FBODaily.com | FedBizOpps: PRESOL | 20 | Ship Service Switchboards for USCG '87 Patrol Boats - Synopsis Docs - J&A

FBO DAILY - FEDBIZOPPS ISSUE OF AUGUST 12, 2017 FBO #5741
SOLICITATION NOTICE

20 -- Ship Service Switchboards for USCG '87 Patrol Boats - Synopsis Docs - J&A

Notice Date: 8/10/2017
Notice Type: Combined Synopsis/Solicitation
NAICS: 335313 — Switchgear and Switchboard Apparatus Manufacturing
Contracting Office: Department of Homeland Security, United States Coast Guard (USCG), USCG Surface Forces Logistics Center (SFLC), 2401 Hawkins Point Road, Building 31, Mail Stop 26, Baltimore, Maryland, 21226-5000, United States
ZIP Code: 21226-5000
Solicitation Number: HSCG40-17-Q-11003
Archive Date: 8/31/2017
Point of Contact: David A. Packard, Phone: 4107626650
E-Mail Address: David.A.Packard@uscg.mil
(David.A.Packard@uscg.mil)
Small Business Set-Aside: Woman Owned Small Business
Description: Justification for Other Than Full and Open Competition Preservation and Packing Spec Spec for Crate Schedule of Supplies Solicitation Combined Synopsis and Solicitation HSCG40-17-Q-11003 Ship Service Switchboards for the 87' Coastal Patrol Boat Class Cutters Notice for Filing Agency Protests United States Coast Guard Ombudsman Program It is the policy of the United States Coast Guard (USCG) to issue solicitations and make contract awards in a fair and timely manner. The Ombudsman Program for Agency Protests (OPAP) was established to investigate agency protest issues and resolve them without expensive and time-consuming litigation. OPAP is an independent reviewing authority that is empowered to grant a prevailing protester essentially the same relief as the Government Accountability Office (GAO). Interested parties are encouraged to seek resolution of their concerns within the USCG as an Alternative Dispute Resolution (ADR) forum rather than filing a protest with the GAO or some external forum. Interested parties may seek resolution of their concerns informally or opt to file a formal agency protest with the Contracting Officer or Ombudsman. Informal Forum with the Ombudsman. Interested parties who believe a specific USCG procurement is unfair or otherwise defective should first direct their concerns to the applicable Contracting Officer. If the Contracting Officer is unable to satisfy their concerns, interested parties are encouraged to contact the U.S. Coast Guard Ombudsman for Agency Protests. Under this informal process the agency is not required to suspend contract award performance. Use of an informal forum does not suspend any time requirement for filing a protest with the agency or other forum. In order to ensure a timely response, interested parties should provide the following information to the Ombudsman: solicitation/contract number, contracting office, Contracting Officer, and solicitation closing date (if applicable). Formal Agency Protest with the Ombudsman. Prior to submitting a formal agency protest, protesters must first use their best efforts to resolve their concerns with the Contracting Officer through open and frank discussions. If the protester's concerns are unresolved, an Independent Review is available by the Ombudsman. The protester may file a formal agency protest to either the Contracting Officer or as an alternative to that, the Ombudsman under the OPAP program. Contract award or performance will be suspended during the protest period unless contract award or performance is justified, in writing, for urgent and compelling reasons or is determined in writing to be in the best interest of the Government. The agency's goal is to resolve protests in less than 35 calendar days from the date of filing. Protests shall include the information set forth in FAR 33.103(d) (2). If the protester fails to submit the required information, resolution of the protest may be delayed or the protest may be dismissed. To be timely protests must be filed within the period specified in FAR 33.103(e). Formal protests filed under the OPAP program should be submitted electronically to OPAP@uscg.mil and the Contracting Officer or by hand delivery to the Contracting Officer. Election of Forum. After an interested party protests a Coast Guard procurement to the Contracting Officer or the Ombudsman, and while the protest is pending, the protester agrees not to file a protest with the GAO or other external forum. If the protest is filed with an external forum, the agency protest will be dismissed. The Ombudsman Hotline telephone number is (202) 372-3695. Commanding Officer USCG Surface Forces Logistics Center (CPD-C&P1-PBPL) 2401 Hawkins Point Road, Bldg. 31 LL Baltimore, MD 21226 Request for Quotes HSCG40-17-Q-11003 The U.S. Coast Guard Surface Forces Logistics Center intends on awarding a Firm-Fixed Price contract in order to purchase ten (10) new Ship Service Switchboards for the 87' Coastal Patrol Boat (WPB) Class Cutters. Powergen Controls (POWERGEN), the OEM, has proprietary software which is installed on the main switchboard and controls and proprietary licensing for the hardware to be installed in the main switchboard and controls. To assure proper form, fit and function of the switchboards, only OEM manufactured switchboards shall be used. Items submitted under this solicitation which are other than OEM switchboards will be rejected as unacceptable. It is the Government's intention to solicit and negotiate solely with a firm in the SBA, WOSB program, POWERGEN. The USCG Contracting Officer intends to make the contract award directly to the WOSB firm, pursuant to the procedures under FAR 19.1506. All responsible sources may submit a quotation which shall be considered by the agency. I. This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in FAR Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation. Quotes are being requested and a written solicitation will not be issued. This requirement will be satisfied using FAR Subpart 13.5, Simplified Procedures for Certain Commercial Items. II. The solicitation number is HSCG40-17-Q-11003. The solicitation is being issued as a request for quotation (RFQ). III. The incorporated clauses and provisions are those in effect through Federal Acquisition Circular (FAC) 2005-95. IV. The North American Industry Classification System (NAICS) Code for this contract is 335313, with a small business size standard of 1,250 employees. V. A list of the contract line item numbers (CLINS), items, quantities, and units of measure to be acquired for the contract can be found in Attachment I: Schedule of Supplies and Prices. Insert unit and total price for all CLINS listed in the Schedule. Unit prices shall include shipping costs, free on board (F.O.B.) destination and the cost of packaging, marking and bar-coding. VI. Description of the Requirement: The Contractor shall manufacture ten (10) marine electrical switchboards. The switchboard design must be strictly adhered to in all aspects of design and construction when manufactured per the following drawings: Coast Guard Drawing 87 WPB CM001079-01-SSDG-01, SSDG System Replace, Communications Coast Guard Drawing 87 WPB C001079-01-SSDG-01, SSDG System Replace, Electrical Elementaries Coast Guard Drawing 87 WPB 1001079-01-SSDG-01, SSDG System Replace, Electrical Interconnection Coast Guard Drawing 87 WPB M001079-01-SSDG-01, SSDG System Replace, Mechanical Coast Guard Drawing 87 WPB 0001079-01-SSDG-01, SSDG System Replace, One Line Coast Guard Drawing 87 WPB W001079-01-SSDG-01, SSDG System Replace, Wiring Diagram Coast Guard Drawing 87 WPB C001079-01-SSDG-01, SSDG 24/12 VDC System, DC Electrical Elementaries Packaging and Marking: Each Switchboard shall be individually preserved per OEM specifications and hermetically sealed in shrink wrap vapor barrier with sufficient amount of desiccant installed within the vapor barrier to prevent moisture build-up and deterioration of the Switchboard. Each preserved Switchboard shall be individually packaged in a MIL-C-104C (Attachment II) Type I, Class 2, Style A, compliant crate. The crate shall be constructed in such a manner as to prevent rain from entering the interior and shall prevent the Switchboard from shifting inside the crate. The crate shall be capable of providing adequate protection from damage during multiple commercial shipments, forklift handling and warehouse storage. The crate lid and one long side panel shall be secured with corrosion/rust resistant wood lag bolts for easy removal and re-installation. The crate shall be labeled in accordance with Attachment III: USCG/SFLC SP-PP&M-001 dated 05/95 Revision 6/06/11. Failure to read the specifications in its entirety will not relieve the offeror from the responsibility for properly estimating the difficulty or price of successfully performing the work. Failure to do so will be at the offeror's risk. All quotes submitted in response to this solicitation shall stand firm for 90 calendar days from the date specified in this solicitation for receipt of quotes. Contract Type: The USCG, Surface Forces Logistics Center (SFLC) intends to award a definitized, firm fixed-price contract. Place of Performance: Contractor's facility. VII. FAR 52.211-8 -- Time of Delivery (June 1997) (a) The Government requires delivery of the ten (10) marine electrical switchboards to be made according to the following schedule: REQUIRED DELIVERY SCHEDULE ITEM NO. QUANTITY WITHIN WEEKS AFTER DATE OF CONTRACT 0001 2 13 0001 2 17 0001 2 21 0001 2 25 0001 2 29 The Government will evaluate equally, as regards time of delivery, offers that propose delivery of each quantity within the applicable delivery period specified above. Offers that propose delivery that will not clearly fall within the applicable required delivery period specified above, will be considered nonresponsive and rejected. The Government reserves the right to award under either the required delivery schedule or the proposed delivery schedule, when an offeror offers an earlier delivery schedule than required above. If the offeror proposes no other delivery schedule, the required delivery schedule above will apply. OFFEROR'S PROPOSED DELIVERY SCHEDULE ITEM NO. QUANTITY WITHIN WEEKS AFTER DATE OF