MODIFICATION
Z -- Rplace High Voltage Switch Gears - Amendment 3
- Notice Date
- 8/22/2017
- Notice Type
- Modification/Amendment
- NAICS
- 237130
— Power and Communication Line and Related Structures Construction
- Contracting Office
- Department of the Air Force, US Air Force Europe, 496 ABS/LGC - Moron, Moron AB, Unit 6585, Moron AB, Spain, 09643-6585, United States
- ZIP Code
- 09643-6585
- Solicitation Number
- FA5575-17-R-0003
- Point of Contact
- Paul J Denton, Phone: 34955848482, Joseph J Carter, Phone: 34955848591
- E-Mail Address
-
paul.denton.6@us.af.mil, joseph.carter.20@us.af.mil
(paul.denton.6@us.af.mil, joseph.carter.20@us.af.mil)
- Small Business Set-Aside
- N/A
- Description
- FA5575-17-B-0003; Change Bid Opening Date See Attachement FA5575-17-B-0006-0003 The United States Air Force intends to issue solicitation FA5575-17-B-0006 to solicit proposals for a Firm-Fixed Price contract to Replace High Voltage Switchgears at various facilities at Morón AB, Spain. The magnitude of construction for this project is estimated to be between $25,000 and $100,000 U.S. Dollars. The period of performance for this project is estimated at 250 calendar days. In accordance with the Agreement of Defense and Cooperation between the Kingdom of Spain and the United States of America, any contract resulting from this notice/solicitation can only be entered into with companies authorized to carry out these activities in Spain under Spanish law. Companies must meet the requirements established by Spanish legislation for execution of Government works. In addition, in accordance with the Agreement of Defense Cooperation between the U.S.A. and the Kingdom of Spain, Annex 6, Article 1 (5) " Spanish material, labor, and equipment shall be used whenever feasible and consistent with the requirements". NOTE: THIS SOLICITATION IS INTENDED ONLY FOR LOCAL SOURCES IN ACCORDANCE WITH FEDERAL ACQUISITION REGULATION 5.202(a)(12). LOCAL SOURCES ARE THOSE SOURCES NORMALLY RESIDENT, LICENSED AND REGISTERED TO CONDUCT CONSTRUCTION BUSINESS IN SPAIN. OFFERS FROM NON-LOCAL SOURCES WILL NOT BE CONSIDERED UNDER THIS SOLICITATION. The work includes, but is not limited to: a. Demolition and disposal of existing high voltage switchgears. b. Supply and installation of new SF6-insulated new high voltage switchgears. c. Supply and installation of high voltage cables and terminals between the high voltage overhead electrical lines and the transformer substations. d. Final cleaning. e. Delivery of As-Built drawings. f. Delivery of Spatial Data. The certification requirements are as follows:The United States Air Force intends to issue solicitation FA5575-17-B-0006 to solicit proposals for a Firm-Fixed Price contract to Replace High Voltage Switchgears at various facilities at Morón AB, Spain. The magnitude of construction for this project is estimated to be between $25,000 and $100,000 U.S. Dollars. The period of performance for this project is estimated at 250 calendar days. A pre-proposal conference/site visit will be held 1 August 2017, 11:00 hours local time in the Contracting Conference room, Building 106. Bids must be received by the Contracting Officer no later than 12:15 hours local time on 31 August 2017. Bids by Facsimile will NOT be accepted. In accordance with the Agreement of Defense and Cooperation between the Kingdom of Spain and the United States of America, any contract resulting from this notice/solicitation can only be entered into with companies authorized to carry out these activities in Spain under Spanish law. Companies must meet the requirements established by Spanish legislation for execution of Government works. In addition, in accordance with the Agreement of Defense Cooperation between the U.S.A. and the Kingdom of Spain, Annex 6, Article 1 (5) " Spanish material, labor, and equipment shall be used whenever feasible and consistent with the requirements". NOTE: THIS SOLICITATION IS INTENDED ONLY FOR LOCAL SOURCES IN ACCORDANCE WITH FEDERAL ACQUISITION REGULATION 5.202(a)(12). LOCAL SOURCES ARE THOSE SOURCES NORMALLY RESIDENT, LICENSED AND REGISTERED TO CONDUCT CONSTRUCTION BUSINESS IN SPAIN. OFFERS FROM NON-LOCAL SOURCES WILL NOT BE CONSIDERED UNDER THIS SOLICITATION. The work includes, but is not limited to: a. Demolition and disposal of existing high voltage switchgears. b. Supply and installation of new SF6-insulated new high voltage switchgears. c. Supply and installation of high voltage cables and terminals between the high voltage overhead electrical lines and the transformer substations. d. Final cleaning. e. Delivery of As-Built drawings. f. Delivery of Spatial Data. The certification requirements are as follows: CERTIFICATION OF CLASSIFICATION: Bidders and/or their subcontractors must hold an updated Certificate of Classification issued by the "Registro Oficial de Licitadores y Empresas Clasificadas del Estado", covering the following groups, subgroups, and categories. The certificate holder must execute the activities related to the certificate. GROUP SUBGROUP CATEGORY I 5 1 I 6 1 It is highly recommended that you register to be notified of any new postings for this solicitation and/or any other postings published by our office. However, failure of the service to notify you of changes cannot be used against the Government in any way, shape or form. Therefore, you should check FedBizOps, https://www.fbo.gov, frequently for any new postings that may have been made. The Government anticipates and reserves the right, to issue all solicitation documents including specifications and drawings in the English language only. In order to be awarded a contract by the U.S. Government, the company must be registered in the System for Award Management (SAM); contracts cannot be awarded to unregistered contractors. Registration can be made online at www.sam.gov/portal/public/SAM/ NOTE: You must have a DUNS number and a NATO Commercial and Government Entity (NCAGE) Code to register. To obtain a Data Universal Numbering System (DUNS) Number you can contact Dun and Bradstreet and request one by calling: 902-446-688. To obtain a NATO CAGE code you must fill out the form found in: http://www.dlis.dla.mil/Forms/Form AC135.asp. Failure to be registered in SAM at the time of award may delay the award and depending on the criticality of the project, may be cause to award to the next qualified best value offeror who is SAM registered. However, do not delay submitting your proposal pending receipt of a DUNS number or CAGE Code. CERTIFICATION OF CLASSIFICATION: Bidders and/or their subcontractors must hold an updated Certificate of Classification issued by the "Registro Oficial de Licitadores y Empresas Clasificadas del Estado", covering the following groups, subgroups, and categories. The certificate holder must execute the activities related to the certificate. GROUP SUBGROUP CATEGORY I 5 1 I 6 1 It is highly recommended that you register to be notified of any new postings for this solicitation and/or any other postings published by our office. However, failure of the service to notify you of changes cannot be used against the Government in any way, shape or form. Therefore, you should check FedBizOps, https://www.fbo.gov, frequently for any new postings that may have been made. The Government anticipates and reserves the right, to issue all solicitation documents including specifications and drawings in the English language only. In order to be awarded a contract by the U.S. Government, the company must be registered in the System for Award Management (SAM); contracts cannot be awarded to unregistered contractors. Registration can be made online at www.sam.gov/portal/public/SAM/ NOTE: You must have a DUNS number and a NATO Commercial and Government Entity (NCAGE) Code to register. To obtain a Data Universal Numbering System (DUNS) Number you can contact Dun and Bradstreet and request one by calling: 902-446-688. To obtain a NATO CAGE code you must fill out the form found in: http://www.dlis.dla.mil/Forms/Form AC135.asp. Failure to be registered in SAM at the time of award may delay the award and depending on the criticality of the project, may be cause to award to the next qualified best value offeror who is SAM registered. However, do not delay submitting your proposal pending receipt of a DUNS number or CAGE Code.
- Web Link
-
FBO.gov Permalink
(https://www.fbo.gov/notices/1113fded04a8c4e3f680502dabba0c70)
- Place of Performance
- Address: Morón Air Base, Carretera Sevilla - Morón km 17, Moron de la Frontera, Sevilla, 41530, Spain, Sevilla, Non-U.S., 42530, Spain
- Record
- SN04641859-W 20170824/170822233249-1113fded04a8c4e3f680502dabba0c70 (fbodaily.com)
- Source
-
FedBizOpps Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |