contract was based, in part, on an evaluation of the personnel and/or subcontractors the Contractor included in its proposal for the positions and/or items of subcontracted work identified at the end of this paragraph. The Contractor agrees these personnel and/or subcontractors will be employed as described in its proposal and no substitutes will be employed without prior written approval of the Contracting Officer or Administrative Contracting Officer. The Contractor further agrees that any proposed substitutes shall meet or exceed the qualifications of the original personnel and/or subcontractors. If the Contractor's proposal did not name a subcontractor for an identified item of work, the Contractor will not be allowed to subcontract that item of work without prior approval of the Contracting Officer or Administrative Contracting Officer. (End of paragraph number 999.215-4001) CLAUSES INCORPORATED BY FULL TEXT NOTICE OF INTENT TO INCORPORATE UNIT PRICES The successful offeror's unit price for individual contract line item numbers (CLINs) and sub-CLINs, if the pricing schedule includes sub-CLINs, will be incorporated into the contract; and therefore will not be exempt from public disclosure. See FAR 24.202(a). (End of paragraph 999.215-1) CLAUSES INCORPORATED BY FULL TEXT UNAUTHORIZED INSTRUCTIONS FROM GOVERNMENT OR OTHER PERSONNEL The Contractor shall not accept any instructions issued by any person, employed by the Government or otherwise, other than the Contracting Officer or the Contracting Officer's Representative (COR) acting within the limits of the COR's authority. See the Contracting Officer's Representative clause of this contract. (End of paragraph number 999.201-4002) CLAUSES INCORPORATED BY FULL TEXT SAFETY REQUIREMENTS -- SERVICE CONTRACTS The Contractor shall comply with the applicable portions of the current edition of the U.S. Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1. The current edition shall be the edition, including all changes, that is posted at http://www.hq.usace.army.mil (at the HQ homepage, select Safety and Occupational Health) on the date the solicitation for this contract was issued. (End of paragraph number 999.223-4003) CLAUSES INCORPORATED BY FULL TEXT 52.203-3 GRATUITIES (APR 1984) (a) The right of the Contractor to proceed may be terminated by written notice if, after notice and hearing, the agency head or a designee determines that the Contractor, its agent, or another representative-- (1) Offered or gave a gratuity (e.g., an entertainment or gift) to an officer, official, or employee of the Government; and (2) Intended, by the gratuity, to obtain a contract or favorable treatment under a contract. (b) The facts supporting this determination may be reviewed by any court having lawful jurisdiction. (c) If this contract is terminated under paragraph (a) of this clause, the Government is entitled-- (1) To pursue the same remedies as in a breach of the contract; and (2) In addition to any other damages provided by law, to exemplary damages of not less than 3 nor more than 10 times the cost incurred by the Contractor in giving gratuities to the person concerned, as determined by the agency head or a designee. (This subparagraph (c)(2) is applicable only if this contract uses money appropriated to the Department of Defense.) (d) The rights and remedies of the Government provided in this clause shall not be exclusive and are in addition to any other rights and remedies provided by law or under this contract. (End of clause) CLAUSES INCORPORATED BY FULL TEXT 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper (May 2011) (a) Definitions. As used in this clause-- Postconsumer fiber means- (1) Paper, paperboard, and fibrous materials from retail stores, office buildings, homes, and so forth, after they have passed through their end-usage as a consumer item, including: used corrugated boxes; old newspapers; old magazines; mixed waste paper; tabulating cards; and used cordage; or (2) All paper, paperboard, and fibrous materials that enter and are collected from municipal solid waste; but not (3) Fiber derived from printers' over-runs, converters' scrap, and over-issue publications. (b) The Contractor is required to submit paper documents, such as offers, letters, or reports that are printed or copied double-sided on paper containing at least 30 percent postconsumer fiber, whenever practicable, when not using electronic commerce methods to submit information or data to the Government. (End of clause) CLAUSES INCORPORATED BY FULL TEXT 52.204-7 SYSTEM FOR AWARD MANAGEMENT (OCT 2016) (a) Definitions. As used in this provision-- Electronic Funds Transfer (EFT) indicator means a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management records for identifying alternative EFT accounts (see subpart 32.11) for the same entity. Registered in the System for Award Management (SAM) database means that-- (1) The Offeror has entered all mandatory information, including the unique entity identifier and the EFT indicator, if applicable, the Commercial and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see subpart 4.14) into the SAM database; (2) The offeror has completed the Core, Assertions, and Representations and Certifications, and Points of Contact sections of the registration in the SAM database; (3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The offeror will be required to provide consent for TIN validation to the Government as a part of the SAM registration process; and (4) The Government has marked the record ``Active''. Unique entity identifier means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers. (b)(1) By submission of an offer, the Offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation. (2) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation ``Unique Entity Identifier'' followed by the unique entity identifier that identifies the Offeror's name and address exactly as stated in the offer. The Offeror also shall enter its EFT indicator, if applicable. The unique entity identifier will be used by the Contracting Officer to verify that the Offeror is registered in the SAM database. (c) If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for establishment of the unique entity identifier directly to obtain one. The Offeror should be prepared to provide the following information: (1) Company legal business name. (2) Tradestyle, doing business, or other name by which your entity is commonly recognized. (3) Company physical street address, city, state, and Zip Code. (4) Company mailing address, city, state and Zip Code (if separate from physical). (5) Company telephone number. (6) Date the company was started. (7) Number of employees at your location. (8) Chief executive officer/key manager. (9) Line of business (industry). (10) Company headquarters name and address (reporting relationship within your entity). (d) If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror. (e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation. (f) Offerors may obtain information on registration at https://www.acquisition.gov. (End of clause) 52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2016) (a) Definitions. As used in this clause-- Electronic Funds Transfer (EFT) indicator means a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management (SAM) records for identifying alternative EFT accounts (see subpart 32.11) for the same entity. Registered in the System for Award Management (SAM) database means that-- (1) The Contractor has entered all mandatory information, including the unique entity identifier and the EFT indicator (if applicable), the Commercial and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see subpart 4.14), into the SAM database; (2) The Contractor has completed the Core, Assertions, Representations and Certifications, and Points of Contact sections of the registration in the SAM database; (3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The Contractor will be required to provide consent for TIN validation to the Government as a part of the SAM registration process; and (4) The Government has marked the record ``Active''. System for Award Management (SAM) means the primary Government repository for prospective Federal awardee and Federal awardee information and the centralized Government system for certain contracting, grants, and other assistance-related processes. It includes- (1) Data collected from prospective Federal awardees required for the conduct of business with the Government; (2) Prospective contractor-submitted annual representations and certifications in accordance with FAR subpart 4.12; and (3) Identification of those parties excluded from receiving Federal contracts, certain subcontracts, and certain types of Federal financial and non-financial assistance and benefits. Unique entity identifier means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers. (b) The Contractor is responsible for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis, from the date of initial registration or subsequent updates, its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. (c)(1)(i) If a Contractor has legally changed its business name, doing business as name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to- (A) Change the name in the SAM database; (B) Comply with the requirements of subpart 42.12 of the FAR; and (C) Agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor shall provide with the notification sufficient documentation to support the legally changed name. (ii) If the Contractor fails to comply with the requirements of paragraph (c)(1)(i) of this clause, or fails to perform the agreement at paragraph (c)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the ``Suspension of Payment'' paragraph of the electronic funds transfer (EFT) clause of this contract. (2) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims (see FAR subpart 32.8, Assignment of Claims). Assignees shall be separately registered in the SAM. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the ``Suspension of Payment'' paragraph of the EFT clause of this contract. (3) The Contractor shall ensure that the unique entity identifier is maintained with the entity designated at www.sam.gov for establishment of the unique entity identifier throughout the life of the contract. The Contractor shall communicate any change to the unique entity identifier to the Contracting Officer within 30 days after the change, so an appropriate modification can be issued to update the data on the contract. A change in the unique entity identifier does not necessarily require a novation be accomplished. (d) Contractors may obtain additional information on registration and annual confirmation requirements at https://www.acquisition.gov. (End of clause) 52.204-14 SERVICE CONTRACT REPORTING REQUIREMENTS (OCT 2016) (a) Definition. First-tier subcontract means a subcontract awarded directly by the Contractor for the purpose of acquiring supplies or services (including construction) for performance of a prime contract. It does not include the Contractor's supplier agreements with vendors, such as long-term arrangements for materials or supplies that benefit multiple contracts and/or the costs of which are normally applied to a Contractor's general and administrative expenses or indirect costs. (b) The Contractor shall report, in accordance with paragraphs (c) and (d) of this clause, annually by October 31, for services performed under this contract during the preceding Government fiscal year (October 1-September 30). (c) The Contractor shall report the following information: (1) Contract number and, as applicable, order number. (2) The total dollar amount invoiced for services performed during the previous Government fiscal year under the contract. (3) The number of Contractor direct labor hours expended on the services performed during the previous Government fiscal year. (4) Data reported by subcontractors under paragraph (f) of this clause. (d) The information required in paragraph (c) of this clause shall be submitted via the internet at www.sam.gov. (See SAM User Guide). If the Contractor fails to submit the report in a timely manner, the contracting officer will exercise appropriate contractual remedies. In addition, the Contracting Officer will make the Contractor's failure to comply with the reporting requirements a part of the Contractor's performance information under FAR subpart 42.15. (e) Agencies will review Contractor reported information for reasonableness and consistency with available contract information. In the event the agency believes that revisions to the Contractor reported information are warranted, the agency will notify the Contractor no later than November 15. By November 30, the Contractor shall revise the report, or document its rationale for the agency. (f)(1) The Contractor shall require each first-tier subcontractor providing services under this contract, with subcontract(s) each valued at or above the thresholds set forth in 4.1703(a)(2), to provide the following detailed information to the Contractor in sufficient time to submit the report: (i) Subcontract number (including subcontractor name and unique entity identifier); and (ii) The number of first-tier subcontractor direct-labor hours expended on the services performed during the previous Government fiscal year. (2) The Contractor shall advise the subcontractor that the information will be made available to the public as required by section 743 of Division C of the Consolidated Appropriations Act, 2010. (End of clause) 52.204-15 SERVICE CONTRACT REPORTING REQUIREMENTS FOR INDEFINITE-DELIVERY CONTRACTS (OCT 2016) (a) Definition. First-tier subcontract meansa subcontract awarded directly by the Contractor for the purpose of acquiring supplies or services (including construction) for performance of a prime contract. It does not include the Contractor's supplier agreements with vendors, such as long-term arrangements for materials or supplies that benefit multiple contracts and/or the costs of which are normally applied to a Contractor's general and administrative expenses or indirect costs. (b) The Contractor shall report, in accordance with paragraphs (c) and (d) of this clause, annually by October 31, for services performed during the preceding Government fiscal year (October 1-September 30) under this contract for orders that exceed the thresholds established in 4.1703(a)(2). (c) The Contractor shall report the following information: (1) Contract number and order number. (2) The total dollar amount invoiced for services performed during the previous Government fiscal year under the order. (3) The number of Contractor direct labor hours expended on the services performed during the previous Government fiscal year. (4) Data reported by subcontractors under paragraph (f) of this clause. (d) The information required in paragraph (c) of this clause shall be submitted via the internet at www.sam.gov. (See SAM User Guide). If the Contractor fails to submit the report in a timely manner, the Contracting Officer will exercise appropriate contractual remedies. In addition, the Contracting Officer will make the Contractor's failure to comply with the reporting requirements a part of the Contractor's performance information under FAR subpart 42.15. (e) Agencies will review Contractor reported information for reasonableness and consistency with available contract information. In the event the agency believes that revisions to the Contractor reported information are warranted, the agency will notify the Contractor no later than November 15. By November 30, the Contractor shall revise the report, or document its rationale for the agency. (f)(1) The Contractor shall require each first-tier subcontractor providing services under this contract, with subcontract(s) each valued at or above the thresholds set forth in 4.1703(a)(2), to provide the following detailed information to the Contractor in sufficient time to submit the report: (i) Subcontract number (including subcontractor name and unique entity identifier), and (ii) The number of first-tier subcontractor direct-labor hours expended on the services performed during the