SPECIAL NOTICE
65 -- Special Notice
- Notice Date
- 4/11/2017
- Notice Type
- Special Notice
- NAICS
- 339112
— Surgical and Medical Instrument Manufacturing
- Contracting Office
- Department of the Navy, Bureau of Medicine and Surgery, Naval Medical Center Portsmouth, 54 Lewis Minor St, Portsmouth, Virginia, 23708-2297, United States
- ZIP Code
- 23708-2297
- Solicitation Number
- N0018317Q0079
- Archive Date
- 5/1/2017
- Point of Contact
- Harold D Woodley, Phone: 757-953-7276, Curtis Price, Jr., Phone: 757-953-7570
- E-Mail Address
-
harold.d.woodley.civ@mail.mil, curtis.c.price2.civ@mail.mil
(harold.d.woodley.civ@mail.mil, curtis.c.price2.civ@mail.mil)
- Small Business Set-Aside
- N/A
- Description
- Section A - Solicitation/Contract Form CONTRACTOR INFORMATION TIN: CAGE: DUNS: Vendor Point of Contact: Phone: Vendor email: Billing/Payment in Arrears. Naval Medical Center Contracting POC: Harold Woodley Phone: 757-953-7276 Fax: 757-953-5006 Email: harold.d.woodley.civ@mail.mil Product/Services for: Naval Medical Center Portsmouth, Cardio Thoracic POC: HM2 Kareem Pinto Phone: 757-953-2428 Email: kareem.o.pinto.mil@mail.mil Vendor to reference RFQ number N0018317Q0079 on all inquires. Reference: PROMPT PAYMENT For Prompt Payment Act Purposes, this contract is: Subject to the 7-calender day constructive acceptance period. AVAILABILITY OF FUNDS. Pursuant to Section I, Availability of Funds (FAR 52.232-18), of the contract, funds are not presently available for this contract. The Government's obligation under this contract is contingent upon the availability of appropriated funds from which payment for contract purposes can be made. No legal liability on the part of the Government for any payment may arise until funds are made available to the Contracting Officer for this contract and until the Contractor receives notice of such availability, to be confirmed in writing to the Contracting Officer. Section B - Supplies or Services and Prices ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT 0001 1 Months Consignment Supplies FFP for Cardio Thoracic for May 1-31, 2017. FOB: Destination MILSTRIP: N0018317RCCV104 PURCHASE REQUEST NUMBER: N0018317RCCV104 NET AMT Section C - Descriptions and Specifications CLAUSES INCORPORATED BY FULL TEXT SUP 5252.204-9400 Contractor Unclassified Access to Federally Controlled Facilities, Sensitive Information, Information Technology (IT) Systems or Protected Health Information (July 2013) Homeland Security Presidential Directive (HSPD)-12, requires government agencies to develop and implement Federal security standards for Federal employees and contractors. The Deputy Secretary of Defense Directive-Type Memorandum (DTM) 08-006 - "DoD Implementation of Homeland Security Presidential Directive - 12 (HSPD-12)" dated November 26, 2008 (or its subsequent DoD instruction) directs implementation of HSPD-12. This clause is in accordance with HSPD-12 and its implementing directives. APPLICABILITY This clause applies to contractor employees requiring physical access to any area of a federally controlled base, facility or activity and/or requiring access to a DoN or DoD computer/network/system to perform certain unclassified sensitive duties. This clause also applies to contractor employees who access Privacy Act and Protected Health Information, provide support associated with fiduciary duties, or perform duties that have been identified by DON as National Security Position, as advised by the command security manager. It is the responsibility of the responsible security officer of the command/facility where the work is performed to ensure compliance. Each contractor employee providing services at a Navy Command under this contract is required to obtain a Department of Defense Common Access Card (DoD CAC). Additionally, depending on the level of computer/network access, the contract employee will require a successful investigation as detailed below. ACCESS TO FEDERAL FACILITIES Per HSPD-12 and implementing guidance, all contractor employees working at a federally controlled base, facility or activity under this clause will require a DoD CAC. When access to a base, facility or activity is required contractor employees shall in-process with the Navy Command's Security Manager upon arrival to the Navy Command and shall out-process prior to their departure at the completion of the individual's performance under the contract. ACCESS TO DOD IT SYSTEMS In accordance with SECNAV M-5510.30, contractor employees who require access to DoN or DoD networks are categorized as IT-I, IT-II, or IT-III. The IT-II level, defined in detail in SECNAV M-5510.30, includes positions which require access to information protected under the Privacy Act, to include Protected Health Information (PHI). All contractor employees under this contract who require access to Privacy Act protected information are therefore categorized no lower than IT-II. IT Levels are determined by the requiring activity's Command Information Assurance Manager. Contractor employees requiring privileged or IT-I level access, (when specified by the terms of the contract) require a Single Scope Background Investigation (SSBI) which is a higher level investigation than the National Agency Check with Law and Credit (NACLC) described below. Due to the privileged system access, a SSBI suitable for High Risk public trusts positions is required. Individuals who have access to system control, monitoring, or administration functions (e.g. system administrator, database administrator) require training and certification to Information Assurance Technical Level 1, and must be trained and certified on the Operating System or Computing Environment they are required to maintain. Access to sensitive IT systems is