CONTRACT 0001 0001 0001 0001 0001 (b) Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed, or otherwise furnished to the successful offeror, results in a binding contract. The Government will mail or otherwise furnish to the offeror an award or notice of award not later than the day award is dated. Therefore, the offeror should compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the Contracting Officer through the ordinary mails. However, the Government will evaluate an offer that proposes delivery based on the Contractor's date of receipt of the contract or notice of award by adding (1) five calendar days for delivery of the award through the ordinary mails, or (2) one working day if the solicitation states that the contract or notice of award will be transmitted electronically. (The term "working day" excludes weekends and U.S. Federal holidays.) If, as so computed, the offered delivery date is later than the required delivery date, the offer will be considered nonresponsive and rejected. (End of Clause) Place of Delivery: All items are to be delivered to the address provided below: Commanding Officer USCG Surface Forces Logistics Center Receiving Room - Bldg.88 2401 Hawkins Point Rd Baltimore, MD 21226 All items are to be delivered F.O.B. Destination. Inspection and acceptance will occur at the delivery addressee. Contract Administration: The Contracting Officer or authorized representative located at the USCG SFLC, Baltimore, MD shall be the contract administrator for this contract. Any written correspondence shall be delivered to the Contract Officer's authorized representative at the following address: Commanding Officer Attn.: David Packard, Contract Administrator USCG Surface Forces Logistics Center (CPD-C&P1-PBPL) 2401 Hawkins Point Rd Bldg. 31 LL Baltimore, MD 21226 Or submitted electronically to: David.A.Packard@uscg.mil VIII. FAR 52.212-1, INSTRUCTIONS TO OFFERORS - COMMERCIAL ITEMS (JAN 2017) APPLIES TO THIS ACQUISITION AND IS INCORPORATED BY REFERENCE. (ADDENDUM) You shall submit an electronic copy of your firm's signed and dated quote to David Packard at David.A.Packard@uscg.mil, no later than 16 August 2017 by 4:00 PM EDT. Your submission shall include HSCG40-17-Q-11003 in the subject line of the email. These submission instructions will also apply to any future correspondence, as applicable, in response to this solicitation. As a minimum, offers must show: (1) The solicitation number HSCG40-17-Q-11003 (2) The Company Name, DUNS Number, Solicitation Number, Company Address and Point of Contact Name, Telephone Number and E-mail Address (3) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary; (4) Warranty Information - Standard Manufacturer's Warranty, see Warranty section of this solicitation (5) Price and any discount terms; Pricing must be submitted for each CLIN. All prices on CLINs (Attachment 1) shall be a firm fixed-price and shall indicate FOB Destination as referenced in FAR 52.247-34. *Note CLIN QUOTE shall state pricing as per published price catalog noting any special discount offered. The total of all CLINS shall be added together to arrive at an aggregate total. (6) A completed copy of the representations and certifications at FAR 52.212-3 (see FAR 52.212-3(b) for those representations and certifications that the offeror shall complete electronically); (7) Acknowledgment of Solicitation Amendments; (8) Offerors are required to submit verification in the form of a letter from the OEM; or any other written confirmation fully demonstrating that they have the capability of procuring and distributing the required OEM parts. All quotes submitted in response to this solicitation shall stand firm for 60 calendar days from the response date of this solicitation. FAR 52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS - COMMERCIAL ITEMS ALT 1 (JAN 2017) The offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at http://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision. (a) Definitions. As used in this provision-- "Administrative merits determination" means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. "Arbitral award or decision" means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. "Civil judgment" means-- (1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction. (2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. "DOL Guidance" means the Department of Labor (DOL) Guidance entitled: "Guidance for Executive Order 13673, ‘Fair Pay and Safe Workplaces' ". The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces. "Economically disadvantaged women-owned small business (EDWOSB) concern" means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program. "Enforcement agency" means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are-- (1) Department of Labor Wage and Hour Division (WHD) for-- (i) The Fair Labor Standards Act; (ii) The Migrant and Seasonal Agricultural Worker Protection Act; (iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act; (v) 41 U.S.C. chapter 67, formerly known as the Service Contract Act; (vi) The Family and Medical Leave Act; and (vii) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors); (2) Department of Labor Occupational Safety and Health Administration (OSHA) for-- (i) The Occupational Safety and Health Act of 1970; and (ii) OSHA-approved State Plans; (3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for-- (i) Section 503 of the Rehabilitation Act of 1973; (ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and (iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity); (4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and (5) Equal Employment Opportunity Commission (EEOC) for-- (i) Title VII of the Civil Rights Act of 1964; (ii) The Americans with Disabilities Act of 1990; (iii) The Age Discrimination in Employment Act of 1967; and (iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act). "Forced or indentured child labor" means all work or service- (6) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or (7) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties. "Highest-level owner" means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner. "Immediate owner" means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees. "Inverted domestic corporation," means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c). "Labor compliance agreement" means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters. "Labor laws" means the following labor laws and E.O.s: (1) The Fair Labor Standards Act. (2) The Occupational Safety and Health Act (OSHA) of 1970. (3) The Migrant and Seasonal Agricultural Worker Protection Act. (4) The National Labor Relations Act. (5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act. (6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act. (7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity). (8) Section 503 of the Rehabilitation Act of 1973. (9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974. (10) The Family and Medical Leave Act. (11) Title VII of the Civil Rights Act of 1964. (12) The Americans with Disabilities Act of 1990. (13) The Age Discrimination in Employment Act of 1967. (14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors). (15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html). "Labor law decision" means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of "labor laws". "Manufactured end product" means any end product in product and service codes (PSCs) 1000-9999, except- (1) PSC 5510, Lumber and Related Basic Wood Materials; (2) Product or Service Group (PSG) 87, Agricultural Supplies; (3) PSG 88, Live Animals; (4) PSG 89, Subsistence; (5) PSC 9410, Crude Grades of Plant Materials; (6) PSC 9430, Miscellaneous Crude Animal Products, Inedible; (7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products; (8) PSC 9610, Ores; (9) PSC 9620, Minerals, Natural and Synthetic; and (10) PSC 9630, Additive Metal Materials. "Place of manufacture" means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture. "Predecessor" means an entity that is replaced by a successor and includes any predecessors of the predecessor. "Restricted business operations" means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate- (1) Are conducted under contract directly and exclusively with the regional government of southern Sudan; (2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization; (3) Consist of providing goods or services to marginalized populations of Sudan; (4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization; (5) Consist of providing goods or services that are used only to promote health or education; or (6) Have been voluntarily suspended. Sensitive technology- (1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically- (i) To restrict the free flow of unbiased information in Iran; or (ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and (2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)). "Service-disabled veteran-owned small business concern"- (1) Means a small business concern- (i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and (ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran. (2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16). "Small business concern" means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation. "Small disadvantaged business concern, consistent with 13 CFR 124.1002," means a small business concern under the size standard applicable to the acquisition, that-- (1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by-- (i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and (ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and (2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition. "Subsidiary" means an entity in which more than 50 percent of the entity is owned- (1) Directly by a parent corporation; or (2) Through another subsidiary of a parent corporation. "Successor" means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term "successor" does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances. "Veteran-owned small business concern" means a small business concern- (1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and (2) The management and daily business operations of which are controlled by one or more veterans. "Women-owned business concern" means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women. "Women-owned small business concern" means a small business concern -- (1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and (2) Whose management and daily business operations are controlled by one or more women. "Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127)," means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States. Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: "Administrative merits determination", "Arbitral award or decision", paragraph (2) of "Civil judgment", "DOL Guidance", "Enforcement agency", "Labor compliance agreement", "Labor laws", and "Labor law decision". The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. (b) (1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAMwebsite. (2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representation and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications-Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ____________. [Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically onSAM.] (c) Offerors must complete the following representations when the resulting contract is to be performed in the United States or its outlying areas. Check all that apply. (1) Small business concern. The offeror represents as part of its offer that it [_] is, [_] is not a small business concern. (2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [_] is, [_] is not a veteran-owned small business concern. (3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it [_] is, [_] is not a service-disabled veteran-owned small business concern. (4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [_] is, [_] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002. (5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [_] is, [_] is not a women-owned small business concern. Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold. (6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that- (i) It [_] is, [_] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and (ii) It [_] is, [_] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: _________.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation. (7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that- (i) It [_] is, [_] is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and (ii) It [_] is, [_] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: _____________.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation. (8) Women-owned business concern (other than small business concern). [Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [_] is, a women-owned business concern. (9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price: _____________________________ (10) HUBZone small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that-- (i) It [_] is, [_] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and (ii) It [_] is, [_] is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: __________.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation. (d) Representations required to implement provisions of Executive Order 11246 -- (1) Previous contracts and compliance. The offeror represents that -- (i) It [_] has, [_] has not, participated in a previous contract or subcontract subject to the Equal Opportunity clause of this solicitation; and (ii) It [_] has, [_] has not, filed all required compliance reports. (2) Affirmative Action Compliance. The offeror represents that -- (i) It [_] has developed and has on file, [_] has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 CFR parts 60-1 and 60-2), or (ii) It [_] has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor. (e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made. (f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American - Supplies, is included in this solicitation.) (1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of "domestic end product." The terms "commercially available off-the-shelf (COTS) item," "component," "domestic end product," "end product," "foreign end product," and "United States" are defined in the clause of this solicitation entitled "Buy American-Supplies." (2) Foreign End Products: LINE ITEM NO. COUNTRY OF ORIGIN [List as necessary] (3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. (g) (1) Buy American -- Free Trade Agreements -- Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American -- Free Trade Agreements -- Israeli Trade Act, is included in this solicitation.) (i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms "Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product," "commercially available off-the-shelf (COTS) item," "component," "domestic end product," "end product," "foreign end product," "Free Trade Agreement country," "Free Trade Agreement country end product," "Israeli end product," and "United States" are defined in the clause of this solicitation entitled "Buy American--Free Trade Agreements--Israeli Trade Act." (ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act": Free Trade Agreement Country End Products (Other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products: LINE ITEM NO. COUNTRY OF ORIGIN [List as necessary] (iii) The offeror shall list those supplies that are foreign end products (other than those listed in paragraph (g)(1)(ii) or this provision) as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act." The offeror shall list as other foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of "domestic end product." Other Foreign End Products: LINE ITEM NO. COUNTRY OF ORIGIN [List as necessary] (iv) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. (2) Buy American-Free Trade Agreements-Israeli Trade Act Certificate, Alternate I. If Alternate I to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Canadian end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act": Canadian End Products: Line Item No.: _____________________________ [List as necessary] (3) Buy American-Free Trade Agreements-Israeli Trade Act Certificate, Alternate II. If Alternate II to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Canadian end products or Israeli end products as defined in the clause of this solicitation entitled "Buy American--Free Trade Agreements--Israeli Trade Act'': Canadian or Israeli End Products: Line Item No.: Country of Origin: [List as necessary] (4) Buy American-Free Trade Agreements-Israeli Trade Act Certificate, Alternate III. If Alternate III to the clause at 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act": Free Trade Agreement Country End Products (Other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products: Line Item No.: Country of Origin: [List as necessary] (5) Trade Agreements Certificate. (Applies only if the clause at FAR 52.225-5, Trade Agreements, is included in this solicitation.) (i) The offeror certifies that each end product, except those listed in paragraph (g)(5)(ii) of this provision, is a U.S.-made or designated country end product as defined in the clause of this solicitation entitled "Trade Agreements." (ii) The offeror shall list as other end products those end products that are not U.S.-made or designated country end products. Other End Products Line Item No.: Country of Origin: [List as necessary] (iii) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. For line items covered by the WTO GPA, the Government will evaluate offers of U.S.-made or designated country end products without regard to the restrictions of the Buy American statute. The Government will consider for award only offers of U.S.-made or designated country end products unless the Contracting Officer determines that there are no offers for such products or that the offers for such products are insufficient to fulfill the requirements of the solicitation. (h) Certification Regarding Responsibility Matters (Executive Order 12689). (Applies only if the contract value is expected to exceed the simplified acquisition threshold.) The offeror certifies, to the best of its knowledge and belief, that the offeror and/or any of its principals-- (1) [_] Are, [_] are not presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency; (2) [_] Have, [_] have not, within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a Federal, state or local government contract or subcontract; violation of Federal or state antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property; and (3) [_] Are, [_] are not presently indicted for, or otherwise criminally or civilly charged by a Government entity with, commission of any of these offenses enumerated in paragraph (h)(2) of this clause; and (4) [_] Have, [_] have not, within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied. (i) Taxes are considered delinquent if both of the following criteria apply: (A) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted. (B) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded. (ii) Examples. (A) The taxpayer has received a statutory notice of deficiency, under I.R.C. §6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appear rights. (B) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. §6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals Contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights. (C) The taxpayer has entered into an installment agreement pursuant to I.R.C. §6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment. (D) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. §362 (the Bankruptcy Code). (i) Certification Regarding Knowledge of Child Labor for Listed End Products (Executive Order 13126). [The Contracting Officer must list in paragraph (i)(1) any end products being acquired under this solicitation that are included in the List of Products Requiring Contractor Certification as to Forced or Indentured Child Labor, unless excluded at 22.1503(b).] (1) Listed End Product Listed End Product: Listed Countries of Origin: (2) Certification. [If the Contracting Officer has identified end products and countries of origin in paragraph (i)(1) of this provision, then the offeror must certify to either (i)(2)(i) or (i)(2)(ii) by checking the appropriate block.] [_] (i) The offeror will not supply any end product listed in paragraph (i)(1) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product. [_] (ii) The offeror may supply an end product listed in paragraph (i)(1) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product. The offeror certifies that is has made a good faith effort to determine whether forced or indentured child labor was used to mine, produce, or manufacture any such end product furnished under this contract. On the basis of those efforts, the offeror certifies that it is not aware of any such use of child labor. (j) Place of manufacture. (Does not apply unless the solicitation is predominantly for the acquisition of manufactured end products.) For statistical purposes only, the offeror shall indicate whether the place of manufacture of the end products it expects to provide in response to this solicitation is predominantly- (1) [_] In the United States (Check this box if the total anticipated price of offered end products manufactured in the United States exceeds the total anticipated price of offered end products manufactured outside the United States); or (2) [_] Outside the United States. (k) Certificates regarding exemptions from the application of the Service Contract Labor Standards. (Certification by the offeror as to its compliance with respect to the contract also constitutes its certification as to compliance by its subcontractor if it subcontracts out the exempt services.) [The contracting officer is to check a box to indicate if paragraph (k)(1) or (k)(2) applies.] (1) [_] Maintenance, calibration, or repair of certain equipment as described in FAR 22.1003-4(c)(1). The offeror [_] does [_] does not certify that- (i) The items of equipment to be serviced under this contract are used regularly for other than Governmental purposes and are sold or traded by the offeror (or subcontractor in the case of an exempt subcontract) in substantial quantities to the general public in the course of normal business operations; (ii) The services will be furnished at prices which are, or are based on, established catalog or market prices (see FAR 22.1003-4(c)(2)(ii)) for the maintenance, calibration, or repair of such equipment; and (iii) The compensation (wage and fringe benefits) plan for all service employees performing work under the contract will be the same as that used for these employees and equivalent employees servicing the same equipment of commercial customers. (2) [_] Certain services as described in FAR 22.1003-4(d)(1). The offeror [_] does [_] does not certify that- (i) The services under the contract are offered and sold regularly to non-Governmental customers, and are provided by the offeror (or subcontractor in the case of an exempt subcontract) to the general public in substantial quantities in the course of normal business operations; (ii) The contract services will be furnished at prices that are, or are based on, established catalog or market prices (see FAR 22.1003-4(d)(2)(iii)); (iii) Each service employee who will perform the services under the contract will spend only a small portion of his or her time (a monthly average of less than 20 percent of the available hours on an annualized basis, or less than 20 percent of available hours during the contract period if the contract period is less than a month) servicing the Government contract; and (iv) The compensation (wage and fringe benefits) plan for all service employees performing work under the contract is the same as that used for these employees and equivalent employees servicing commercial customers. (3) If paragraph (k)(1) or (k)(2) of this clause applies- (i) If the offeror does not certify to the conditions in paragraph (k)(1) or (k)(2) and the Contracting Officer did not attach a Service Contract Labor Standards wage determination to the solicitation, the offeror shall notify the Contracting Officer as soon as possible; and (ii) The Contracting Officer may not make an award to the offeror if the offeror fails to execute the certification in paragraph (k)(1) or (k)(2) of this clause or to contact the Contracting Officer as required in paragraph (k)(3)(i) of this clause. (l) Taxpayer identification number (TIN) (26 U.S.C. 6109, 31 U.S.C. 7701). (Not applicable if the offeror is required to provide this information to the SAM database to be eligible for award.) (1) All offerors must submit the information required in paragraphs (l)(3) through (l)(5) of this provision to comply with debt collection requirements of 31 U.S.C. 7701(c) and 3325(d), reporting requirements of 26 U.S.C. 6041, 6041A, and 6050M, and implementing regulations issued by the Internal Revenue Service (IRS). (2) The TIN may be used by the government to collect and report on any delinquent amounts arising out of the offeror's relationship with the Government (31 U.S.C. 7701(c)(3)). If the resulting contract is subject to the payment reporting requirements described in FAR 4.904, the TIN provided hereunder may be matched with IRS records to verify the accuracy of the offeror's TIN. (3) Taxpayer Identification Number (TIN). [_] TIN:_____________________. [_] TIN has been applied for. [_] TIN is not required because: [_] Offeror is a nonresident alien, foreign corporation, or foreign partnership that does not have income effectively connected with the conduct of a trade or business in the United States and does not have an office or place of business or a fiscal paying agent in the United States; [_] Offeror is an agency or instrumentality of a foreign government; [_] Offeror is an agency or instrumentality of the Federal Government; (4) Type of organization. [_] Sole proprietorship; [_] Partnership; [_] Corporate entity (not tax-exempt); [_] Corporate entity (tax-exempt); [_] Government entity (Federal, State, or local); [_] Foreign government; [_] International organization per 26 CFR 1.6049-4; [_] Other ____________________. (5) Common parent. [_] Offeror is not owned or controlled by a common parent: [_] Name and TIN of common parent: Name_____________________________ TIN _____________________________ (m) Restricted business operations in Sudan. By submission of its offer, the offeror certifies that the offeror does not conduct any restricted business operations in Sudan. (n) Prohibition on Contracting with Inverted Domestic Corporations- (1) Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation, unless the exception at 9.108-2(b) applies or the requirement is waived in accordance with the procedures at 9.108-4. (2) Representation. The offeror represents that- (i) It [ ] is, [ ] is not an inverted domestic corporation; and (ii) It [ ] is, [ ] is not a subsidiary of an inverted domestic corporation. (o) Prohibition on contracting with entities engaging in certain activities or transactions relating to Iran. (1) The offeror shall email questions concerning sensitive technology to the Department of State at CISADA106@state.gov. (2) Representation and Certification. Unless a waiver is granted or an exception applies as provided in paragraph (o)(3) of this provision, by submission of its offer, the offeror- (i) Represents, to the best of its knowledge and belief, that the offeror does not export any sensitive technology to the government of Iran or any entities or individuals owned or controlled by, or acting on behalf or at the direction of, the government of Iran; (ii) Certifies that the offeror, or any person owned or controlled by the offeror, does not engage in any activities for which sanctions may be imposed under section 5 of the Iran Sanctions Act; and (iii) Certifies that the offeror, and any person owned or controlled by the offeror, does not knowingly engage in any transaction that exceeds $3,500 with Iran's Revolutionary Guard Corps or any of its officials, agents, or affiliates, the property and interests in property of which are blocked pursuant to the International Emergency Economic Powers Act (50(U.S.C. 1701 et seq.) (see OFAC's Specially Designated Nationals and Blocked Persons List at http://www.treasury.gov/ofac/downloads/t11sdn.pdf). (3) The representation and certification requirements of paragraph (o)(2) of this provision do not apply if- (i) This solicitation includes a trade agreements certification (e.g., 52.212-3(g) or a comparable agency provision); and (ii) The offeror has certified that all the offered products to be supplied are designated country end products. (p) Ownership or Control of Offeror. (Applies in all solicitations when there is a requirement to be registered in SAM or a requirement to have a unique entity identifier in the solicitation. (1) The Offeror represents that it [ ] has or [ ] does not have an immediate owner. If the Offeror has more than one immediate owner (such as a joint venture), then the Offeror shall respond to paragraph (2) and if applicable, paragraph (3) of this provision for each participant in the joint venture. (2) If the Offeror indicates "has" in paragraph (p)(1) of this provision, enter the following information: Immediate owner CAGE code:______________________________ Immediate owner legal name:______________________________ (Do not use a "doing business as" name) Is the immediate owner owned or controlled by another entity: [ ] Yes or [ ] No. (3) If the Offeror indicates "yes" in paragraph (p)(2) of this provision, indicating that the immediate owner is owned or controlled by another entity, then enter the following information: Highest level owner CAGE code:_ _____________________________ Highest level owner legal name:_ _____________________________ (Do not use a "doing business as" name) (q) Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. (1) As required by section 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that- (i) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless and agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or (ii) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government. (2) The Offeror represents that-- (i) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and (ii) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months. (r) Predecessor of Offeror. (Applies in all solicitations that include the provision at 52.204-16, Commercial and Government Entity Code Reporting.) (1) The Offeror represents that it [ ] is or [ ] is not a successor to a predecessor thatheld a Federal contract or grant within the last three years. (2) If the Offeror has indicated "is" in paragraph (r)(1) of this provision, enter the following information for all predecessors that held a Federal contract or grant within the last three years (if more than one predecessor, list in reverse chronological order): Predecessor CAGE code ______(or mark "Unknown). Predecessor legal name: _________________________. (Do not use a "doing business as" name). (s) Representation regarding compliance with labor laws (Executive Order 13673). If the offeror is a joint venture that is not itself a separate legal entity, each concern participating in the joint venture shall separately comply with the requirements of this provision. (1)(i) For solicitations issued on or after October 25, 2016 through April 24, 2017: The Offeror [ ] does [ ] does not anticipate submitting an offer with an estimated contract value of greater than $50 million. (ii) For solicitations issued after April 24, 2017: The Offeror [ ] does [ ] does not anticipate submitting an offer with an estimated contract value of greater than $500,000. (2) If the Offeror checked ``does'' in paragraph (s)(1)(i) or (ii) of this provision, the Offeror represents to the best of the Offeror's knowledge and belief [Offeror to check appropriate block]: [ ](i) There has been no administrative merits determination, arbitral award or decision, or civil judgment for any labor law violation(s) rendered against the offeror (see definitions in paragraph (a) of this section) during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter; or [ ](ii) There has been an administrative merits determination, arbitral award or decision, or civil judgment for any labor law violation(s) rendered against the Offeror during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter. (3)(i) If the box at paragraph (s)(2)(ii) of this provision is checked and the Contracting Officer has initiated a responsibility determination and has requested additional information, the Offeror shall provide-- (A) The following information for each disclosed labor law decision in the System for Award Management (SAM) at www.sam.gov, unless the information is already current, accurate, and complete in SAM. This information will be publicly available in the Federal Awardee Performance and Integrity Information System (FAPIIS): (1) The labor law violated. (2) The case number, inspection number, charge number, docket number, or other unique identification number. (3) The date rendered. (4) The name of the court, arbitrator(s), agency, board, or commission that rendered the determination or decision; (B) The administrative merits determination, arbitral award or decision, or civil judgment document, to the Contracting Officer, if the Contracting Officer requires it; (C) In SAM, such additional information as the Offeror deems necessary to demonstrate its responsibility, including mitigating factors and remedial measures such as offeror actions taken to address the violations, labor compliance agreements, and other steps taken to achieve compliance with labor laws. Offerors may provide explanatory text and upload documents. This information will not be made public unless the contractor determines that it wants the information to be made public; and (D) The information in paragraphs (s)(3)(i)(A) and (s)(3)(i)(C) of this provision to the Contracting Officer, if the Offeror meets an exception to SAM registration (see FAR 4.1102(a)). (ii)(A) The Contracting Officer will consider all information provided under (s)(3)(i) of this provision as part of making a responsibility determination. (B) A representation that any labor law decision(s) were rendered against the Offeror will not necessarily result in withholding of an award under this solicitation. Failure of the Offeror to furnish a representation or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible. (C) The representation in paragraph (s)(2) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous representation, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation in accordance with the procedures set forth in FAR 12.403. (4) The Offeror shall provide immediate written notice to the Contracting Officer if at any time prior to contract award the Offeror learns that its representation at paragraph (s)(2) of this provision is no longer accurate. (5) The representation in paragraph (s)(2) of this provision will be public information in the Federal Awardee Performance and Integrity Information System (FAPIIS). Note to paragraph (s): By a court order issued on October 24, 2016, this paragraph (s) is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. (t) Public Disclosure of Greenhouse Gas Emissions and Reduction Goals. Applies in all solicitations that require offerors to register in SAM (52.212-1(k)). (1) This representation shall be completed if the Offeror received $7.5 million or more in contract awards in the prior Federal fiscal year. The representation is optional if the Offeror received less than $7.5 million in Federal contract awards in the prior Federal fiscal year. (2) Representation. [Offeror to check applicable block(s) in paragraph (t)(2)(i) and (ii)]. (i) The Offeror (itself or through its immediate owner or highest-level owner) [ ] does, [ ] does not publicly disclose greenhouse gas emissions, i.e., makes available on a publicly accessible Web site the results of a greenhouse gas inventory, performed in accordance with an accounting standard with publicly available and consistently applied criteria, such as the Greenhouse Gas Protocol Corporate Standard. (ii) The Offeror (itself or through its immediate owner or highest-level owner) [ ] does, [ ] does not publicly disclose a quantitative greenhouse gas emissions reduction goal, i.e., make available on a publicly accessible Web site a target to reduce absolute emissions or emissions intensity by a specific quantity or percentage. (iii) A publicly accessible Web site includes the Offeror's own Web site or a recognized, third-party greenhouse gas emissions reporting program. (3) If the Offeror checked ``does'' in paragraphs (t)(2)(i) or (t)(2)(ii) of this provision, respectively, the Offeror shall provide the publicly accessible Web site(s) where greenhouse gas emissions and/or reduction goals are reported:_____. (u) (1) In accordance with section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions), Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with an entity that requires employees or subcontractors of such entity seeking to report waste, fraud, or abuse to sign internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting such waste, fraud, or abuse to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information. (2) The prohibition in paragraph (u)(1) of this provision does not contravene requirements applicable to Standard Form 312 (Classified Information Nondisclosure Agreement), Form 4414 (Sensitive Compartmented Information Nondisclosure Agreement), or any other form issued by a Federal department or agency governing the nondisclosure of classified information. (3) Representation. By submission of its offer, the Offeror represents that it will not require its employees or subcontractors to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting waste, fraud, or abuse related to the performance of a Government contract to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information (e.g., agency Office of the Inspector General). (End of Provision) Alternate I (Oct 2014). As prescribed in 12.301(b)(2), add the following paragraph (c)(11) to the basic provision: (11) (Complete if the offeror has represented itself as disadvantaged in paragraph (c)(4) of this provision.) [The offeror shall check the category in which its ownership falls]: ____ Black American. ___ Hispanic American. ___ Native American (American Indians, Eskimos, Aleuts, or Native Hawaiians). ___ Asian-Pacific American (persons with origins from Burma, Thailand, Malaysia, Indonesia, Singapore, Brunei, Japan, China, Taiwan, Laos, Cambodia (Kampuchea), Vietnam, Korea, The Philippines, Republic of Palau, Republic of the Marshall Islands, Federated States of Micronesia, the Commonwealth of the Northern Mariana Islands, Guam, Samoa, Macao, Hong Kong, Fiji, Tonga, Kiribati, Tuvalu, or Nauru). ___ Subcontinent Asian (Asian-Indian) American (persons with origins from India, Pakistan, Bangladesh, Sri Lanka, Bhutan, the Maldives Islands, or Nepal). ___ Individual/concern, other than one of the preceding. IX. Evaluation The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. X. Offerors must include a completed copy of the provision at FAR 52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS - COMMERCIAL ITEMS (MAR 2015) with its offer. XI. FAR 52.212-4, CONTRACT TERMS AND CONDITIONS-COMMERICIAL ITEMS (MAY 2015) APPLIES TO THIS ACQUISITION AND IS INCORPORATED BY REFERENCE. (ADDENDUM) XII. FAR 52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS- COMMERICIAL ITEMS (MARCH 2016) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (1) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015) (2) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553). (3) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004)(Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)). (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: X (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402). __ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509)). __ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.) X (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2015) (Pub. L. 109-282) (31 U.S.C. 6101 note). __ (5) [Reserved]. __ (6) 52.204-14, Service Contract Reporting Requirements (Jan 2014) (Pub. L. 111-117, section 743 of Div. C). __ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Jan 2014) (Pub. L. 111-117, section 743 of Div. C). X (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note). X (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313). __ (10) [Reserved]. __ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a). __ (ii) Alternate I (Nov 2011) of 52.219-3. __ (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a). __ (ii) Alternate I (Jan 2011) of 52.219-4. __ (13) [Reserved] __ (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2011) (15 U.S.C. 644). __ (ii) Alternate I (Nov 2011). __ (iii) Alternate II (Nov 2011). __ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644). __ (ii) Alternate I (Oct 1995) of 52.219-7. __ (iii) Alternate II (Mar 2004) of 52.219-7. X (16) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)). __ (17)(i) 52.219-9, Small Business Subcontracting Plan (Oct 2015) (15 U.S.C. 637(d)(4)). __ (ii) Alternate I (Oct 2001) of 52.219-9. __ (iii) Alternate II (Oct 2001) of 52.219-9. __ (iv) Alternate III (Oct 2015) of 52.219-9. __ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)). __ (19) 52.219-14, Limitations on Subcontracting (Nov 2011) (15 U.S.C. 637(a)(14)). __ (20) 52.219-16, Liquidated Damages-Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)). __ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657 f). X (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)). __ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)). X (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)). X (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755). X (26) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Jan 2016) (E.O. 13126). X (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). X (28) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246). X (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015)(38 U.S.C. 4212). X (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). X (31) 52.222-37, Employment Reports on Veterans (Oct 2015) (38 U.S.C. 4212). X (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). X (33)(i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627). __ (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627). __ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.) __ (35)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.) __ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.) __ (36)(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514). __ (ii) Alternate I (Oct 2015) of 52.223-13. __ (37)(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (Jun 2014) (E.O.s 13423 and 13514). __ (ii) Alternate I (Jun 2014) of 52.223-14. __ (38) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b). __ (39)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514). __ (ii) Alternate I (Jun 2014) of 52.223-16. X (40) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011) (E.O. 13513). X (41) 52.225-1, Buy American-Supplies (May 2014) (41 U.S.C. chapter 83). __ (42)(i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43. __ (ii) Alternate I (May 2014) of 52.225-3. __ (iii) Alternate II (May 2014) of 52.225-3. __ (iv) Alternate III (May 2014) of 52.225-3. __ (43) 52.225-5, Trade Agreements (Nov 2013) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note). X (44) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). __ (45) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). __ (46) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150). __ (47) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150). __ (48) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)). __ (49) 52.232-30, Installment Payments for Commercial Items (Oct 1995) (41 U.S.C. 4505, 10 U.S.C. 2307(f)). X (50) 52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Jul 2013) (31 U.S.C. 3332). __ (51) 52.232-34, Payment by Electronic Funds Transfer-Other than System for Award Management (Jul 2013) (31 U.S.C. 3332). __ (52) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332). __ (53) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a). __ (54)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631). __ (ii) Alternate I (Apr 2003) of 52.247-64. (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: __ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014)(E.O. 13495). __ (2) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67). __ (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). __ (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). __ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). __ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67). __ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67). __ (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (E.O. 13658). __ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792). __ (10) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) (31 U.S.C. 5112(p)(1)). (d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records-Negotiation. (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract. (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. (e)(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509). (ii) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (iii) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph (l) of FAR clause 52.222-17. (iv) 52.222-21, Prohibition of Segregated Facilities (Apr 2015) (v) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246). (vi) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212). (vii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). (viii) 52.222-37, Employment Reports on Veterans (Oct 2015) (38 U.S.C. 4212) (ix) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (x) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67). (xi) __(A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O 13627). __(B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O 13627). (xii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67). (xiii) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67). (xiv) 52.222-54, Employment Eligibility Verification (Oct 2015) (E.O. 12989). (xv) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (E.O. 13658). (xvi) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). (xvii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6. (xviii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. (2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations. (End of Clause) XIII. Additional contract requirements: FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporated one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at http://farsite.hill.af.mil/. Clause Date FAR 52.203-17 Contractor Employee Whistleblower Rights and Requirement to Inform Employees of Whistleblower Rights APR 2014 FAR 52.211-15 Defense Priority and Allocation Requirement APR 2008 FAR 52.232-40 Providing Accelerated Payments to Small Business Subcontractors DEC 2013 FAR 52.247-34 F.O.B. Destination NOV 1991 HSAR 3052.222-70 Strikes or Picketing Affecting Timely Completion of the Contract Work DEC 2003 FAR 52.215-20 - REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA AND OTHER THAN CERTIFIED COST OR PRICING DATA (OCT 2010) (a) Exceptions from certified cost or pricing data. (1) In lieu of submitting certified cost or pricing data, offerors may submit a written request for exception by submitting the information described in the following subparagraphs. The Contracting Officer may require additional supporting information, but only to the extent necessary to determine whether an exception should be granted, and whether the price is fair and reasonable. (i) Identification of the law or regulation establishing the price offered. If the price is controlled under law by periodic rulings, reviews, or similar actions of a governmental body, attach a copy of the controlling document, unless it was previously submitted to the contracting office. (ii) Commercial item exception. For a commercial item exception, the offeror shall submit, at a minimum, information on prices at which the same item or similar items have previously been sold in the commercial market that is adequate for evaluating the reasonableness of the price for this acquisition. Such information may include -- (A) For catalog items, a copy of or identification of the catalog and its date, or the appropriate pages for the offered items, or a statement that the catalog is on file in the buying office to which the proposal is being submitted. Provide a copy or describe current discount policies and price lists (published or unpublished), e.g., wholesale, original equipment manufacturer, or reseller. Also explain the basis of each offered price and its relationship to the established catalog price, including how the proposed price relates to the price of recent sales in quantities similar to the proposed quantities; (B) For market-priced items, the source and date or period of the market quotation or other basis for market price, the base amount, and applicable discounts. In addition, describe the nature of the market; (C) For items included on an active Federal Supply Service Multiple Award Schedule contract, proof that an exception has been granted for the schedule item. (2) The offeror grants the Contracting Officer or an authorized representative the right to examine, at any time before award, books, records, documents, or other directly pertinent records to verify any request for an exception under this provision, and the reasonableness of price. For items priced using catalog or market prices, or law or regulation, access does not extend to cost or profit information or other data relevant solely to the offeror's determination of the prices to be offered in the catalog or marketplace. (b) Requirements for certified cost or pricing data. If the offeror is not granted an exception from the requirement to submit certified cost or pricing data, the following applies: (1) The offeror shall prepare and submit certified cost or pricing data, and data other than certified cost or pricing data, and supporting attachments in accordance with the instructions contained in Table 15-2 of FAR 15.408, which is incorporated by reference with the same force and effect as though it were inserted here in full text. The instructions in Table 15-2 are incorporated as a mandatory format to be used in this contract, unless the Contracting Officer and the Contractor agree to a different format and change this clause to use Alternate I. (2) As soon as practicable after agreement on price, but before contract award (except for unpriced actions such as letter contracts), the offeror shall submit a Certificate of Current Cost or Pricing Data, as prescribed by FAR 15.406-2. (End of Provision) FAR 52.252-6 - AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984) (a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause. (b) The use in this solicitation or contract of any Contractor Employee Whistleblower Rights and Requirement to Inform Employees of Whistleblower Rights. 52.203-17 clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation. (End of Clause) HSAR 3052.209-79 REPRESENTATION BY CORPORATIONS REGARDING A FELONY CRIMINAL VIOLATION UNDER ANY FEDERAL OR STATE LAW OR UNPAID FEDERAL TAX LIABILITY (FEB 2014) (DHS FAR CLASS DEVIATION 14-02) (a) In accordance with sections 561 and 562 of Division F, Title V of the Consolidated Appropriations Act, 2014 (Pub. L. 113-76), none of the funds made available by that Act may be used to enter into a contract with any corporation that: (1) Was convicted (or had an officer or agent of such corporation acting on behalf of the corporation convicted) of a felony criminal violation under any Federal or State law within the preceding 24 months, where the awarding agency is aware of the conviction, unless the agency has considered suspension or debarment of the corporation, or such officer or agency, and made a determination that this further action is not necessary to protect the interests of the Government. (2) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless the agency has considered suspension or debarment of the corporation and made a determination that this further action is not necessary to protect the interests of the Government. (b) The Offeror represents that: (1) It is [ ] is not [ ] a corporation that was convicted (or had an officer or agent of such corporation acting on behalf of the corporation convicted) of a felony criminal violation under any Federal or State law within the preceding 24 months. (2) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability. (c) If the offeror represents in (b) above that it is a corporation that was convicted (or had an officer or agent of such corporation acting on behalf of the corporation convicted) of a felony criminal violation under any Federal or State law within the preceding 24 months, or that it is a corporation that has unpaid Federal tax liability that has been assessed, the offeror shall provide all information related to the felony or tax liability within 3 business days of the Government's request. (End of Provision) HSAR 3052.212-70 CONTRACT TERMS AND CONDITIONS APPLICABLE TO DHS ACQUISITION OF COMMERCIAL ITEMS (SEPT 2012) The Contractor agrees to comply with any provision or clause that is incorporated herein by reference to implement agency policy applicable to acquisition of commercial items or components. The provision or clause in effect based on the applicable regulation cited on the date the solicitation is issued applies unless otherwise stated herein. The following provisions and clauses are incorporated by reference: (a) Provisions. __ 3052.209-72 Organizational Conflicts of Interest. __ 3052.216-70 Evaluation of Offers Subject to An Economic Price Adjustment Clause. __ 3052.219-72 Evaluation of Prime Contractor Participation in the DHS Mentor Protégé Program. (b) Clauses. __ 3052.203-70 Instructions for Contractor Disclosure of Violations. __ 3052.204-70 Security Requirements for Unclassified Information Technology Resources. __ 3052.204-71 Contractor Employee Access. __ Alternate I X 3052.205-70 Advertisement, Publicizing Awards, and Releases. __ 3052.209-73 Limitation on Future Contracting. __ 3052.215-70 Key Personnel or Facilities. __ 3052.216-71 Determination of Award Fee. __ 3052.216-72 Performance Evaluation Plan. __ 3052.216-73 Distribution of Award Fee. __ 3052.217-91 Performance. (USCG) __ 3052.217-92 Inspection and Manner of Doing Work. (USCG) __ 3052.217-93 Subcontracts. (USCG) __ 3052.217-94 Lay Days. (USCG) __ 3052.217-95 Liability and Insurance. (USCG) __ 3052.217-96 Title. (USCG) __ 3052.217-97 Discharge of Liens. (USCG) __ 3052.217-98 Delays. (USCG) __ 3052.217-99 Department of Labor Safety and Health Regulations for Ship Repair. X 3052.217-100 Guarantee. (USCG) __ 3052.219-70 Small Business Subcontracting Plan Reporting. X 3052.219-71 DHS Mentor Protégé Program. __ 3052.228-70 Insurance. __ 3052.228-90 Notification of Miller Act Payment Bond Protection. (USCG) __ 3052.228-91 Loss of or Damage to Leased Aircraft. (USCG) __ 3052.228-92 Fair Market Value of Aircraft. (USCG) __ 3052.228-93 Risk and Indemnities. (USCG) __ 3052.236-70 Special Provisions for Work at Operating Airports. X 3052.242-72 Contracting Officer's Technical Representative. __ 3052.247-70 F.o.B. Origin Information. __ Alternate I __ Alternate II __ 3052.247-71 F.o.B. Origin Only. X 3052.247-72 F.o.B. Destination Only. CONTRACT ADMINISTRATION DATA: INVOICING REQUIREMENTS: (a) All information set forth in FAR Clause 52.212-4(g), Contract Terms and Conditions  Commercial Items, Invoice, must be included in an invoice for it to constitute a proper invoice. (b) An original invoice shall be submitted to the following designated payment office: https://www.fincen.uscg.mil/secure/web_invoices.htm - or e-mail to: fin-smb-yardteam@uscg.mil - or mail to: Yard Commercial Invoices U.S. Coast Guard Yard P.O. Box 4122 Chesapeake, VA 23327-4122 Failure to submit invoices directly to this office will delay prompt payment of your invoice. A copy of any invoice submitted for payment must also be forwarded to the Contract Administrator. ELECTRONIC FUNDS TRANSFER Any payment that the USCG makes to you will be made by electronic funds transfer unless you certify in writing that you do not have an account with a financial institution or an authorized payment agent. Invoices shall include: (1) Name and address of the Contractor; (2) Invoice date and number; (3) Contract number, contract line item number and, if applicable, the order number; (4) Description, quantity, unit of measure, unit price and extended price of the items delivered; (5) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading; (6) Terms of any discount for prompt payment offered; (7) Name and address of official to whom payment is to be sent; (8) Name, title, and phone number of person to notify in event of defective invoice; and (9) Data Universal Numbering System (DUNS) number. The Contractor shall include its DUNS number on the invoice. (10) Electronic funds transfer (EFT) banking information. UNAUTHORIZED INSTRUCTIONS FROM GOVERNMENT PERSONNEL (a) The Contractor shall not accept any instructions issued by any person employed by the U.S. Government or otherwise other than the Contracting Officer or the Contracting Officer's Representative acting within the limits of their authority. A Contracting Officer's Representative shall be designated in writing to the Contractor and shall set forth the scope of their authority. (b) No information, other than that which may be contained in an authorized amendment to this purchase instrument duly issued by the Contracting Officer, which may be received from any person employed by the Government or otherwise will be considered as grounds for deviation from any stipulations of the purchase instruments. GOVERNMENT REPRESENTATIVES (a) The Government may, upon contract award or thereafter, name representatives with titles such as Project Officer, Contracting Officer's Representative(s), and so on. Such individuals, IF APPOINTED, will be named in writing by the Contracting Officer. The letter of appointment will indicate the individuals, titles, and stipulate the rights, responsibilities, and limitations of their appointment. (b) In any event, no such named individual has the authority to issue any direction under this contract, either technical or otherwise, which constitutes a change to the terms, conditions, and price or delivery schedule of the contract. ONLY the Contracting Officer is authorized to alter the contract in any manner. STANDARD COMMERCIAL WARRANTY The Contractor agrees that the supplies furnished under this contract shall be covered by the most favorable warranties the Contractor gives to any customer for such supplies and services and by the rights and remedies provided to the Government by law or by any other clause of this contract. If the item(s) required in the contract resulting from this solicitation are customarily warranted in the trade by a standard commercial warranty, such warranty shall be incorporated into this contract and thereby provided to the Government at no additional cost. Any standard commercial warranty provided shall be identical to the standard commercial warranty normally offered by the Contractor to the Contractor's most favored customer. REQUIRED STANDARD OF WORKMANSHIP Unless otherwise specifically provided in this contract, the quality of all supplies and services rendered hereunder shall conform to the highest standards in the relevant profession, trade, or field of endeavor. All supplies and services shall be rendered or supervised directly by individuals fully qualified in the relevant profession, trade, or field, and holding any licenses required by law. If the contractor's organization as standard practice in the sale of these items issues a certificate of warranty setting forth the terms and conditions of their Standard Commercial Warranty, any contract resulting from this solicitation shall require the contractor to submit said certificate with each unit. CONTRACTOR PERFORMANCE ASSESSMENT REPORT (CPAR) (a) General: The USCG SFLC will monitor and evaluate the successful offeror's past performance of this contract and prepare a Contractor Performance Assessment Report (CPAR) in accordance with FAR Subpart 42.15. All information contained in this assessment may be used, within the limitations of FAR 42.15, by the government for future source selections and in accordance with FAR 15.304, when past performance is an evaluation factor for award. (b) Notification: Upon completion of the contract or base year and each option year, if exercised, the contractor will be notified of the assessment. The contractor will be allowed 60 days to respond to the SFLC's assessment of its performance entered into CPARS. The contractor's response, if any, will be made part of the CPAR system. (c) Information: Information included in the CPAR may include, but is not limited to, the contractor's record of conforming to contract requirements and to standards of good workmanship; the contractor's record of forecasting and controlling costs; the contractor's adherence to contract schedules, including the administrative aspects of performance; the contractor's history of reasonable and cooperative behavior and commitment to customer satisfaction; the contractor's record of integrity and business ethics, and generally, the contractor's business-like concern for the interest of the customer. (d) RELEASE OF DATA: CPARS information is considered business sensitive and will not be released except: (1) to other Federal procurement activities; (2) when SFLC must release pursuant to a Freedom of Information Act (FOIA) request; or (3) when prior written consent is requested and obtained from the contractor. FAR 52.233-2 SERVICE OF PROTEST (SEPT 2006) (a) Protests, as defined in FAR 31.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer by obtaining written and dated acknowledgment of receipt from Jennifer B. Lucas at: USCG Surface Forces Logistics Center CPD C&P1 PBPL 2401 Hawkins Point Road, Bldg 31 LL Baltimore, MD 21226 (b) The copy of any protest shall be received in the office designated above within one (1) day of filing a protest with the GAO. (End of provision) HSAR 3052.209-70 PROHIBITION ON CONTRACTS WITH CORPORATE EXPATRIATES (JUN 2006) (a) Prohibitions. Section 835 of the Homeland Security Act, 6 U.S.C. 395, prohibits the Department of Homeland Security from entering into any contract with a foreign incorporated entity which is treated as an inverted domestic corporation as defined in this clause, or with any subsidiary of such an entity. The Secretary shall waive the prohibition with respect to any specific contract if the Secretary determines that the waiver is required in the interest of national security. (b) Definitions. As used in this clause: Expanded Affiliated Group means an affiliated group as defined in section 1504(a) of the Internal Revenue Code of 1986 (without regard to section 1504(b) of such Code), except that section 1504 of such Code shall be applied by substituting `more than 50 percent' for at least 80 percent each place it appears. Foreign Incorporated Entity means any entity which is, or but for subsection (b) of section 835 of the Homeland Security Act, 6 U.S.C. 395, would be, treated as a foreign corporation for purposes of the Internal Revenue Code of 1986. Inverted Domestic Corporation. A foreign incorporated entity shall be treated as an inverted domestic corporation if, pursuant to a plan (or a series of related transactions)- (1) The entity completes the direct or indirect acquisition of substantially all of the properties held directly or indirectly by a domestic corporation or substantially all of the properties constituting a trade or business of a domestic partnership; (2) After the acquisition at least 80 percent of the stock (by vote or value) of the entity is held- (i) In the case of an acquisition with respect to a domestic corporation, by former shareholders of the domestic corporation by reason of holding stock in the domestic corporation; or (ii) In the case of an acquisition with respect to a domestic partnership, by former partners of the domestic partnership by reason of holding a capital or profits interest in the domestic partnership; and (3) The expanded affiliated group which after the acquisition includes the entity does not have substantial business activities in the foreign country in which or under the law of which the entity is created or organized when compared to the total business activities of such expanded affiliated group. Person, domestic, and foreign have the meanings given such terms by paragraphs (1), (4), and (5) of section 7701(a) of the Internal Revenue Code of 1986, respectively. (c) Special rules. The following definitions and special rules shall apply when determining whether a foreign incorporated entity should be treated as an inverted domestic corporation. (1) Certain Stock Disregarded. For the purpose of treating a foreign incorporated entity as an inverted domestic corporation these shall not be taken into account in determining ownership: (i) Stock held by members of the expanded affiliated group which includes the foreign incorporated entity; or (ii) stock of such entity which is sold in a public offering related to the acquisition described in subsection (b)(1) of Section 835 of the Homeland Security Act, 6 U.S.C. 395(b)(1). (2) Plan Deemed In Certain Cases. If a foreign incorporated entity acquires directly or indirectly substantially all of the properties of a domestic corporation or partnership during the 4-year period beginning on the date which is 2 years before the ownership requirements of subsection (b)(2) are met, such actions shall be treated as pursuant to a plan. (3) Certain Transfers Disregarded. The transfer of properties or liabilities (including by contribution or distribution) shall be disregarded if such transfers are part of a plan a principal purpose of which is to avoid the purposes of this section. (d) Special Rule for Related Partnerships. For purposes of applying section 835(b) of the Homeland Security Act, 6 U.S.C. 395(b) to the acquisition of a domestic partnership, except as provided in regulations, all domestic partnerships which are under common control (within the meaning of section 482 of the Internal Revenue Code of 1986) shall be treated as a partnership. (e) Treatment of Certain Rights. (1) Certain rights shall be treated as stocks to the extent necessary to reflect the present value of all equitable interests incident to the transaction, as follows: (i) warrants; (ii) options; (iii) contracts to acquire stock; (iv) convertible debt instruments; and (v) others similar interests. (2) Rights labeled as stocks shall not be treated as stocks whenever it is deemed appropriate to do so to reflect the present value of the transaction or to disregard transactions whose recognition would defeat the purpose of Section 835. (f) Disclosure. The offeror under this solicitation represents that [Check one]: __ it is not a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.104-70 through 3009.104-73; __ it is a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.104-70 through 3009.104-73, but it has submitted a request for waiver pursuant to 3009.104-74, which has not been denied; or __ it is a foreign incorporated entity that should be treated as an inverted domestic corporation pursuant to the criteria of (HSAR) 48 CFR 3009.104-70 through 3009.104-73, but it plans to submit a request for waiver pursuant to 3009.104-74. (g) A copy of the approved waiver, if a waiver has already been granted, or the waiver request, if awaiver has been applied for, shall be attached to the bid or quotation. (End of Clause) FAR 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JUL 2013) (a) Definitions. As used in this provision- "Administrative proceeding" means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceeding at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables. "Federal contracts and grants with total value greater than $10,000,000" means- (1) The total value of all current, active contracts and grants, including all priced options; and (2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules). "Principal" means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions). (b) The offeror [_] has [_] does not have current active Federal contracts and grants with total value greater than $10,000,000. (c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information: (1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions: (i) In a criminal proceeding, a conviction. (ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more. (iii) In an administrative proceeding, a finding of fault and liability that results in- (A) The payment of a monetary fine or penalty of $5,000 or more; or (B) The payment of a reimbursement, restitution, or damages in excess of $100,000. (iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision. (2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence. (d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7). (End of Provision) FAR 52.204-1 APPROVAL OF CONTRACT (DEC 1989) This contract is subject to the written approval of the CPD-C&P1 Section Chief and shall not be binding until so approved. (End of Clause) XIV. FAR 52.211-14 EMERGENCY PREPAREDNESS NOTICE OF PRIORITY RATING FOR NATIONAL DEFENSE Any contract awarded as a result of this solicitation will be [ ] DX rated order; [X] DO rated order certified for national defense, emergency preparedness, and energy program use under the Defense Priorities and Allocations System (DPAS) (15 CFR 700), and the Contractor will be required to follow all of the requirements of this regulation. (End of Provision) XV. Quotations are due 16 August 2017, no later than 1600 EST. Quotes must be submitted electronically to David.A.Packard@uscg.mil. Documents may have to be compressed into a zip file or sent in separate e-mails due to USCG e-mail size restrictions.
Web Link: FBO.gov Permalink
(https://www.fbo.gov/spg/DHS/USCG/USCGELC/HSCG40-17-Q-11003/listing.html)
Place of Performance: Address: Contractor's facility, United States
Record: SN04622847-W 20170812/170810232122-1c12d220596a0b5136ebe43c09414d66 (fbodaily.com)
Source: FedBizOpps Link to This Notice
(may not be valid after Archive Date)

| FSG Index | This Issue's Index | Today's FBO Daily Index Page |

Loren Data's SAM Daily™

20 -- Ship Service Switchboards for USCG '87 Patrol Boats - Synopsis Docs - J&A