previous Government fiscal year. (2) The Contractor shall advise the subcontractor that the information will be made available to the public as required by section 743 of Division C of the Consolidated Appropriations Act, 2010. (End of clause) CLAUSES INCORPORATED BY REFERENCE 52.204-17 Ownership or Control of Offeror JUL 2016 CLAUSES INCORPORATED BY FULL TEXT 52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE (JUL 2016) (a) Definition. As used in this clause-- Commercial and Government Entity (CAGE) code means-- (1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity; or (2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code. (b) Contractors shall ensure that the CAGE code is maintained throughout the life of the contract. For contractors registered in the System for Award Management (SAM), the DLA Commercial and Government Entity (CAGE) Branch shall only modify data received from SAM in the CAGE master file if the contractor initiates those changes via update of its SAM registration. Contractors undergoing a novation or change-of-name agreement shall notify the contracting officer in accordance with subpart 42.12. The contractor shall communicate any change to the CAGE code to the contracting officer within 30 days after the change, so that a modification can be issued to update the CAGE code on the contract. (c) Contractors located in the United States or its outlying areas that are not registered in SAM shall submit written change requests to the DLA Commercial and Government Entity (CAGE) Branch. Requests for changes shall be provided at https://cage.dla.mil. Change requests to the CAGE master file are accepted from the entity identified by the code. (d) Contractors located outside the United States and its outlying areas that are not registered in SAM shall contact the appropriate National Codification Bureau (points of contact available at http://www.nato.int/structur/AC/135/main/links/contacts.htm) or NSPA at https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx to request CAGE changes. (e) Additional guidance for maintaining CAGE codes is available at https://cage.dla.mil. (End of Clause) 52.204-16 COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING (JUL 2016) (a) Definition. As used in this provision-- Commercial and Government Entity (CAGE) code means- (1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity; or (2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code. (b) The Offeror shall enter its CAGE code in its offer with its name and address or otherwise include it prominently in its proposal. The CAGE code entered must be for that name and address. Enter ``CAGE'' before the number. The CAGE code is required prior to award. (c) CAGE codes may be obtained via-- (1) Registration in the System for Award Management (SAM) at www.sam.gov. If the Offeror is located in the United States or its outlying areas and does not already have a CAGE code assigned, the DLA Commercial and Government Entity (CAGE) Branch will assign a CAGE code as a part of the SAM registration process. SAM registrants located outside the United States and its outlying areas shall obtain a NCAGE code prior to registration in SAM (see paragraph (c)(3) of this provision). (2) The DLA Commercial and Government Entity (CAGE) Branch. If registration in SAM is not required for the subject procurement, and the offeror does not otherwise register in SAM, an offeror located in the United States or its outlying areas may request that a CAGE code be assigned by submitting a request at https://cage.dla.mil. (3) The appropriate country codification bureau. Entities located outside the United States and its outlying areas may obtain an NCAGE code by contacting the Codification Bureau in the foreign entity's country if that country is a member of NATO or a sponsored nation. NCAGE codes may be obtained from the NSPA at https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx if the foreign entity's country is not a member of NATO or a sponsored nation. Points of contact for codification bureaus, as well as additional information on obtaining NCAGE codes, are available at http://www.nato.int/structur/AC/135/main/links/contacts.htm. (d) Additional guidance for establishing and maintaining CAGE codes is available at https://cage.dla.mil. (e) When a CAGE Code is required for the immediate owner and/or the highest-level owner by 52.204-17 or 52.212-3(p), the Offeror shall obtain the respective CAGE Code from that entity to supply the CAGE Code to the Government. (f) Do not delay submission of the offer pending receipt of a CAGE code. (End of Provision) CLAUSES INCORPORATED BY FULL TEXT 52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC 2014) The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract. (End of clause) CLAUSES INCORPORATED BY FULL TEXT 52.216-19 ORDER LIMITATIONS (OCT 1995) (CESAJ ADAPTATION) (a) Minimum order. When the Government requires services covered by this contract in an amount of less than $2,500.00, the Government is not obligated to purchase, nor is the Contractor obligated to furnish, those services under the contract. (b) Maximum order. The Contractor is not obligated to honor: (1) Any order for a single item in excess of $50,000.00; or (2) A series of orders from the same ordering office within 5 days that together call for quantities exceeding $250,000.00. (c) If this is a requirements contract (i.e., includes the Requirements clause at subsection 52.216-21 of the Federal Acquisition Regulation (FAR)), the Government is not required to order a part of any one requirement from the Contractor if that requirement exceeds the maximum-order limitations in paragraph (b) above. (d) Notwithstanding paragraphs (b) and (c) above, the Contractor shall honor any order exceeding the maximum order limitations in paragraph (b), unless that order (or orders) is returned to the ordering office within 5 days after issuance, with written notice stating the Contractor's intent not to perform the services called for and the reasons. Upon receiving this notice, the Government may acquire the services from another source. (End of clause) CLAUSES INCORPORATED BY FULL TEXT 52.216-22 INDEFINITE QUANTITY (OCT 1995) (CESAJ ADAPTATION) (a) This is an indefinite-quantity contract for the supplies or services specified, and effective for the period stated, in the Schedule. The quantities of supplies and services specified in the Schedule are estimates only and are not purchased by this contract. (b) Delivery or performance shall be made only as authorized by orders issued in accordance with the Ordering clause. The Contractor shall furnish to the Government, when and if ordered, the supplies or services specified in the Schedule up to and including the quantity designated in the Schedule as the "maximum." The Government shall order at least the quantity of supplies or services designated in the Schedule as the "minimum." (c) Except for any limitations on quantities in the Order Limitations clause or in the Schedule, there is no limit on the number of orders that may be issued. The Government may issue orders requiring delivery to multiple destinations or performance at multiple locations. (d) Any order issued during the effective period of this contract and not completed within that period shall be completed by the Contractor within the time specified in the order. The contract shall govern the Contractor's and Government's rights and obligations with respect to that order to the same extent as if the order were completed during the contract's effective period; provided, that the Contractor shall not be required to make any deliveries under this contract after completion of all outstanding orders. (End of clause) CLAUSES INCORPORATED BY FULL TEXT 52.217-8 OPTION TO EXTEND SERVICES (NOV 1999) The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within 30 days.. (End of clause) CLAUSES INCORPORATED BY FULL TEXT 52.222-49 SERVICE CONTRACT LABOR STANDARDS--PLACE OF PERFORMANCE UNKNOWN (MAY 2014) (a) This contract is subject to the Service Contract Labor Standards statute, and the place of performance was unknown when the solicitation was issued. In addition to places or areas identified in wage determinations, if any, attached to the solicitation, wage determinations have also been requested for the following all Florida Counties. The Contracting Officer will request wage determinations for additional places or areas of performance if asked to do so in writing by the COR. (b) Offerors who intend to perform in a place or area of performance for which a wage determination has not been attached or requested may nevertheless submit bids or proposals. However, a wage determination shall be requested and incorporated in the resultant contract retroactive to the date of contract award, and there shall be no adjustment in the contract price. (End of clause) CLAUSES INCORPORATED BY FULL TEXT 52.223-4 RECOVERED MATERIAL CERTIFICATION (MAY 2008) As required by the Resource Conservation and Recovery Act of 1976 (42 U.S.C. 6962(c)(3)(A)(i)), the offeror certifies, by signing this offer, that the percentage of recovered materials content for EPA-designated items to be delivered or used in the performance of the contract will be at least the amount required by the applicable contract specifications or other contractual requirements. (End of provision) CLAUSES INCORPORATED BY FULL TEXT 52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA-DESIGNATED ITEMS (MAY 2008) (a) Definitions. As used in this clause-- Postconsumer material means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item. Postconsumer material is a part of the broader category of "recovered material." Recovered material means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process. (b) The Contractor, on completion of this contract, shall-- (1) Estimate the percentage of the total recovered material content for EPA-designated item(s) delivered and/or used in contract performance, including, if applicable, the percentage of post-consumer material content; and (2) Submit this estimate to (Contracting Officer complete in accordance with agency procedures). (End of clause) CLAUSES INCORPORATED BY FULL TEXT 52.223-17 AFFIRMATIVE PROCUREMENT OF EPA-DESIGNATED ITEMS IN SERVICE AND CONSTRUCTION CONTRACTS (MAY 2008) (a) In the performance of this contract, the Contractor shall make maximum use of products containing recovered materials that are EPA-designated items unless the product cannot be acquired- (1) Competitively within a timeframe providing for compliance with the contract performance schedule; (2) Meeting contract performance requirements; or (3) At a reasonable price. (b) Information about this requirement is available at EPA's Comprehensive Procurement Guidelines web site, http://www.epa.gov/cpg/. The list of EPA-designated items is available at http://www.epa.gov/cpg/products.htm. (End of clause) CLAUSES INCORPORATED BY FULL TEXT 52.225-25 PROHIBITION ON CONTRACTING WITH ENTITIES ENGAGING IN CERTAIN ACTIVITIES OR TRANSACTIONS RELATING TO IRAN--REPRESENTATION AND CERTIFICATIONS. (OCT 2015) (a) Definitions. As used in this provision-- Person-- (1) Means-- (i) A natural person; (ii) A corporation, business association, partnership, society, trust, financial institution, insurer, underwriter, guarantor, and any other business organization, any other nongovernmental entity, organization, or group, and any governmental entity operating as a business enterprise; and (iii) Any successor to any entity described in paragraph (1)(ii) of this definition; and (2) Does not include a government or governmental entity that is not operating as a business enterprise. Sensitive technology-- (1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically-- (i) To restrict the free flow of unbiased information in Iran; or (ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and (2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)). (b) The offeror shall email questions concerning sensitive technology to the Department of State at CISADA106@state.gov. (c) Except as provided in paragraph (d) of this provision or if a waiver has been granted in accordance with 25.703-4, by submission of its offer, the offeror- (1) Represents, to the best of its knowledge and belief, that the offeror does not export any sensitive technology to the government of Iran or any entities or individuals owned or controlled by, or acting on behalf or at the direction of, the government of Iran; (2) Certifies that the offeror, or any person owned or controlled by the offeror, does not engage in any activities for which sanctions may be imposed under section 5 of the Iran Sanctions Act. These sanctioned activities are in the areas of development of the petroleum resources of Iran, production of refined petroleum products in Iran, sale and provision of refined petroleum products to Iran, and contributing to Iran's ability to acquire or develop certain weapons or technologies; and (3) Certifies that the offeror, and any person owned or controlled by the offeror, does not knowingly engage in any transaction that exceeds $3,500 with Iran's Revolutionary Guard Corps or any of its officials, agents, or affiliates, the property and interests in property of which are blocked pursuant to the International Emergency Economic Powers Act (50 U.S.C. 1701 et seq.) (see OFAC's Specially Designated Nationals and Blocked Persons List at http://www.treasury.gov/ofac/downloads/t11sdn.pdf). (d) Exception for trade agreements. The representation requirement of paragraph (c)(1) and the certification requirements of paragraphs (c)(2) and (c)(3) of this provision do not apply if- (1) This solicitation includes a trade agreements notice or certification (e.g., 52.225-4, 52.225-6, 52.225-12, 52.225-24, or comparable agency provision); and (2) The offeror has certified that all the offered products to be supplied are designated country end products or designated country construction material. (End of provision) CLAUSES INCORPORATED BY REFERENCE 52.232-39 Unenforceability of Unauthorized Obligations JUL 2013 CLAUSES INCORPORATED BY FULL TEXT 52.242-15 STOP-WORK ORDER (AUG 1989) (a) The Contracting Officer may, at any time, by written order to the Contractor, require the Contractor to stop all, or any part, of the work called for by this contract for a period of 90 days after the order is delivered to the Contractor, and for any further period to which the parties may agree. The order shall be specifically identified as a stop-work order issued under this clause. Upon receipt of the order, the Contractor shall immediately comply with its terms and take all reasonable steps to minimize the incurrence of costs allocable to the work covered by the order during the period of work stoppage. Within a period of 90 days after a stop-work is delivered to the Contractor, or within any extension of that period to which the parties shall have agreed, the Contracting Officer shall either-- (1) Cancel the stop-work order; or (2) Terminate the work covered by the order as provided in the Default, or the Termination for Convenience of the Government, clause of this contract. (b) If a stop-work order issued under this clause is canceled or the period of the order or any extension thereof expires, the Contractor shall resume work. The Contracting Officer shall make an equitable adjustment in the delivery schedule or contract price, or both, and the contract shall be modified, in writing, accordingly, if-- (1) The stop-work order results in an increase in the time required for, or in the Contractor's cost properly allocable to, the performance of any part of this contract; and (2) The Contractor asserts its right to the adjustment within 30 days after the end of the period of work stoppage; provided, that, if the Contracting Officer decides the facts justify the action, the Contracting Officer may receive and act upon the claim submitted at any time before final payment under this contract. (c) If a stop-work order is not canceled and the work covered by the order is terminated for the convenience of the Government, the Contracting Officer shall allow reasonable costs resulting from the stop-work order in arriving at the termination settlement. (d) If a stop-work order is not canceled and the work covered by the order is terminated for default, the Contracting Officer shall allow, by equitable adjustment or otherwise, reasonable costs resulting from the stop-work order. (End of clause) 52.242-17 GOVERNMENT DELAY OF WORK (APR 1984) (a) If the performance of all or any part of the work of this contract is delayed or interrupted (1) by an act of the Contracting Officer in the administration of this contract that is not expressly or impliedly authorized by this contract, or (2) by a failure of the Contracting Officer to act within the time specified in this contract, or within a reasonable time if not specified, an adjustment (excluding profit) shall be made for any increase in the cost of performance of this contract caused by the delay or interruption and the contract shall be modified in writing accordingly. Adjustment shall also be made in the delivery or performance dates and any other contractual term or condition affected by the delay or interruption. However, no adjustment shall be made under this clause for any delay or interruption to the extent that performance would have been delayed or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an adjustment is provided or excluded under any other term or condition of this contract. (b) A claim under this clause shall not be allowed (1) for any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved, and (2) unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the delay or interruption, but not later than the day of final payment under the contract. (End of clause) 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): http://farsite.hill.af.mil (End of clause) 252.201-7000 CONTRACTING OFFICER'S REPRESENTATIVE (DEC 1991) (a) "Definition. Contracting officer's representative" means an individual designated in accordance with subsection 201.602-2 of the Defense Federal Acquisition Regulation Supplement and authorized in writing by the contracting officer to perform specific technical or administrative functions. (b) If the Contracting Officer designates a contracting officer's representative (COR), the Contractor will receive a copy of the written designation. It will specify the extent of the COR's authority to act on behalf of the contracting officer. The COR is not authorized to make any commitments or changes that will affect price, quality, quantity, delivery, or any other term or condition of the contract. (End of clause) 252.203-7000 REQUIREMENTS RELATING TO COMPENSATION OF FORMER DOD OFFICIALS (SEP 2011) (a) Definition. Covered DoD official, as used in this clause, means an individual that-- (1) Leaves or left DoD service on or after January 28, 2008; and (2)(i) Participated personally and substantially in an acquisition as defined in 41 U.S.C. 131 with a value in excess of $10 million, and serves or served-- (A) In an Executive Schedule position under subchapter II of chapter 53 of Title 5, United States Code; (B) In a position in the Senior Executive Service under subchapter VIII of chapter 53 of Title 5, United States Code; or (C) In a general or flag officer position compensated at a rate of pay for grade O-7 or above under section 201 of Title 37, United States Code; or (ii) Serves or served in DoD in one of the following positions: Program manager, deputy program manager, procuring contracting officer, administrative contracting officer, source selection authority, member of the source selection evaluation board, or chief of a financial or technical evaluation team for a contract in an amount in excess of $10 million. (b) The Contractor shall not knowingly provide compensation to a covered DoD official within 2 years after the official leaves DoD service, without first determining that the official has sought and received, or has not received after 30 days of seeking, a written opinion from the appropriate DoD ethics counselor regarding the applicability of post-employment restrictions to the activities that the official is expected to undertake on behalf of the Contractor. (c) Failure by the Contractor to comply with paragraph (b) of this clause may subject the Contractor to rescission of this contract, suspension, or debarment in accordance with 41 U.S.C. 2105(c). (End of clause) 252.204-7004 ALTERNATE A, SYSTEM FOR AWARD MANAGEMENT (FEB 2014) (a) Definitions. As used in this provision- "System for Award Management (SAM) database" means the primary Government repository for contractor information required for the conduct of business with the Government. "Commercial and Government Entity (CAGE) code" means- (1) A code assigned by the Defense Logistics Information Service (DLIS) to identify a commercial or Government entity; or (2) A code assigned by a member of the North Atlantic Treaty Organization that DLIS records and maintains in the CAGE master file. This type of code is known as an "NCAGE code." "Data Universal Numbering System (DUNS) number" means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities. "Data Universal Numbering System +4 (DUNS+4) number" means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.) This 4-character suffix may be assigned at the discretion of the business concern to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts (see FAR 32.11) for the same parent concern. "Registered in the System for Award Management (SAM) database" means that- (1) The contractor has entered all mandatory information, including the DUNS number or the DUNS+4 number, and Contractor and Government Entity (CAGE) code into the SAM database; and (2) The contractor has completed the Core Data, Assertions, Representations and Certifications, and Points of Contact sections of the registration in the SAM database; (3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The Contractor will be required to provide consent for TIN validation to the Government as part of the SAM registration process; and (4) The Government has marked the record "Active." (b) (1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation. (2) The offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation "DUNS" or "DUNS+4" followed by the DUNS or DUNS+4 number that identifies the offeror's name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the SAM database. (c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one. (1) An offeror may obtain a DUNS number- (i) Via the internet at http://fedgov.dnb.com/webform or if the offeror does not have internet access, it may call Dun and Bradstreet at 1-866-705-5711 if located within the United States; or (ii) If located outside the United States, by contacting the local Dun and Bradstreet office. The offeror should indicate that it is an offeror for a U.S. Government contract when contacting the local Dun and Bradstreet office. (2) The offeror should be prepared to provide the following information: (i) Company legal business name. (ii) Tradestyle, doing business, or other name by which your entity is commonly recognized. (iii) Company physical street address, city, state and Zip Code. (iv) Company mailing address, city, state and Zip Code (if separate from physical). (v) Company telephone number. (vi) Date the company was started. (vii) Number of employees at your location. (viii) Chief executive officer/key manager. (ix) Line of business (industry). (x) Company Headquarters name and address (reporting relationship within your entity). (d) If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror. (e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation. (f) Offerors may obtain information on registration at https://www.acquisition.gov. (End of Provision) 252.204-7011 ALTERNATIVE LINE-ITEM STRUCTURE (SEP 2011) (a) Line items are the basic structural elements in a solicitation or contract that provide for the organization of contract requirements to facilitate pricing, delivery, inspection, acceptance and payment. Line items are organized into contract line items, subline items, and exhibit line items. Separate line items should be established to account for separate pricing, identification (see section 211.274 of the Defense Federal Acquisition Regulation Supplement), deliveries, or funding. The Government recognizes that the line item structure in this solicitation may not conform to every offeror's practices. Failure to correct these issues can result in difficulties in accounting for deliveries and processing payments. Therefore, offerors are invited to propose an alternative line item structure for items on which bids, proposals, or quotes are requested in this solicitation to ensure that the resulting contract structure is economically and administratively advantageous to the Government and the Contractor. (b) If an alternative line item structure is proposed, the structure must be consistent with subpart 204.71 of the Defense Federal Acquisition Regulation Supplement and PGI 204.71. A sample solicitation line-item structure and a corresponding offer of a proposed alternative line-item structure follow. Solicitation: ---------------------------------------------------------------------------------------------------------------- Item No. Supplies/Service Quantity Unit Unit price Amount ---------------------------------------------------------------------------------------------------------------- 0001............................ Computer, Desktop with 20 EA....................... CPU, Monitor, Keyboard and Mouse. ---------------------------------------------------------------------------------------------------------------- Alternative line-item structure offer where monitors are shipped separately: ---------------------------------------------------------------------------------------------------------------- Item No. Supplies/Service Quantity Unit Unit Price Amount ---------------------------------------------------------------------------------------------------------------- 0001............................ Computer, Desktop with 20 EA....................... CPU, Keyboard and Mouse. 0002............................ Monitor................. 20 EA....................... ---------------------------------------------------------------------------------------------------------------- (End of provision) 252.215-7007 NOTICE OF INTENT TO RESOLICIT (JUN 2012) This solicitation provides offerors fewer than 30 days to submit proposals. In the event that only one offer is received in response to this solicitation, the Contracting Officer may cancel the solicitation and resolicit for an additional period of at least 30 days in accordance with 215.371-2. (End of provision) 252.215-7008 ONLY ONE OFFER (OCT 2013) (a) After initial submission of offers, the Offeror agrees to submit any subsequently requested additional cost or pricing data if the Contracting Officer notifies the Offeror that-- (1) Only one offer was received; and (2) Additional cost or pricing data is required in order to determine whether the price is fair and reasonable or to comply with the statutory requirement for certified cost or pricing data (10 U.S.C. 2306a and FAR 15.403-3). (b) Requirement for submission of additional cost or pricing data. Except as provided in paragraph (c) of this provision, the Offeror shall submit additional cost or pricing data as follows: (1) If the Contracting Officer notifies the Offeror that additional cost or pricing data are required in accordance with paragraph (a) of this clause, the data shall be certified unless an exception applies (FAR 15.403-1(b)). (2) Exceptions from certified cost or pricing data. In lieu of submitting certified cost or pricing data, the Offeror may submit a written request for exception by submitting the information described in the following paragraphs. The Contracting Officer may require additional supporting information, but only to the extent necessary to determine whether an exception should be granted, and whether the price is fair and reasonable. (i) Identification of the law or regulation establishing the price offered. If the price is controlled under law by periodic rulings, reviews, or similar actions of a governmental body, attach a copy of the controlling document, unless it was previously submitted to the contracting office. (ii) Commercial item exception. For a commercial item exception, the Offeror shall submit, at a minimum, information on prices at which the same item or/similar items have previously been sold in the commercial market that is adequate for evaluating the reasonableness of the price for this acquisition. Such information may include- (A) For catalog items, a copy of or identification of the catalog and its date, or the appropriate pages for the offered items, or a statement that the catalog is on file in the buying office to which the proposal is being submitted. Provide a copy or describe current discount policies and price lists (published or unpublished), e.g., wholesale, original equipment manufacturer, or reseller. Also explain the basis of each offered price and its relationship to the established catalog price, including how the proposed price relates to the price of recent sales in quantities similar to the proposed quantities; (B) For market-priced items, the source and date or period of the market quotation or other basis for market price, the base amount, and applicable discounts. In addition, describe the nature of the market; or (C) For items included on an active Federal Supply Service Multiple Award Schedule contract, proof that an exception has been granted for the schedule item. (3) The Offeror grants the Contracting Officer or an authorized representative the right to examine, at any time before award, books, records, documents, or other directly pertinent records to verify any request for an exception under this provision, and the reasonableness of price. For items priced using catalog or market prices, or law or regulation, access does not extend to cost or profit information or other data relevant solely to the Offeror's determination of the prices to be offered in the catalog or marketplace. (4) Requirements for certified cost or pricing data. If the Offeror is not granted an exception from the requirement to submit certified cost or pricing data, the following applies: (i) The Offeror shall prepare and submit certified cost or pricing data and supporting attachments in accordance with the instructions contained in Table 15-2 of FAR 15.408, which is incorporated by reference with the same force and effect as though it were inserted here in full text. The instructions in Table 15-2 are incorporated as a mandatory format to be used, unless the Contracting Officer and the Offeror agree to a different format. (ii) As soon as practicable after agreement on price, but before contract award (except for unpriced actions such as letter contracts), the offeror shall submit a Certificate of Current Cost or Pricing Data, as prescribed by FAR 15.406-2. (c) If the Offeror is the Canadian Commercial Corporation, certified cost or pricing data are not required. If the Contracting Officer notifies the Canadian Commercial Corporation that additional data other than certified cost or pricing data are required in accordance with 225.870-4(c), the Canadian Commercial Corporation shall obtain and provide the following: (1) Profit rate or fee (as applicable). (2) Analysis provided by Public Works and Government Services Canada to the Canadian Commercial Corporation to determine a fair and reasonable price (comparable to the analysis required at FAR 15.404-1). (3) Data other than certified cost or pricing data necessary to permit a determination by the U.S. Contracting Officer that the proposed price is fair and reasonable [U.S. Contracting Officer to provide description of the data required in accordance with FAR 15.403-3(a)(1) with the notification]. (4) As specified in FAR 15.403-3(a)(4), an offeror who does not comply with a requirement to submit data that the U.S. Contracting Officer has deemed necessary to determine price reasonableness or cost realism is ineligible for award unless the head of the contracting activity determines that it is in the best interest of the Government to make the award to that offeror. (d) If negotiations are conducted, the negotiated price should not exceed the offered price. (End of provision) 252.226-7001 UTILIZATION OF INDIAN ORGANIZATIONS AND INDIAN-OWNED ECONOMIC ENTERPRISES, AND NATIVE HAWAIIAN SMALL BUSINESS CONCERNS (SEP 2004) (a) Definitions. As used in this clause-- Indian means-- (1) Any person who is a member of any Indian tribe, band, group, pueblo, or community that is recognized by the Federal Government as eligible for services from the Bureau of Indian Affairs (BIA) in accordance with 25 U.S.C. 1452(c); and (2) Any ``Native'' as defined in the Alaska Native Claims Settlement Act (43 U.S.C. 1601 et seq.). Indian organization means the governing body of any Indian tribe or entity established or recognized by the governing body of an Indian tribe for the purposes of 25 U.S.C. chapter 17. Indian-owned economic enterprise means any Indian-owned (as determined by the Secretary of the Interior) commercial, industrial, or business activity established or organized for the purpose of profit, provided that Indian ownership constitutes not less than 51 percent of the enterprise. Indian tribe means any Indian tribe, band, group, pueblo, or community, including native villages and native groups (including corporations organized by Kenai, Juneau, Sitka, and Kodiak) as defined in the Alaska Native Claims Settlement Act, that is recognized by the Federal Government as eligible for services from BIA in accordance with 25 U.S.C. 1452(c). Interested party means a contractor or an actual or prospective offeror whose direct economic interest would be affected by the award of a subcontract or by the failure to award a subcontract. Native Hawaiian small business concern means an entity that is-- (1) A small business concern as defined in section 3 of the Small Business Act (15 U.S.C. 632) and relevant implementing regulations; and (2) Owned and controlled by a Native Hawaiian as defined in 25 U.S.C. 4221(9). (b) The Contractor shall use its best efforts to give Indian organizations, Indian-owned economic enterprises, and Native Hawaiian small business concerns the maximum practicable opportunity to participate in the subcontracts it awards, to the fullest extent consistent with efficient performance of the contract. (c) The Contracting Officer and the Contractor, acting in good faith, may rely on the representation of an Indian organization, Indian-owned economic enterprise, or Native Hawaiian small business concern as to its eligibility, unless an interested party challenges its status or the Contracting Officer has independent reason to question that status. (d) In the event of a challenge to the representation of a subcontractor, the Contracting Officer will refer the matter to-- (1) For matters relating to Indian organizations or Indian-owned economic enterprises: U.S. Department of the Interior, Bureau of Indian Affairs, Attn: Chief, Division of Contracting and Grants Administration, 1849 C Street NW, MS-2626-MIB, Washington, DC 20240-4000. The BIA will determine the eligibility and will notify the Contracting Officer. (2) For matters relating to Native Hawaiian small business concerns: Department of Hawaiian Home Lands, PO Box 1879, Honolulu, HI 96805. The Department of Hawaiian Home Lands will determine the eligibility and will notify the Contracting Officer. (e) No incentive payment will be made-- (1) While a challenge is pending; or (2) If a subcontractor is determined to be an ineligible participant. (f)(1) The Contractor, on its own behalf or on behalf of a subcontractor at any tier, may request an incentive payment in accordance with this clause. (2) The incentive amount that may be requested is 5 percent of the estimated cost, target cost, or fixed price included in the subcontract at the time of award to the Indian organization, Indian-owned economic enterprise, or Native Hawaiian small business concern. (3) In the case of a subcontract for commercial items, the Contractor may receive an incentive payment only if the subcontracted items are produced or manufactured in whole or in part by an Indian organization, Indian-owned economic enterprise, or Native Hawaiian small business concern. (4) The Contractor has the burden of proving the amount claimed and shall assert its request for an incentive payment prior to completion of contract performance. (5) The Contracting Officer, subject to the terms and conditions of the contract and the availability of funds, will authorize an incentive payment of 5 percent of the estimated cost, target cost, or fixed price included in the subcontract awarded to the Indian organization, Indian-owned economic enterprise, or Native Hawaiian small business concern. (6) If the Contractor requests and receives an incentive payment on behalf of a subcontractor, the Contractor is obligated to pay the subcontractor the incentive amount. (g) The Contractor shall insert the substance of this clause, including this paragraph (g), in all subcontracts exceeding $500,000. (End of clause) 252.232-7003 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS AND RECEIVING REPORTS (JUNE 2012) (a) Definitions. As used in this clause- (1) Contract financing payment and invoice payment have the meanings given in section 32.001 of the Federal Acquisition Regulation. (2) Electronic form means any automated system that transmits information electronically from the initiating system to all affected systems. Facsimile, e-mail, and scanned documents are not acceptable electronic forms for submission of payment requests. However, scanned documents are acceptable when they are part of a submission of a payment request made using Wide Area WorkFlow (WAWF) or another electronic form authorized by the Contracting Officer. (3) Payment request means any request for contract financing payment or invoice payment submitted by the Contractor under this contract. (4) Receiving report means the data required by the clause at 252.246-7000, Material Inspection and Receiving Report. (b) Except as provided in paragraph (c) of this clause, the Contractor shall submit payment requests and receiving reports using WAWF, in one of the following electronic formats that WAWF accepts: Electronic Data Interchange, Secure File Transfer Protocol, or World Wide Web input. Information regarding WAWF is available on the Internet at https://wawf.eb.mil/. (c) The Contractor may submit a payment request and receiving report using other than WAWF only when- (1) The Contracting Officer administering the contract for payment has determined, in writing, that electronic submission would be unduly burdensome to the Contractor. In such cases, the Contractor shall include a copy of the Contracting Officer's determination with each request for payment; (2) DoD makes payment for commercial transportation services provided under a Government rate tender or a contract for transportation services using a DoD-approved electronic third party payment system or other exempted vendor payment/invoicing system (e.g., PowerTrack, Transportation Financial Management System, and Cargo and Billing System); (3) DoD makes payment for rendered health care services using the TRICARE Encounter Data System (TEDS) as the electronic format; or (4) When the Governmentwide commercial purchase card is used as the method of payment, only submission of the receiving report in electronic form is required. (d) The Contractor shall submit any non-electronic payment requests using the method or methods specified in Section G of the contract. (e) In addition to the requirements of this clause, the Contractor shall meet the requirements of the appropriate payment clauses in this contract when submitting payments requests. (End of clause) 252.232-7010 LEVIES ON CONTRACT PAYMENTS (DEC 2006) (a) 26 U.S.C. 6331(h) authorizes the Internal Revenue Service (IRS) to continuously levy up to 100 percent of contract payments, up to the amount of tax debt. (b) When a levy is imposed on a payment under this contract and the Contractor believes that the levy may result in an inability to perform the contract, the Contractor shall promptly notify the Procuring Contracting Officer in writing, with a copy to the Administrative Contracting Officer, and shall provide-- (1) The total dollar amount of the levy; (2) A statement that the Contractor believes that the levy may result in an inability to perform the contract, including rationale and adequate supporting documentation; and (3) Advice as to whether the inability to perform may adversely affect national security, including rationale and adequate supporting documentation. (c) DoD shall promptly review the Contractor's assessment, and the Procuring Contracting Officer shall provide a written notification to the Contractor including-- (1) A statement as to whether DoD agrees that the levy may result in an inability to perform the contract; and (2)(i) If the levy may result in an inability to perform the contract and the lack of performance will adversely affect national security, the total amount of the monies collected that should be returned to the Contractor; or (ii) If the levy may result in an inability to perform the contract but will not impact national security, a recommendation that the Contractor promptly notify the IRS to attempt to resolve the tax situation. (d) Any DoD determination under this clause is not subject to appeal under the Contract Disputes Act. (End of clause) 52.237-10 IDENTIFICATION OF UNCOMPENSATED OVERTIME (MAR 2015) (a) Definitions. As used in this provision-- Adjusted hourly rate (including uncompensated overtime) is the rate that results from multiplying the hourly rate for a 40-hour work week by 40, and then dividing by the proposed hours per week which includes uncompensated overtime hours over and above the standard 40-hour work week. For example, 45 hours proposed on a 40- hour work week basis at $20 per hour would be converted to an uncompensated overtime rate of $17.78 per hour ($20.00 x 40 divided by 45 = $17.78). Uncompensated overtime means the hours worked without additional compensation in excess of an average of 40 hours per week by direct charge employees who are exempt from the Fair Labor Standards Act. Compensated personal absences such as holidays, vacations, and sick leave shall be included in the normal work week for purposes of computing uncompensated overtime hours. (b)(1) Whenever there is uncompensated overtime, the adjusted hourly rate (including uncompensated overtime), rather than the hourly rate, shall be applied to all proposed hours, whether regular or overtime hours. (2) All proposed labor hours subject to the adjusted hourly rate (including uncompensated overtime) shall be identified as either regular or overtime hours, by labor categories, and described at the same level of detail. This is applicable to all proposals whether the labor hours are at the prime or subcontract level. This includes uncompensated overtime hours that are in indirect cost pools for personnel whose regular hours are normally charged direct. (c) The offeror's accounting practices used to estimate uncompensated overtime must be consistent with its cost accounting practices used to accumulate and report uncompensated overtime hours. (d) Proposals that include unrealistically low labor rates, or that do not otherwise demonstrate cost realism, will be considered in a risk assessment and will be evaluated for award in accordance with that assessment. (e) The offeror shall include a copy of its policy addressing uncompensated overtime with its proposal. (End of clause) 252.243-7002 REQUESTS FOR EQUITABLE ADJUSTMENT (DEC 2012) (a) The amount of any request for equitable adjustment to contract terms shall accurately reflect the contract adjustment for which the Contractor believes the Government is liable. The request shall include only costs for performing the change, and shall not include any costs that already have been reimbursed or that have been separately claimed. All indirect costs included in the request shall be properly allocable to the change in accordance with applicable acquisition regulations. (b) In accordance with 10 U.S.C. 2410(a), any request for equitable adjustment to contract terms that exceeds the simplified acquisition threshold shall bear, at the time of submission, the following certificate executed by an individual authorized to certify the request on behalf of the Contractor: I certify that the request is made in good faith, and that the supporting data are accurate and complete to the best of my knowledge and belief. ---------------------------------------------------------------------- (Official's Name) ---------------------------------------------------------------------- (Title) (c) The certification in paragraph (b) of this clause requires full disclosure of all relevant facts, including-- (1) Certified cost or pricing data if required in accordance with subsection 15.403-4 of the Federal Acquisition Regulation (FAR); and (2) Data other than certified cost or pricing data, in accordance with subsection 15.403-3 of the FAR, including actual cost data and data to support any estimated costs, even if certified cost or pricing data are not required. (d) The certification requirement in paragraph (b) of this clause does not apply to---- (1) Requests for routine contract payments; for example, requests for payment for accepted supplies and services, routine vouchers under a cost-reimbursement type contract, or progress payment invoices; or (2) Final adjustment under an incentive provision of the contract. ADDENDUM TO 52.212-4 CLAUSES INCORPORATED BY FULL TEXT 52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS--COMMERCIAL ITEMS (JAN 2017) ALTERNATE I (FEB 2000) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (2) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015). (3) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553). (4) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)). (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (Contracting Officer check as appropriate.) _X__ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402). ____ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509). ____ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.) _X__ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-282) (31 U.S.C. 6101 note). ___ (5) [Reserved] ___ (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111-117, section 743 of Div. C). ___ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C). _X__ (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note). ____ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (July 2013) (41 U.S.C. 2313). ____ (10) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (MAY 2012) (section 738 of Division C of Pub. L. 112-74, section 740 of Division C of Pub. L. 111-117, section 743 of Division D of Pub. L. 111-8, and section 745 of Division D of Pub. L. 110-161). ____ (11) (i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (NOV 2011) (15 U.S.C. 657a). ____ (ii) Alternate I (NOV 2011) of 52.219-3. ____ (12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a). ____ (ii) Alternate I (JAN 2011) of 52.219-4. ____ (13) [Reserved] __X__ (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2011) (15 U.S.C. 644). ____ (ii) Alternate I (NOV 2011). ____ (iii) Alternate II (NOV 2011). ____ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644). ____ (ii) Alternate I (Oct 1995) of 52.219-7. ____ (iii) Alternate II (Mar 2004) of 52.219-7. __X__ (16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)). ____ (17)(i) 52.219-9, Small Business Subcontracting Plan (Jan 2017) (15 U.S.C. 637(d)(4)). ____ (ii) Alternate I (Nov 2016) of 52.219-9. ____ (iii) Alternate II (Nov 2016) of 52.219-9. ____ (iv) Alternate III (Nov 2016) of 52.219-9. ____ (v) Alternate IV (Nov 2016) of 52.219-9. ____ (18) 52.219-13, Notice of Set-Aside of Orders (NOV 2011) (15 U.S.C. 644(r)). __X__ (19) 52.219-14, Limitations on Subcontracting (JAN 2017) (15 U.S.C. 637(a)(14)). ____ (20) 52.219-16, Liquidated Damages-Subcon-tracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)). ____ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (NOV 2011) (15 U.S.C. 657f). _X___ (22) 52.219-28, Post Award Small Business Program Rerepresentation (July 2013) (15 U.S.C. 632(a)(2)). ____ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)). ____ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)). __X__ (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755). __X__(26) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126). __X__ (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). _X___ (28) 52.222-26, Equal Opportunity (Sept 2015) (E.O. 11246). __X__ (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212). _X___ (30) 52.222-36, Equal Opportunity for Workers with Disabilities (July 2014) (29 U.S.C. 793). __X__ (31) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212). _X___ (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). __X__ (33)(i) 52.222-50, Combating Trafficking in Persons (March 2, 2015) (22 U.S.C. chapter 78 and E.O. 13627). ____ (ii) Alternate I (March 2, 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627). __X__ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.) ____ (35) 52.222-59, Compliance with Labor Laws (Executive Order 13673) (OCT 2016). (Applies at $50 million for solicitations and resultant contracts issued from October 25, 2016 through April 24, 2017; applies at $500,000 for solicitations and resultant contracts issued after April 24, 2017). Note to paragraph (b)(35): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. ____ (36) 52.222-60, Paycheck Transparency (Executive Order 13673) (OCT 2016). __X__ (37)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.) ____ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.) ____ (38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (June, 2016) (E.O. 13693). ____ (39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (June, 2016) (E.O. 13693). ____ (40) (i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514). ____ (ii) Alternate I (OCT 2015) of 52.223-13. ____ (41) (i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (Jun 2014) (E.O.s 13423 and 13514). ____ (ii) Alternate I (Jun 2014) of 52.223-14. ____ (42) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b). ____ (43)(i) 52.223-16, Acquisition of EPEAT[supreg]-Registered Personal Computer Products (OCT 2015) (E.O.s 13423 and 13514). ____ (ii) Alternate I (Jun 2014) of 52.223-16. _X___ (44) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011) (E.O. 13513). ____ (45) 52.223-20, Aerosols (June, 2016) (E.O. 13693). ____ (46) 52.223-21, Foams (June, 2016) (E.O. 13693). ____ (47)(i) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a). ____ (ii) Alternate I (JAN 2017) of 52.224-3. ____ (48) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83). ____ (49) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43. ____ (ii) Alternate I (May 2014) of 52.225-3. ____ (iii) Alternate II (May 2014) of 52.225-3. ____ (iv) Alternate III (May 2014) of 52.225-3. ____ (50) 52.225-5, Trade Agreements (Oct 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note). __X__ (51) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). ____ (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). ____ (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150 ____ (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150). ____ (55) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 255(f), 10 U.S.C. 2307(f)). ____ (56) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C. 255(f), 10 U.S.C. 2307(f)). _X___ (57) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (July 2013) (31 U.S.C. 3332). ____ (58) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (July 2013) (31 U.S.C. 3332). ____ (59) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332). ____ (60) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a). ____ (61) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C. 637(d)(12)). ____ (62)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631). ____ (ii) Alternate I (Apr 2003) of 52.247-64. (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (Contracting Officer check as appropriate.) _____ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). __X___ (2) 52.222-41, Service Contract Labor Standards (MAY 2014) (41 U.S.C. chapter 67). __X___ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (MAY 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). __X___ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (Multiple Year and Option Contracts) (MAY 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). _____ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (MAY 2014) (29 U.S.C 206 and 41 U.S.C. chapter 67). _____ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (MAY 2014) (41 U.S.C. chapter 67). _____ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (MAY 2014) (41 U.S.C. chapter 67). _____(8) 52.222-55, Minimum Wages Under Executive Order 13658 (DEC 2015) (E.O. 13658). _____(9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706). _____ (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (MAY 2014) (42 U.S.C. 1792). _____ (11) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) (31 U.S.C. 5112(p)(1)). (d) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), and (c) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1)in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (i) 52.203-13, Contractor Code of Business Ethics and Conduct (APR 2010) (Pub. L. 110-252, Title VI, Chapter 1 (41 U.S.C. 251 note). (ii) 52.219-8, Utilization of Small Business Concerns (Jul 2013) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $650,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (iii) Reserved. (iv) 52.222-26, Equal Opportunity (MAR 2007) (E.O. 11246). (v) 52.222-35, Equal Opportunity for Veterans (SEP 2010) (38 U.S.C. 4212). (vi) 52.222-36, Affirmative Action for Workers with Disabilities (OCT 1998) (29 U.S.C. 793). (vii) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (viii) 52.222-41, Service Contract Act of 1965 (Nov 2007) (41 U.S.C. 351, et seq.). (ix) 52.222-50, Combating Trafficking in Persons (FEB 2009) (22 U.S.C. 7104(g)). Alternate I (AUG 2007) of 52.222-50 (22 U.S.C. 7104(g)). (x) 52.222-51, Exemption from Application of the Service Contract Act to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (Nov 2007) (41 U.S.C. 351, et seq.). (xi) 52.222-53, Exemption from Application of the Service Contract Act to Contracts for Certain Services--Requirements (FEB 2009) (41 U.S.C. 351, et seq.). (xii) 52.222-54, Employment Eligibility Verification (JUL 2012). (xiii) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). (xiv) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (MAR 2009) (Pub. L. 110-247). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6. (xv) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (FEB 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. (2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations. (End of clause) ELECTRONIC PROPOSALS (a) Definition. Electronic proposal, as used in this provision, means a proposal, revision or modification of a proposal, or withdrawal of a proposal that is transmitted to and received by the Government via email or other means for transmitting electronic data. No flash drives will be accepted. (b) Offerors must submit electronic proposals in responses to this solicitation in order to be considered for award. Electronic proposals are subject to the same rules as paper proposals. (c) The email address to receive email proposals is jesse.lugo@usace.army.mil (d) The physical address for submitting proposals via CD or other means for transmitting electronic data, except for flash drives, is 701 San Marco Blvd., Jacksonville, FL 32207. (e) If the Federal Business Opportunities (FBO) posting indicates, the offeror may submit an electronic proposal on the Army Single Face to Industry (ASFI) site. (f) If any portion of proposal received by the Contracting Officer is unreadable to the degree that conformance to the essential requirements of the solicitation cannot be ascertained from the document -- (1) The Contracting Officer shall immediately notify the offeror and permit the offeror to resubmit the proposal if the proposal has been received prior to due date indicated in the solicitation; (2) The method and time for resubmission shall by prescribed by the Contracting Officer after consultation with the offeror. (g) The Government reserves the right to make award solely on the electronic proposal. However, if requested to do so by the Contracting Officer, the apparently successful offeror shall submit the complete original signed proposal. (End of paragraph 999.213-4001) 52.204-16 COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING (JUL 2016) (a) Definition. As used in this provision-- Commercial and Government Entity (CAGE) code means- (1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity; or (2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code. (b) The Offeror shall enter its CAGE code in its offer with its name and address or otherwise include it prominently in its proposal. The CAGE code entered must be for that name and address. Enter ``CAGE'' before the number. The CAGE code is required prior to award. (c) CAGE codes may be obtained via-- (1) Registration in the System for Award Management (SAM) at www.sam.gov. If the Offeror is located in the United States or its outlying areas and does not already have a CAGE code assigned, the DLA Commercial and Government Entity (CAGE) Branch will assign a CAGE code as a part of the SAM registration process. SAM registrants located outside the United States and its outlying areas shall obtain a NCAGE code prior to registration in SAM (see paragraph (c)(3) of this provision). (2) The DLA Commercial and Government Entity (CAGE) Branch. If registration in SAM is not required for the subject procurement, and the offeror does not otherwise register in SAM, an offeror located in the United States or its outlying areas may request that a CAGE code be assigned by submitting a request at https://cage.dla.mil. (3) The appropriate country codification bureau. Entities located outside the United States and its outlying areas may obtain an NCAGE code by contacting the Codification Bureau in the foreign entity's country if that country is a member of NATO or a sponsored nation. NCAGE codes may be obtained from the NSPA at https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx if the foreign entity's country is not a member of NATO or a sponsored nation. Points of contact for codification bureaus, as well as additional information on obtaining NCAGE codes, are available at http://www.nato.int/structur/AC/135/main/links/contacts.htm. (d) Additional guidance for establishing and maintaining CAGE codes is available at https://cage.dla.mil. (e) When a CAGE Code is required for the immediate owner and/or the highest-level owner by 52.204-17 or 52.212-3(p), the Offeror shall obtain the respective CAGE Code from that entity to supply the CAGE Code to the Government. (f) Do not delay submission of the offer pending receipt of a CAGE code. (End of Provision) 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013) (a) Definitions. As used in this provision-- Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables. Federal contracts and grants with total value greater than $10,000,000 means-- (1) The total value of all current, active contracts and grants, including all priced options; and (2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules). Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions). (b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000. (c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information: (1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions: (i) In a criminal proceeding, a conviction. (ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more. (iii) In an administrative proceeding, a finding of fault and liability that results in-- (A) The payment of a monetary fine or penalty of $5,000 or more; or (B) The payment of a reimbursement, restitution, or damages in excess of $100,000. (iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision. (2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence. (d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7). (End of provision) 252.203-7005 REPRESENTATION RELATING TO COMPENSATION OF FORMER DOD OFFICIALS (NOV 2011) (a) Definition. Covered DoD official is defined in the clause at 252.203-7000, Requirements Relating to Compensation of Former DoD Officials. (b) By submission of this offer, the offeror represents, to the best of its knowledge and belief, that all covered DoD officials employed by or otherwise receiving compensation from the offeror, and who are expected to undertake activities on behalf of the offeror for any resulting contract, are presently in compliance with all post-employment restrictions covered by 18 U.S.C. 207, 41 U.S.C. 2101-2107, and 5 CFR parts 2637 and 2641, including Federal Acquisition Regulation 3.104-2. (End of provision) 52.212-1 INSTRUCTIONS TO OFFERORS--COMMERCIAL ITEMS (JAN 2017) (a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code and small business size standard for this acquisition appear in Block 10 of the solicitation cover sheet (SF 1449). However, the small business size standard for a concern which submits an offer in its own name, but which proposes to furnish an item which it did not itself manufacture, is 500 employees. (b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show-- (1) The solicitation number; (2) The time specified in the solicitation for receipt of offers; (3) The name, address, and telephone number of the offeror; (4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary; (5) Terms of any express warranty; (6) Price and any discount terms; (7) "Remit to" address, if different than mailing address; (8) A completed copy of the representations and certifications at FAR 52.212-3 (see FAR 52.212-3(b) for those representations and certifications that the offeror shall complete electronically); (9) Acknowledgment of Solicitation Amendments; (10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and (11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration. (c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 30 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation. (d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender's request and expense, unless they are destroyed during preaward testing. (e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions, including alternative line items (provided that the alternative line items are consistent with subpart 4.10 of the Federal Acquisition Regulation), or alternative commercial items for satisfying the requirements of this solicitation. Each offer submitted will be evaluated separately. (f) Late submissions, modifications, revisions, and withdrawals of offers: (1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due. (2)(i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is "late" and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and-- (A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of offers; or (B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or (C) If this solicitation is a request for proposals, it was the only proposal received. (ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted. (3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel. (4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume. (5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers. Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer. (g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror's initial offer should contain the offeror's best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received. (h) Multiple awards. The Government may accept any item or group of items of an offer, unless the offeror qualifies the offer by specific limitations. Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specifies otherwise in the offer. (i) Availability of requirements documents cited in the solicitation. (1)(i) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to--GSA Federal Supply Service Specifications Section, Suite 8100, 470 East L'Enfant Plaza, SW, Washington, DC 20407, Telephone (202) 619-8925, Facsimile (202) 619-8978. (ii) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (i)(1)(i) of this provision. Additional copies will be issued for a fee. (2) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites: (i) ASSIST (https://assist.dla.mil/online/start/). (ii) Quick Search (http://quicksearch.dla.mil/). (iii) ASSISTdocs.com (http://assistdocs.com). (3) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by-- (i) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm); (ii) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or (iii) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone (215) 697-2667/2179, Facsimile (215) 697-1462. (4) Nongovernment (voluntary) standards must be obtained from the organization responsible for their preparation, publication, or maintenance. (j) Unique entity identifier. (Applies to all offers exceeding $3,500, and offers of $3,500 or less if the solicitation requires the Contractor to be registered in the System for Award Management (SAM) database.) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation ``Unique Entity Identifier'' followed by the unique entity identifier that identifies the Offeror's name and address. The Offeror also shall enter its Electronic Funds Transfer (EFT) indicator, if applicable. The EFT indicator is a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the Offeror to establish additional SAM records for identifying alternative EFT accounts (see subpart 32.11) for the same entity. If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for unique entity identifier establishment directly to obtain one. The Offeror should indicate that it is an offeror for a Government contract when contacting the entity designated at www.sam.gov for establishing the unique entity identifier. (k) System for Award Management. Unless exempted by an addendum to this solicitation, by submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance and through final payment of any contract resulting from this solicitation. If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror. Offerors may obtain information on registration and annual confirmation requirements via the SAM database accessed through https://www.acquisition.gov. (l) Debriefing. If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable: (1) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer. (2) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror. (3) The overall ranking of all offerors, when any ranking was developed by the agency during source selection. (4) A summary of the rationale for award; (5) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror. (6) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency. (End of provision) ADDENDUM TO 52.212-1 ADDENDUM TO FAR 52.212-1 INSTRUCTIONS TO OFFERORS-(OCTOBER 2000) Any questions regarding this solicitation should be submitted via email to jesse.lugo@usace.army.mil not later than 3 April 2017. I. PROPOSAL PREPARATION INSTRUCTIONS 1. These instructions prescribe the format of the proposal and describe the approach for the development and presentation of proposal data. These instructions are designed to ensure the submission of all necessary information. Offeror's shall submit an electronic copy of their proposal, but see FAR clause 52.212-1(f)(2)(i) above regarding the timeliness of electronic proposals. Please e-mail your proposal to jesse.lugo@usace.army.mil. a. To aid in the evaluation process, proposals shall be complete, comprehensive, and clearly presented, as detailed in "Instructions to Offerors" section of this solicitation. Proposals shall be neat, indexed, and assembled in an orderly manor. All pages of each part shall be appropriately numbered and identified with the Request for Proposal (RFP) number. Include only information that is relevant to this source selection. A complete proposal shall consist of the following three (3) sections. b. Section I - Include the signed SF 1449 with a copy of your total proposed price from the RFP and an indication that your current Representations and Certifications are on line in SAM. If not, include the Representations and Certifications from RFP Provision 52.212-3 in this Section. Also, if there are any amendments issued to the RFP, your signed acknowledgments (SF 30s) shall be provided in this section as well. c. Section II - your Technical Proposal. SECTION II - TECHNICAL PROPOSAL: (a) Technical capability: The offeror shall submit documentation addressing technical capabilities in accordance with qualification requirements contained in PWS Part 5. d. Section III - your Past Performance information. (see collection sheet form below) SECTION III - PAST PERFORMANCE: (a) Each quotation shall provide current and relevant information regarding offerors actions under previously awarded contracts. Offerors shall identify past contracts (including Federal, State, and local government, as well as private) for efforts similar to the Government requirement as stated in this RFP. Offerors must provide information on 2 contracts performed in the past 3 years. NOTE: USACE REQUESTS THAT THE CLIENT COMPLETES THIS QUESTIONNAIRE AND SUBMITS DIRECTLY BACK TO THE OFFEROR. THE OFFEROR WILL SUBMIT THE COMPLETED QUESTIONNAIRE TO USACE WITH THEIR PROPOSAL, AND MAY DUPLICATE THIS QUESTIONNAIRE FOR FUTURE SUBMISSION ON USACE SOLICITATIONS. CLIENTS ARE HIGHLY ENCOURAGED TO SUBMIT QUESTIONNAIRES DIRECTLY TO THE OFFEROR. HOWEVER, QUESTIONNAIRES MAY BE SUBMITTED DIRECTLY TO USACE. PLEASE CONTACT THE OFFEROR FOR USACE POC INFORMATION. THE GOVERNMENT RESERVES THE RIGHT TO VERIFY ANY AND ALL INFORMATION ON THIS FORM. USACE PAST PERFORMANCE QUESTIONNAIRE (Form PPQ-0) CONTRACT INFORMATION (Contractor to complete Blocks 1-4) 1. Contractor Information Firm Name: CAGE Code: Address: DUNs Number: Phone Number: Email Address: Point of Contact: Contact Phone Number: 2. Work Performed as: 0 Prime Contractor 0 Sub Contractor 0 Joint Venture 0 Other (Explain) Percent of project work performed: If subcontractor, who was the prime (Name/Phone #): 3. Contract Information Contract Number: Delivery/Task Order Number (if applicable): Contract Type: 0 Firm Fixed Price 0 Cost Reimbursement 0 Other (Please specify): Contract Title: Contract Location: Award Date (mm/dd/yy): Contract Completion Date (mm/dd/yy): Actual Completion Date (mm/dd/yy): Explain Differences: Original Contract Price (Award Amount): Final Contract Price (to include all modifications, if applicable): Explain Differences: 4. Project Description: Complexity of Work 0 High 0 Med 0 Routine How is this project relevant to project of submission? (Please provide details such as similar equipment, requirements, conditions, etc.) CLIENT INFORMATION (Client to complete Blocks 5-8) 5. Client Information Name: Title: Phone Number: Email Address: 6. Describe the client's role in the project: 7. Date Questionnaire was completed (mm/dd/yy): 8. Client's Signature: CLAUSES INCORPORATED BY FULL TEXT 52.212-2 EVALUATION--COMMERCIAL ITEMS (OCT 2014) See ADDENDUM 52.212-2 Evaluation below. (End of provision) ADDENDUM TO 52.212-2 ADDENDUM TO FAR 52.212-2 EVALUATION COMMERCIAL ITEMS (JANUARY 1999) (a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers: 1. This acquisition will utilize FAR Part 12 and 13, in which the Government seeks to award to an offeror who provides the greatest confidence that they will meet the Government's requirements affordably. Blanket Purchase Agreement award will be made on the basis of price reasonableness and proposals meeting or exceeding the acceptability standard for non-cost factors. Each proposal will be evaluated for all factors listed below. a. Proposals that are unrealistic in terms of technical or price may be rejected at any time during the evaluation process. Offerors are cautioned to follow the detailed instructions fully and carefully, as the Government reserves the right to make an award based on initial offers received, without discussion of such offers. 2. Technical Proposal: The offeror's proposal shall include documentation demonstrating their technical capabilities in accordance with the qualification requirements in Part 5 (Technical - Qualifications) of the PWS. Evaluator(s) shall assign a rating which falls within one of the following ranges according to the degree to which the offeror meets the minimum requirements described above: (1) Acceptable-Meets evaluation criteria and minimum requirements. Proposal is acceptable. Minor clarifications/corrections can be readily made. (2) Unacceptable-Fails to meet minimum requirements. Deficiencies are significant and require major revisions to proposal to make it acceptable. If determined to be unacceptable, this will render the entire proposal as technically unacceptable and eliminate the offeror from further consideration. 3. Past Performance Evaluation: Using information provided in your proposal, the contracting officer will review performance information for only those offerors rated technically acceptable. a. The offeror must submit the required reference information in the form of a PAST PERFORMANCE INFORMATION COLLECTION SHEET as provided in the Proposal Preparation Instructions. The Government will evaluate the offeror's previous performance in the following areas: Adherence to progress schedules; technical experience of key personnel and administrative experience of management; quality of the deliverable products; timely submission of submittal data; timely resolution of any problem areas; and ability to meet the contract performance schedule. The Government may evaluate information on problems identified and encountered on previous contracts and corrective actions taken by the offeror. In the case of an offeror without a record of relevant past performance or for whom information on past performance is not available, the offeror will not be evaluated favorably or unfavorably on past performance. b. The Government will conduct a performance confidence assessment rating, based upon past performance of the offerors as it relates to the probability of successfully performing the solicitation requirements. The rating may be determined initially or as a result of discussions. The ratings are defined as: (1) Acceptable-Meets evaluation criteria and minimum requirements. Proposal is acceptable. Minor clarifications/corrections can be readily made. (2) Unacceptable-Fails to meet minimum requirements. Deficiencies are significant and require major revisions to proposal to make it acceptable. If determined to be unacceptable, this will render the entire proposal as technically unacceptable and eliminate the offeror from further consideration. 4. Price/Cost Evaluation: Each offeror's price will be evaluated for completeness and reasonableness. Unrealistically low proposed costs/prices may be grounds for eliminating a proposal from competition either on the basis that the offeror does not understand the requirement or the offeror has made an unrealistic proposal. Technical and past performance, when combined, are approximately equal to cost or price. (End of provision) CLAUSES INCORPORATED BY FULL TEXT 52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (JAN 2017) The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision. (a) Definitions. As used in this provision -- "Administrative merits determination" means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. "Arbitral award or decision" means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. "Civil judgment" means- (1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction. (2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. "DOL Guidance" means the Department of Labor (DOL) Guidance entitled: ``Guidance for Executive Order 13673, `Fair Pay and Safe Workplaces' ''. The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces. "Economically disadvantaged women-owned small business (EDWOSB) Concern" means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program. "Enforcement agency" means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are-- (1) Department of Labor Wage and Hour Division (WHD) for-- (i) The Fair Labor Standards Act; (ii) The Migrant and Seasonal Agricultural Worker Protection Act; (iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act; (iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act; (v) The Family and Medical Leave Act; and (vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors); (2) Department of Labor Occupational Safety and Health Administration (OSHA) for-- (i) The Occupational Safety and Health Act of 1970; and (ii) OSHA-approved State Plans; (3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for-- (i) Section 503 of the Rehabilitation Act of 1973; (ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and (iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity); (4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and (5) Equal Employment Opportunity Commission (EEOC) for-- (i) Title VII of the Civil Rights Act of 1964; (ii) The Americans with Disabilities Act of 1990; (iii) The Age Discrimination in Employment Act of 1967; and (iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act). "Forced or indentured child labor" means all work or service- (1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or (2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties. "Highest-level owner" means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner. "Immediate owner" means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees. "Inverted domestic corporation" means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c). "Labor compliance agreement" means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters. "Labor laws" means the following labor laws and E.O.s: (1) The Fair Labor Standards Act. (2) The Occupational Safety and Health Act (OSHA) of 1970. (3) The Migrant and Seasonal Agricultural Worker Protection Act. (4) The National Labor Relations Act. (5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act. (6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act. (7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity). (8) Section 503 of the Rehabilitation Act of 1973. (9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974. (10) The Family and Medical Leave Act. (11) Title VII of the Civil Rights Act of 1964. (12) The Americans with Disabilities Act of 1990. (13) The Age Discrimination in Employment Act of 1967. (14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors). (15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html). "Labor law decision" means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of ``labor laws''. "Manufactured end product" means any end product in product and service codes (PSCs) 1000-9999, except-- (1) PSC 5510, Lumber and Related Basic Wood Materials; (2) Product or Service Group (PSG) 87, Agricultural Supplies; (3) PSG 88, Live Animals; (4) PSG 89, Subsistence; (5) PSC 9410, Crude Grades of Plant Materials; (6) PSC 9430, Miscellaneous Crude Animal Products, Inedible; (7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products; (8) PSC 9610, Ores; (9) PSC 9620, Minerals, Natural and Synthetic; and (10) PSC 9630, Additive Metal Materials. "Place of manufacture" means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture. "Predecessor" means an entity that is replaced by a successor and includes any predecessors of the predecessor. "Restricted business operations" means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate-- (1) Are conducted under contract directly and exclusively with the regional government of southern Sudan; (2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization; (3) Consist of providing goods or services to marginalized populations of Sudan; (4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization; (5) Consist of providing goods or services that are used only to promote health or education; or (6) Have been voluntarily suspended. Sensitive technology-- (1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically-- (i) To restrict the free flow of unbiased information in Iran; or (ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and (2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)). Service-disabled veteran-owned small business concern-- (1) Means a small business concern-- (i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and (ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran. (2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16). "Small business concern" means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation. "Small disadvantaged business concern", consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that-- (1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by-- (i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and (ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and (2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition. "Subsidiary" means an entity in which more than 50 percent of the entity is owned-- (1) Directly by a parent corporation; or (2) Through another subsidiary of a parent corporation. "Successor" means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term "successor" does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances. "Veteran-owned small business concern" means a small business concern-- (1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and (2) The management and daily business operations of which are controlled by one or more veterans. "Women-owned business concern" means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and whose management and daily business operations are controlled by one or more women. "Women-owned small business concern" means a small business concern-- (1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; or (2) Whose management and daily business operations are controlled by one or more women. "Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127)", means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States. Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: ``Administrative merits determination'', ``Arbitral award or decision'', paragraph (2) of ``Civil judgment'', ``DOL Guidance'', ``Enforcement agency'', ``Labor compliance agreement'', ``Labor laws'', and ``Labor law decision''. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. (b) (1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted electronically on the SAM website. (2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications--Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ___. [Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any.) These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on ORCA.] (c) Offerors must complete the following representations when the resulting contract will be performed in the United States or its outlying areas. Check all that apply. (1) Small business concern. The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a small business concern. (2) Veteran-owned small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a veteran-owned small business concern. (3) Service-disabled veteran-owned small business concern. (Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.) The offeror represents as part of its offer that it ( ___ ) is, ( ___ ) is not a service-disabled veteran-owned small business concern. (4) Small disadvantaged business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents that it ( ___ ) is, ( ___ ) is not a small disadvantaged business concern as defined in 13 CFR 124.1002. (5) Women-owned small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents that it ( ___ ) is, ( ___ ) is not a women-owned small business concern. Note to paragraphs (c)(8) and (9): Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold. (6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that-- (i) It [ ___ ] is, [ ___ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and (ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ___.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation. (7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that-- (i) It [ ___ ] is, [ ___ ] is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and (ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: ___ -.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation. (8) Women-owned business concern (other than small business concern). (Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents that it ( ___ ) is, a women-owned business concern. (9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price: ___ (10) HUBZone small business concern. (Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.) The offeror represents, as part of its offer, that-- (i) It [ ___ ] is, [ ___ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and (ii) It [ ___ ] is, [ ___ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: ___.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation. (d) Certifications and representations required to implement provisions of Executive Order 11246-- (1) Previous Contracts and Compliance. The offeror represents that-- (i) It ( ___ ) has, ( ___ ) has not, participated in a previous contract or subcontract subject either to the Equal Opportunity clause of this solicitation, the and (ii) It ( ___ ) has, ( ___ ) has not, filed all required compliance reports. (2) Affirmative Action Compliance. The offeror represents that-- (i) It ( ___ ) has developed and has on file, ( ___ ) has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 CFR Subparts 60-1 and 60-2), or (ii) It ( ___ ) has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor. (e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made. (f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American --Supplies, is included in this solicitation.) (1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of "domestic end product." The terms "commercially available off-the-shelf (COTS) item," "component," "domestic end product," "end product," "foreign end product," and "United States" are defined in the clause of this solicitation entitled "Buy American--Supplies." (2) Foreign End Products: Line Item No. Country of Origin ___ ___ ___ ___ ___ ___ (List as necessary) (3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. (g)(1) Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act, is included in this solicitation.) (i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms ``Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product,'' ``commercially available off-the-shelf (COTS) item,'' ``component,'' ``domestic end product,'' ``end product,'' ``foreign end product,'' ``Free Trade Agreement country,'' ``Free Trade Agreement country end product,'' ``Israeli end product,'' and ``United States'' are defined in the clause of this solicitation entitled ``Buy American--Free Trade Agreements--Israeli Trade Act.'' (ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled ``Buy American--Free Trade Agreements--Israeli Trade Act'': Free Trade Agreement Country End Products (Other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products: Line Item No. Country of Origin ___ ___ ___ ___ ___ ___ [List as necessary] (iii) The offeror shall list those supplies that are foreign end products (other than those listed in paragraph (g)(1)(ii) of this provision) as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act." The offeror shall list as other foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of "domestic end product." Other Foreign End Products: Line Item No. Country of Origin ___ ___ ___ ___ ___ ___ [List as necessary] (iv) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. (2) Buy American Act-Free Trade Agreements-Israeli Trade Act Certificate, Alternate I (Jan 2004). If Alternate I to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Canadian end products as defined in the clause of this solicitation entitled "Buy American -Free Trade Agreements-Israeli Trade Act": Canadian End Products: Line Item No. ___ ___ ___ [List as necessary] (3) Buy American-Free Trade Agreements-Israeli Trade Act Certificate, Alternate II (Jan 2004). If Alternate II to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Canadian end products or Israeli end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act": Canadian or Israeli End Products: Line Item No. Country of Origin ___ ___ ___ ___ ___ ___ [List as necessary] (4) Buy American--Free Trade Agreements--Israeli Trade Act Certificate, Alternate III. If Alternate III to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled ``Buy American --Free Trade Agreements--Israeli Trade Act'': Free Trade Agreement Country End Products (Other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products: Line Item No. Country of Origin ___ ___ ___ ___ ___ ___ [List as necessary] (5) Trade Agreements Certificate. (Applies only if the clause at FAR 52.225-5, Trade Agreements, is included in this solicitation.) (i) The offeror certifies that each end product, except those listed in paragraph (g)(5)(ii) of this provision, is a U.S.-made or designated country end product, as defined in the clause of this solicitation entitled ``Trade Agreements''. (ii) The offeror shall list as other end products those end products that are not U.S.-made or designated country end products. Other End Products: Line Item No. Country of Origin ___ ___ ___ ___ ___ ___ [List as necessary] (iii) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. For line items covered by the WTO GPA, the Government will evaluate offers of U.S.-made or designated country end products without regard to the restrictions of the Buy American statute. The Government will consider for award only offers of U.S.-made or designated country end products unless the Contracting Officer determines that there are no offers for such products or that the offers for such products are insufficient to fulfill the requirements of the solicitation. (h) Certification Regarding Responsibility Matters (Executive Order 12689). (Applies only if the contract value is expected to exceed the simplified acquisition threshold.) The offeror certifies, to the best of its knowledge and belief, that the offeror and/or any of its principals-- (1) [ ___ ] Are, [ ___ ] are not presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency; (2) [ ___ ] Have, [ ___ ] have not, within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a Federal, state or local government contract or subcontract; violation of Federal or state antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property; and (3) [ ___ ] Are, [ ___ ] are not presently indicted for, or otherwise criminally or civilly charged by a Government entity with, commission of any of these offenses enumerated in paragraph (h)(2) of this clause; and (4) [ ___ ] Have, [ ___ ] have not, within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied. (i) Taxes are considered delinquent if both of the following criteria apply: (A) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted. (B) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded. (ii) Examples. (A) The taxpayer has received a statutory notice of deficiency, under I.R.C. §6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appear rights. (B) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. §6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals Contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights. (C) The taxpayer has entered into an installment agreement pursuant to I.R.C. §6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment. (D) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. §362 (the Bankruptcy Code). (i) Certification Regarding Knowledge of Child Labor for Listed End Products (Executive Order 13126). [The Contracting Officer must list in paragraph (i)(1) any end products being acquired under this solicitation that are included in the List of Products Requiring Contractor Certification as to Forced or Indentured Child Labor, unless excluded at 22.1503(b).] (1) Listed end products. Listed End Product Listed Countriesof Origin ___ ___ ___ ___ ___ ___ (2) Certification. [If the Contracting Officer has identified end products and countries of origin in paragraph (i)(1) of this provision, then the offeror must certify to either (i)(2)(i) or (i)(2)(ii) by checking the appropriate block.] [ ___ ] (i) The offeror will not supply any end product listed in paragraph (i)(1) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product. [ ___ ] (ii) The offeror may supply an end product listed in paragraph (i)(1) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product. The offeror certifies that it has made a good faith effort to determine whether forced or indentured child labor was used to mine, produce, or manufacture any such end product furnished under this contract. On the basis of those efforts, the offeror certifies that it is not aware of any such use of child labor. (j) Place of manufacture. (Does not apply unless the solicitation is predominantly for the acquisition of manufactured end products.) For statistical purposes only, the offeror shall indicate whether the place of manufacture of the end products it expects to provide in response to this solicitation is predominantly- (1) ( ___ ) In the United States (Check this box if the total anticipated price of offered end products manufactured in the United States exceeds the total anticipated price of offered end products manufactured outside the United States); or (2) ( ___ ) Outside the United States. (j) Place of manufacture. (Does not apply unless the solicitation is predominantly for the acquisition of manufactured end products.) For statistical purposes only, the offeror shall indicate whether the place of manufacture of the end products it expects to provide in response to this solicitation is predominantly-- (1) ( ___ ) In the United States (Check this box if the total anticipated price of offered end products manufactured in the United States exceeds the total anticipated price of offered end products manufactured outside the United States); or (2) ( ___ ) Outside the United States. (k) Certificates regarding exemptions from the application of the Service Contract Labor Standards. (Certification by the offeror as to its compliance with respect to the contract also constitutes its certification as to compliance by its subcontractor if it subcontracts out the exempt services.) [The contracting officer is to check a box to indicate if paragraph (k)(1) or (k)(2) applies.] [ ___ ] (1) Maintenance, calibration, or repair of certain equipment as described in FAR 22.1003-4(c)(1). The offeror ( ___ ) does ( ___ ) does not certify that- (i) The items of equipment to be serviced under this contract are used regularly for other than Governmental purposes and are sold or traded by the offeror (or subcontractor in the case of an exempt subcontract) in substantial quantities to the general public in the course of normal business operations; (ii) The services will be furnished at prices which are, or are based on, established catalog or market prices (see FAR 22.1003-4(c)(2)(ii)) for the maintenance, calibration, or repair of such equipment; and (iii) The compensation (wage and fringe benefits) plan for all service employees performing work under the contract will be the same as that used for these employees and equivalent employees servicing the same equipment of commercial customers. [ ___ ] (2) Certain services as described in FAR 22.1003-4(d)(1). The offeror ( ___ ) does ( ___ ) does not certify that- (i) The services under the contract are offered and sold regularly to non-Governmental customers, and are provided by the offeror (or subcontractor in the case of an exempt subcontract) to the general public in substantial quantities in the course of normal business operations; (ii) The contract services will be furnished at prices that are, or are based on, established catalog or market prices (see FAR 22.1003-4(d)(2)(iii)); (iii) Each service employee who will perform the services under the contract will spend only a small portion of his or her time (a monthly average of less than 20 percent of the available hours on an annualized basis, or less than 20 percent of available hours during the contract period if the contract period is less than a month) servicing the Government contract; and (iv) The compensation (wage and fringe benefits) plan for all service employees performing work under the contract is the same as that used for these employees and equivalent employees servicing commercial customers. (3) If paragraph (k)(1) or (k)(2) of this clause applies- (i) If the offeror does not certify to the conditions in paragraph (k)(1) or (k)(2) and the Contracting Officer did not attach a Service Contract Labor Standards wage determination to the solicitation, the offeror shall notify the Contracting Officer as soon as possible; and (ii) The Contracting Officer may not make an award to the offeror if the offeror fails to execute the certification in paragraph (k)(1) or (k)(2) of this clause or to contact the Contracting Officer as required in paragraph (k)(3)(i) of this clause. (l) Taxpayer Identification Number (TIN) (26 U.S.C. 6109, 31 U.S.C. 7701). (Not applicable if the offeror is required to provide this information to the SAM database to be eligible for award.) (1) All offerors must submit the information required in paragraphs (l)(3) through (l)(5) of this provision to comply with debt collection requirements of 31 U.S.C. 7701(c) and 3325(d), reporting requirements of 26 U.S.C. 6041, 6041A, and 6050M, and implementing regulations issued by the Internal Revenue Service (IRS). (2) The TIN may be used by the Government to collect and report on any delinquent amounts arising out of the offeror's relationship with the Government (31 U.S.C. 7701(c)(3)). If the resulting contract is subject to the payment reporting requirements described in FAR 4.904, the TIN provided hereunder may be matched with IRS records to verify the accuracy of the offeror's TIN. (3) Taxpayer Identification Number (TIN). ( ___ ) TIN: --------------------. ( ___ ) TIN has been applied for. ( ___ ) TIN is not required because: ( ___ ) Offeror is a nonresident alien, foreign corporation, or foreign partnership that does not have income effectively connected with the conduct of a trade or business in the United States and does not have an office or place of business or a fiscal paying agent in the United States; ( ___ ) Offeror is an agency or instrumentality of a foreign government; ( ___ ) Offeror is an agency or instrumentality of the Federal Government. (4) Type of organization. ( ___ ) Sole proprietorship; ( ___ ) Partnership; ( ___ ) Corporate entity (not tax-exempt); ( ___ ) Corporate entity (tax-exempt); ( ___ ) Government entity (Federal, State, or local); ( ___ ) Foreign government; ( ___ ) International organization per 26 CFR 1.6049-4; ( ___ ) Other ----------. (5) Common parent. ( ___ ) Offeror is not owned or controlled by a common parent; ( ___ ) Name and TIN of common parent: Name - ___. TIN - ___. (m) Restricted business operations in Sudan. By submission of its offer, the offeror certifies that the offeror does not conduct any restricted business operations in Sudan. (n) Prohibition on Contracting with Inverted Domestic Corporations- (1) Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation, unless the exception at 9.108-2(b) applies or the requirement is waived in accordance with the procedures at 9.108-4. (2) Representation. By submission of its offer, the offeror represents that-- (i) It is not an inverted domestic corporation; and (ii) It is not a subsidiary of an inverted domestic corporation. (o) Prohibition on contracting with entities engaging in certain activities or transactions relating to Iran. (1) The offeror shall email questions concerning sensitive technology to the Department of State at CISADA106@state.gov. (2) Representation. The Offeror represents that-- (i) It [ ___ ] is, [ ___ ] is not an inverted domestic corporation; and (ii) It [ ___ ] is, [ ___ ] is not a subsidiary of an inverted domestic corporation. (3) The representation and certification requirements of paragraph (o)(2) of this provision do not apply if- (i) This solicitation includes a trade agreements certification (e.g., 52.212-3(g) or a comparable agency provision); and (ii) The offeror has certified that all the offered products to be supplied are designated country end products. (p) Ownership or Control of Offeror. (Applies in all solicitations when there is a requirement to be registered in SAM or a requirement to have a unique entity identifier in the solicitation. (1) The Offeror represents that it [ ___ ] has or [ ___ ] does not have an immediate owner. If the Offeror has more than one immediate owner (such as a joint venture), then the Offeror shall respond to paragraph (2) and if applicable, paragraph (3) of this provision for each participant in the joint venture. (2) If the Offeror indicates "has" in paragraph (p)(1) of this provision, enter the following information: Immediate owner CAGE code: ___ Immediate owner legal name: ___ (Do not use a "doing business as" name) Is the immediate owner owned or controlled by another entity: [ ___ ] Yes or [ ___ ] No. (3) If the Offeror indicates "yes" in paragraph (p)(2) of this provision, indicating that the immediate owner is owned or controlled by another entity, then enter the following information: Highest level owner CAGE code: ___ Highest level owner legal name: ___ (Do not use a "doing business as" name) (q) Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. (1) As required by section 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that- (i) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless and agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or (ii) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government. (2) The Offeror represents that-- (i) It is [ ___ ] is not [ ___ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and (ii) It is [ ___ ] is not [ ___ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months. (r) Predecessor of Offeror. (Applies in all solicitations that include the provision at 52.204-16, Commercial and Government Entity Code Reporting.) (1) The Offeror represents that it [ ___ ] is or [ ___ ] is not a successor to a predecessor that held a Federal contract or grant within the last three years. (2) If the Offeror has indicated ``is'' in paragraph (r)(1) of this provision, enter the following information for all predecessors that held a Federal contract or grant within the last three years (if more than one predecessor, list in reverse chronological order): Predecessor CAGE code: ___ (or mark ``Unknown''). Predecessor legal name: ___. (Do not use a ``doing business as'' name). (s) Representation regarding compliance with labor laws (Executive Order 13673). If the offeror is a joint venture that is not itself a separate legal entity, each concern participating in the joint venture shall separately comply with the requirements of this provision. (1)(i) For solicitations issued on or after October 25, 2016 through April 24, 2017: The Offeror [ ___ ] does [ ___ ] does not anticipate submitting an offer with an estimated contract value of greater than $50 million. (ii) For solicitations issued after April 24, 2017: The Offeror [ ___ ] does [ ___ ] does not anticipate submitting an offer with an estimated contract value of greater than $500,000. (2) If the Offeror checked ``does'' in paragraph (s)(1)(i) or (ii) of this provision, the Offeror represents to the best of the Offeror's knowledge and belief [Offeror to check appropriate block]: [ ___ ](i) There has been no administrative merits determination, arbitral award or decision, or civil judgment for any labor law violation(s) rendered against the offeror (see definitions in paragraph (a) of this section) during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter; or [ ___ ](ii) There has been an administrative merits determination, arbitral award or decision, or civil judgment for any labor law violation(s) rendered against the Offeror during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter. (3)(i) If the box at paragraph (s)(2)(ii) of this provision is checked and theContracting Officer has initiated a responsibility determination and has requested additional information, the Offeror shall provide-- (A) The following information for each disclosed labor law decision in the System for Award Management (SAM) at www.sam.gov, unless the information is already current, accurate, and complete in SAM. This information will be publicly available in the Federal Awardee Performance and Integrity Information System (FAPIIS): (1) The labor law violated. (2) The case number, inspection number, charge number, docket number, or other unique identification number. (3) The date rendered. (4) The name of the court, arbitrator(s), agency, board, or commission that rendered the determination or decision; (B) The administrative merits determination, arbitral award or decision, or civil judgment document, to the Contracting Officer, if the Contracting Officer requires it; (C) In SAM, such additional information as the Offeror deems necessary to demonstrate its responsibility, including mitigating factors and remedial measures such as offeror actions taken to address the violations, labor compliance agreements, and other steps taken to achieve compliance with labor laws. Offerors may provide explanatory text and upload documents. This information will not be made public unless the contractor determines that it wants the information to be made public; and (D) The information in paragraphs (s)(3)(i)(A) and (s)(3)(i)(C) of this provision to the Contracting Officer, if the Offeror meets an exception to SAM registration (see FAR 4.1102(a)). (ii)(A) The Contracting Officer will consider all information provided under (s)(3)(i) of this provision as part of making a responsibility determination. (B) A representation that any labor law decision(s) were rendered against the Offeror will not necessarily result in withholding of an award under this solicitation. Failure of the Offeror to furnish a representation or provide such additional information as requested by the Contracting Officer may render the Offeror non-responsible. (C) The representation in paragraph (s)(2) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous representation, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation in accordance with the procedures set forth in FAR 12.403. (4) The Offeror shall provide immediate written notice to the Contracting Officer if at any time prior to contract award the Offeror learns that its representation at paragraph (s)(2) of this provision is no longer accurate. (5) The representation in paragraph (s)(2) of this provision will be public information in the Federal Awardee Performance and Integrity Information System (FAPIIS). Note to paragraph (s): By a court order issued on October 24, 2016, this paragraph (s) is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. (t) Public Disclosure of Greenhouse Gas Emissions and Reduction Goals. Applies in all solicitations that require offerors to register in SAM (52.212-1(k)). (1) This representation shall be completed if the Offeror received $7.5 million or more in contract awards in the prior Federal fiscal year. The representation is optional if the Offeror received less than $7.5 million in Federal contract awards in the prior Federal fiscal year. (2) Representation. [Offeror to check applicable block(s) in paragraph (t)(2)(i) and (ii)]. (i) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose greenhouse gas emissions, i.e., makes available on a publicly accessible Web site the results of a greenhouse gas inventory, performed in accordance with an accounting standard with publicly available and consistently applied criteria, such as the Greenhouse Gas Protocol Corporate Standard. (ii) The Offeror (itself or through its immediate owner or highest-level owner) [ ___ ] does, [ ___ ] does not publicly disclose a quantitative greenhouse gas emissions reduction goal, i.e., make available on a publicly accessible Web site a target to reduce absolute emissions or emissions intensity by a specific quantity or percentage. (iii) A publicly accessible Web site includes the Offeror's own Web site or a recognized, third-party greenhouse gas emissions reporting program. (3) If the Offeror checked ``does'' in paragraphs (t)(2)(i) or (t)(2)(ii) of this provision, respectively, the Offeror shall provide the publicly accessible Web site(s) where greenhouse gas emissions and/or reduction goals are reported: ___. (u)(1) In accordance with section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions), Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with an entity that requires employees or subcontractors of such entity seeking to report waste, fraud, or abuse to sign internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting such waste, fraud, or abuse to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information. (2) The prohibition in paragraph (u)(1) of this provision does not contravene requirements applicable to Standard Form 312 (Classified Information Nondisclosure Agreement), Form 4414 (Sensitive Compartmented Information Nondisclosure Agreement), or any other form issued by a Federal department or agency governing the nondisclosure of classified information. (3) Representation. By submission of its offer, the Offeror represents that it will not require its employees or subcontractors to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting waste, fraud, or abuse related to the performance of a Government contract to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information (e.g., agency Office of the Inspector General). (End of provision) (vi) Terms and Conditions of BPA The required commercial item clauses will be included in the BPA and apply only to orders issued under the BPA. TERMS AND CONDITIONS OF BPA. Per the Federal Acquisition Regulation (FAR) 13.303-3(a), the following terms and conditions are mandatory: 1. Description of Agreement: The supplier shall furnish all services if and when requested by the Contracting Officer (or the authorized representative of the Contracting Officer) during the specified performance period (detailed in the Delivery Information Section) and within the stipulated aggregate amount. 2. Extent of Obligation: The Government is obligated only to the extent of authorized purchases actually made under the BPA. 3. Purchase Limitation: The dollar limitation for each individual purchase order under this BPA is ONE HUNDRED AND FIFTY THOUSAND AND NO CENTS ($150,000.00). 4. Individuals Authorized to Purchase under the BPA: A list of individuals authorized to purchase under this BPA, identified either by title of position, by name of individual or organizational component, will be furnished to the supplier by the contracting officer. 5. It will be required that all BPA holders provide a Liability Insurance Certificate of $1 million 6. The McNamara-O'Hara Service Contract Act (SCA) applies to the BPA and all BPA Calls (iii) Defense Priorities and Allocations System (DPAS) and assigned rating. Not applicable (iv) The due date for the receipt of offers is April 7, 2017 by 12:00PM EST. The due date for the receipt of questions in regards to this RFQ is seven (7) calendar days prior to the due date listed for receipt of offers. The Government reserves the right to cancel this combined synopsis/solicitation at any time. Any questions can be addressed to Jesse Lugo at 904-232-1051, but note, all questions must be put in writing and sent to the email listed. (v) Offers may be submitted electronically to jesse.lugo@usace.army.mil. Adobe (.pdf) are acceptable formats for submitting offers. The electronic file must be under 8MB total to ensure it can be received by e-mail. Offers may also be mailed to the attention of Jesse Lugo at the address listed on this solicitation. If you are having any issues submitting your offer, please contact Jesse Lugo as soon as possible.
Web Link: FBO.gov Permalink
(https://www.fbo.gov/spg/USA/COE/DACA17/W912EP-17-T-0002/listing.html)
Place of Performance: Address: Across the state of Florida, Jacksonville, Florida, 32207, United States; Zip Code: 32207
Record: SN04446812-W 20170326/170324234333-a2cadbecf8ce7a74ba08d4eaae735ee9 (fbodaily.com)
Source: FedBizOpps Link to This Notice
(may not be valid after Archive Date)

| FSG Index | This Issue's Index | Today's FBO Daily Index Page |

Loren Data's SAM Daily™

J -- Repair Hydorgraphic Survey Equipment - Price Schedule