contingent upon a favorably adjudicated background investigation. When access to IT systems is required for performance of the contractor employee's duties, such employees shall in-process with the Navy Command's Security Manager and Information Assurance Manager upon arrival to the Navy command and shall out-process prior to their departure at the completion of the individual's performance under the contract. Completion and approval of a System Authorization Access Request Navy (SAAR-N) form is required for all individuals accessing Navy Information Technology resources. The decision to authorize access to a government IT system/network is inherently governmental. The contractor supervisor is not authorized to sign the SAAR-Ni therefore, the government employee with knowledge of the system/network access required or the COR shall sign the SAAR-N as the "supervisor". The SAAR-N shall be forwarded to the Navy Command's Security Manager at least 30 days prior to the individual's start date. Failure to provide the required documentation at least 30 days prior to the individual's start date may result in delaying the individual's start date. When required to maintain access to required IT systems or networks, the contractor shall ensure that all employees requiring access complete annual Information Assurance (IA) training, and maintain a current requisite background investigation. The Contractor's Security Representative shall contact the Command Security Manager for guidance when reinvestigations are required. INTERIM ACCESS The Navy Command' s Security Manager may authorize issuance of a DoD CAC and interim access to a DoN or DoD unclassified computer/network upon a favorable review of the investigative questionnaire and advance favorable fingerprint results. When the results of the investigation are received and a favorable determination is not made, the contractor employee working on the contract under interim access will be denied access to the computer network and this denial will not relieve the contractor of his/her responsibility to perform. DENIAL OR TERMINATION OF ACCESS The potential consequences of any requirement under this clause including denial or termination of physical or system access in no way relieves the contractor from the requirement to execute performance under the contract within the timeframes specified in the contract. Contractors shall plan ahead in processing their employees and subcontractor employees. The contractor shall insert this clause in all subcontracts when the subcontractor is permitted to have unclassified access to a federally controlled facility, federally-controlled information system/network and/or to government information, meaning information not authorized for public release. CONTRACTOR'S SECURITY REPRESENTATIVE The contractor shall designate an employee to serve as the Contractor's Security Representative. Within three work days after contract award, the contractor shall provide to the requiring activity's Security Manager and the Contracting Officer, in writing, the name, title, address and phone number for the Contractor's Security Representative. The Contractor's Security Representative shall be the primary point of contact on any security matter. The Contractor's Security Representative shall not be replaced or removed without prior notice to the Contracting Officer and Command Security Manager. BACKGROUND INVESTIGATION REQUIREMENTS AND SECURITY APPROVAL PROCESS FOR CONTRACTORS ASSIGNED TO NATIONAL SECURITY POSITIONS OR PERFORMING SENSITIVE DUTIES Navy security policy requires that all positions be given a sensitivity value based on level of risk factors to ensure appropriate protective measures are applied. Navy recognizes contractor employees under this contract as Non-Critical Sensitive [ADP/IT-II] when the contract scope of work require physical access to a federally controlled base, facility or activity and/or requiring access to a DoD computer/network, to perform unclassified sensitive duties. This designation is also applied to contractor employees who access Privacy Act and Protected Health Information (PHI), provide support associated with fiduciary duties, or perform duties that have been identified by DON as National Security Positions. At a minimum, each contractor employee must be a US citizen and have a favorably completed NACLC to obtain a favorable determination for assignment to a non-critical sensitive or IT-II position. The NACLC consists of a standard NAC and a FBI fingerprint check plus law enforcement checks and credit check. Each contractor employee filling a non-critical sensitive or IT-II position is required to complete: * SF-86 Questionnaire for National Security Positions (or equivalent OPM investigative product) * Two FD-258 Applicant Fingerprint Cards (or an electronic fingerprint submission) * Original Signed Release Statements Failure to provide the required documentation at least 30 days prior to the individual's start date shall result in delaying the individual's start date. Background investigations shall be reinitiated as required to ensure investigations remain current (not older than 10 years) throughout the contract performance period. The Contractor's Security Representative shall contact the Command Security Manager for guidance when reinvestigations are required. Regardless of their duties or IT access requirements ALL contractor employees shall in-process with the Navy Command's Security Manager upon arrival to the Navy command and shall out-process prior to their departure at the completion of the individual's performance under the contract. Employees requiring IT access shall also check-in and check-out with the Navy Command's Information Assurance Manager. Completion and approval of a System Authorization Access Request Navy (SAAR-N) form is required for all individuals accessing Navy Information Technology resources. The SAAR-N shall be forwarded to the Navy Command's Security Manager at least 30 days prior to the individual's start date. Failure to provide the required documentation at least 30 days prior to the individual's start date shall result in delaying the individual's start date. The contractor shall ensure that each contract employee requiring access to IT systems or networks complete annual Information Assurance (IA) training, and maintain a current requisite background investigation. Contractor employees shall accurately complete the required investigative forms prior to submission to the Navy Command Security Manager. The Navy Command's Security Manager will review the submitted documentation for completeness prior to submitting it to the Office of Personnel Management (OPM). Suitability/security issues identified by the Navy may render the contractor employee ineligible for the assignment. An unfavorable determination made by the Navy is final (subject to SF-86 appeal procedures) and such a determination does not relieve the contractor from meeting any contractual obligation under the contract. The Navy Command's Security Manager will forward the required forms to OPM for processing. Once the investigation is complete, the results will be forwarded by OPM to the DON Central Adjudication Facility (CAF) for a determination. If the contractor employee already possesses a current favorably adjudicated investigation, the contractor shall submit a Visit Authorization Request (VAR) via the Joint Personnel Adjudication System (JPAS) or a hard copy VAR directly from the contractor's Security Representative. Although the contractor will take JPAS "Owning" role over the contractor employee, the Navy Command will take JPAS "Servicing" role over the contractor employee during the hiring process and for the duration of assignment under that contract. The contractor shall include the IT Position Category per SECNAV M-5510.30 for each employee designated on a VAR. The VAR requires annual renewal for the duration of the employee's performance under the contract. BACKGROUND INVESTIGATION REQUIREMENTS AND SECURITY APPROVAL PROCESS FOR CONTRACTORS ASSIGNED TO OR PERFORMING NON-SENSITIVE DUTIES Contractor employee whose work is unclassified and non-sensitive (e.g., performing certain duties such as lawn maintenance, vendor services, etc...) and who require physical access to publicly accessible areas to perform those duties shall meet the following minimum requirements: * Must be either a US citizen or a US permanent resident with a minimum of 3 years legal residency in the United States (as required by The Deputy Secretary of Defense DTM 08-006 or its subsequent DoD instruction) and * Must have a favorably completed National Agency Check with Written Inquiries (NACI) including a FBI fingerprint check prior to installation access. To be considered for a favorable trustworthiness determination, the Contractor's Security Representative must submit for all employees each of the following: * SF-85 Questionnaire for Non-Sensitive Positions * Two FD-258 Applicant Fingerprint Cards (or an electronic fingerprint submission) * Original Signed Release Statements The contractor shall ensure each individual employee has a current favorably completed National Agency Check with Written Inquiries (NACI) or ensure successful FBI fingerprint results have been gained and investigation has been processed with OPM. Failure to provide the required documentation at least 30 days prior to the individual's start date may result in delaying the individual's start date. * Consult with your Command Security Manager and Information Assurance Manager for local policy when IT-III (non-sensitive) access is required for non-US citizens outside the United States. Section E - Inspection and Acceptance INSPECTION AND ACCEPTANCE TERMS Supplies/services will be inspected/accepted at: CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY 0001 Destination Government Destination Government Section F - Deliveries or Performance DELIVERY HOURS Naval Medical Center Portsmouth (NMCP) Receiving Dock Hours of Operation: NMCP Receiving Dock is open Monday through Friday 0700 to 1600 (7:00 a.m. to 4:00 p.m.), excluding federal holidays. Receiving personnel may be reached at 757-953-5770. DELIVERY INFORMATION CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC / CAGE 0001 POP 01-MAY-2017 TO 31-MAY-2017 N/A NAVAL MEDICAL CENTER RECEIVING OFFICER 54 LEWIS MINOR STREET BLDG. 250 PORTSMOUTH VA 23708-2297 757-953-5770 FOB: Destination N00183 Section G - Contract Administration Data CLAUSES INCORPORATED BY FULL TEXT 252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JUN 2012) (a) Definitions. As used in this clause-- "Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization. "Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF). "Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system. (b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports. (c) WAWF access. To access WAWF, the Contractor shall-- (1) Have a designated electronic business point of contact in the Central Contractor Registration at https://www.acquisition.gov; and (2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site. (d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/. (e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol. (f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order: (1) Document type. The Contractor shall use the following document type(s). INVOICE AND RECEIVING REPORT COMBO ----------------------------------------------------------------------- (2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer. DESTINATION / DESTINATION ----------------------------------------------------------------------- (3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system. Routing Data Table* Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC HQ0248 Issue By DoDAAC N00183 Admin DoDAAC N00183 Inspect By DoDAAC N/A Ship To Code N00183 Ship From Code N/A Mark For Code N/A Service Approver (DoDAAC) N/A Service Acceptor (DoDAAC) N/A Accept at Other DoDAAC N/A LPO DoDAAC N00183 DCAA Auditor DoDAAC N/A Other DoDAAC(s) N/A (4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request. (5) WAWF email notifications. The Contractor shall enter the email address identified below in the "Send Additional Email Notifications" field of WAWF once a document is submitted in the system. WAWF Acceptor/COR Email Address: charles.k.lovell2.civ@mail.mil ----------------------------------------------------------------------- (g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact. usn.detrick.navmedlogcomftdmd.list.nmlc-wafwf@mail.mil ----------------------------------------------------------------------- (2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988. (End of clause) Section I - Contract Clauses CLAUSES INCORPORATED BY REFERENCE 252.203-7000 Requirements Relating to Compensation of Former DoD Officials SEP 2011 252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7005 Oral Attestation of Security Responsibilities NOV 2001 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting OCT 2016 252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support MAY 2016 252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7000 Buy American--Balance Of Payments Program Certificate--Basic (Nov 2014) NOV 2014 252.225-7048 Export-Controlled Items JUN 2013 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports JUN 2012 252.232-7010 Levies on Contract Payments DEC 2006 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.244-7000 Subcontracts for Commercial Items JUN 2013 252.247-7023 Transportation of Supplies by Sea APR 2014 CLAUSES INCORPORATED BY FULL TEXT 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): FAR Clauses http://acquisition.gov/comp/far/index.htm DFAR Clauses http://www.acq.osd.mil/dpap/dars/dfars/index.htm (End of clause) 252.203-7994 PROHIBITION ON CONTRACTING WITH ENTITIES THAT REQUIRE CERTAIN INTERNAL CONFIDENTIALITY AGREEMENTS-REPRESENTATION (DEVIATION 2017-O0001)(NOV 2016) (a) In accordance with Continuing Appropriations Act, 2017 (Pub. L. 114-223), or any other Act that extends to fiscal year 2017 funds the same prohibitions as contained in section 743, division E, title VII, of the Consolidated Appropriations Act, 2016 (Pub. L. 114-113), none of the funds appropriated (or otherwise made available) by this or any other Act may be used for a contract with an entity that requires employees or subcontractors of such entity seeking to report fraud, waste, or abuse to sign internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or contactors from lawfully reporting such waste, fraud, or abuse to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information. (b) The prohibition in paragraph (a) of this provision does not contravene requirements applicable to Standard Form 312, Form 4414, or any other form issued by a Federal department or agency governing the nondisclosure of classified information. (c) Representation. By submission of its offer, the Offeror represents that it does not require employees or subcontractors of such entity seeking to report fraud, waste, or abuse to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or contactors from lawfully reporting such waste, fraud, or abuse to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information. (End of provision) 252.203-7995 PROHIBITION ON CONTRACTING WITH ENTITIES THAT REQUIRE CERTAIN INTERNAL CONFIDENTIALITY AGREEMENTS (DEVIATION 2017-O0001)(NOV 2016) (a) The Contractor shall not require employees or subcontractors seeking to report fraud, waste, or abuse to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or contactors from lawfully reporting such waste, fraud, or abuse to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information. (b) The Contractor shall notify employees that the prohibitions and restrictions of any internal confidentiality agreements covered by this clause are no longer in effect. (c) The prohibition in paragraph (a) of this clause does not contravene requirements applicable to Standard Form 312, Form 4414, or any other form issued by a Federal department or agency governing the nondisclosure of classified information. (d)(1) Use of funds appropriated (or otherwise made available) by the Continuing Appropriations Act, 2017 (Pub. L. 114-223), or any other Act that extends to fiscal year 2017 funds the same prohibitions as contained in section 743, division E, title VII, of the Consolidated Appropriations Act, 2016 (Pub. L. 114-113) may be prohibited, if the Government determines that the Contractor is not in compliance with the provisions of this clause. (2) The Government may seek any available remedies in the event the Contractor fails to perform in accordance with the terms and conditions of the contract as a result of Government action under this clause. (End of clause)
- Web Link
-
FBO.gov Permalink
(https://www.fbo.gov/spg/DON/BUMED/N00183/N0018317Q0079/listing.html)
- Place of Performance
- Address: Naval Medical Center Portsmouth, 54 Lewis Minor Street, Building 250, Portsmouth, Virginia, 23708, United States
- Zip Code: 23708
- Zip Code: 23708
- Record
- SN04467892-W 20170413/170411234658-2a9357e1771a4400b650329a8264ebf0 (fbodaily.com)
- Source
-
FedBizOpps Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |