FBODaily.com | FedBizOpps: PRESOL | J | USCGC TRUMP WPC-1111 DOCKSIDE REPAIRS - SPECS

FBO DAILY - FEDBIZOPPS ISSUE OF OCTOBER 20, 2017 FBO #5810
SOLICITATION NOTICE

J -- USCGC TRUMP WPC-1111 DOCKSIDE REPAIRS - SPECS

Notice Date: 10/18/2017
Notice Type: Combined Synopsis/Solicitation
NAICS: 336611 — Ship Building and Repairing
Contracting Office: Department of Homeland Security, United States Coast Guard (USCG), USCG Surface Forces Logistics Center (SFLC) Procurement Branch 1, 300 East Main Street, Suite 600, Norfolk, Virginia, 23510-9102, United States
ZIP Code: 23510-9102
Solicitation Number: HSCG80-18-Q-P45020
Point of Contact: Shean E. Mohammed, Phone: 7576284957
E-Mail Address: shean.e.mohammed@uscg.mil
(shean.e.mohammed@uscg.mil)
Small Business Set-Aside: Total Small Business
Description: specs COMBINED SYNOPSIS/ SOLICITATION (i) This is a combined synopsis/solicitation for commercial services prepared in accordance with the format in FAR Subpart 12.6, supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotations are being requested and a separate written solicitation will not be issued. (ii) The solicitation is issued as a Request for Quotation (RFQ). ( i i i ) This solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular FAC 2005-95. ( iv ) This RFQ is being solicited as 100% total small business set aside using FAR Part 12 Acquisition of Commercial Items and FAR 13.5 Simplified Procedures for Certain Commercial Items. The NAICS Code is 336611- Ship Repair with a small business size standard of 1,250 employees. The solicitation number is HSCG80-18-Q-P45020. (v) SCHEDULE OF SERVICES: See Attachment 1. (vi) DESCRIPTION OF WORK: The Contractor shall furnish all necessary facilities, labor, materials, services, equipment, supplies, power, accessories, special tools, consumables and other things necessary to perform dockside ship repairs for USCGC TRUMP (WPB-1111), a 154-foot patrol boat, all in exact accordance with this solicitation and the attached specification. See Attachment 2. (vii) PERIOD OF PERFORMANCE: The performance period for this requirement is thirty-two (32) calendar days from 17 January through 02 March 2018. REQUEST FOR DRAWINGS / SUBMISSION OF QUESTIONS: Last day to request drawings or ask questions regarding this solicitation is 11:00 E.S.T., 01 November 2017. PLACE OF PERFORMANCE: The place of performance will take place onboard USCGC TRUMP home port at 100 Trumbo Road, Key West, FL 33040. Additionally, each offeror must provide the following information with the quote: 1. The RFQ number. 2. The Name, Address, Telephone Number, and DUNS Number of the Offeror. 3. Completed pricing for Attachment (1) Schedule of Services; include a separate price breakdown for CLIN (D-00C) Travel and Per Diem (example: number of Contracted personnel assigned to project, mileage, tolls, etc). 4. List of subcontractor's and associated CLINS. 5. All required documents listed under 52.212-2 Evaluation of Commercial Items; for Past Performance and Technical Capabilities and Price, found on pages 9 and 10 of this solicitation. 6. A completed copy of FAR 52.209-2 (page 6), FAR 52.209-11 (page 7) and the Representations and Certifications at FAR 52.212-3 (starting on page 11) of this solicitation. 7. Certificate of Insurance. Failure to provide required documentation QUOTATION DUE DATE: All responsible sources may submit a quotation which shall be considered by the agency. Quotes must be submitted electronically via e-mail to Shean.E.Mohammed@uscg.mil before 11:00 a.m. EST on 08 November 2017 NOTICE FOR FILING AGENCY PROTESTS United States Coast Guard Ombudsman Program It is the policy of the United States Coast Guard (USCG) to issue solicitations and make contract awards in a fair and timely manner. The Ombudsman Program for Agency Protests (OPAP) was established to investigate agency protest issues and resolve them without expensive and time- consuming litigation. OPAP is an independent reviewing authority that is empowered to grant a prevailing protester essentially the same relief as the Government Accountability Office (GAO). Interested parties are encouraged to seek resolution of their concerns within the USCG as an Alternative Dispute Resolution (ADR) forum rather than filing a protest with the GAO or some external forum. Interested parties may seek resolution of their concerns informally or opt to file a formal agency protest with the Contracting Officer or Ombudsman. Informal Forum with the Ombudsman. Interested parties who believe a specific USCG procurement is unfair or otherwise defective should first direct their concerns to the applicable Contracting Officer. If the Contracting Officer is unable to satisfy their concerns, interested parties are encouraged to contact the U.S. Coast Guard Ombudsman for Agency Protests. Under this informal process, the agency is not required to suspend contract award performance. Use of an informal forum does not suspend any time requirement for filing a protest with the agency or other forum. In order to ensure a timely response, interested parties should provide the following information to the Ombudsman: solicitation/contract number, contracting office, Contracting Officer, and solicitation closing date (if applicable). Formal Agency Protest with the Ombudsman. Prior to submitting a formal agency protest, protesters must first use their best efforts to resolve their concerns with the Contracting Officer through open and frank discussions. If the protester's concerns are unresolved, an Independent Review is available by the Ombudsman. The protester may file a formal agency protest to either the Contracting Officer or as an alternative to that, the Ombudsman under the OPAP program. Contract award or performance will be suspended during the protest period unless contract award or performance is justified, in writing, for urgent and compelling reasons or is determined in writing to be in the best interest of the Government. The agency's goal is to resolve protests in less than 35 calendar days from the date of filing. Protests shall include the information set forth in FAR 33.103(d) (2). If the protester fails to submit the required information, resolution of the protest may be delayed or the protest may be dismissed. To be timely protests must be filed within the period specified in FAR 33.103(e). Formal protests filed under the OPAP program should be submitted to: COMMANDANT (CG-9131) U S COAST GUARD OMBUDSMAN PROGRAM FOR AGENCY PROTESTS 2100 2ND ST SW STOP 7112 WASHINGTON DC 20593-7112 The Ombudsman Hotline Telephone Number is (202)372-3695. (viii) FAR 52.212-1 INSTRUCTIONS TO OFFERORS- COMMERCIAL ITEMS (JAN 2017) ADDENDA INVOICE SUBMISSION PROCESS: 1. The Contractor shall prepare a proper invoice IAW FAR clause 52.212-4, and in addition to the information required by FAR 52.212-4(g) as cited in the contract. All invoices shall be itemized to correlate to the Schedule of Services. (A) The Government will make payment under this contract based on a percentage or stage of completion. The Contractor may invoice each contract line item (CLIN) as work progresses. The amount invoiced shall be calculated based on those prices stipulated in the contract Schedule of Supplies/Services as follows: (B) A CLIN may not be invoiced until the percentage complete reaches 25 percent. Future invoices for that CLIN have no limitation as to the percentage of completion required before invoicing. (The minimum percentage of completion (25%) to be reached prior to billing each CLIN may be waived by the Contracting Officer on a case by case basis for large dollar CLINS.) (C) In addition to the information required by FAR 52.212-4 (g) Invoices shall include: 1) Contract Number 2) Contractor Name and Address 3) Invoice Number and current Invoice Date 4) DUNS Number 5) Vessel name 6) Name of Contracting Officer 7) Invoice Routing Code (IRC): SFLC -1 8) Indicate Small Business Status 9) Indicate if Final Invoice, the Contractor's final invoice submitted under the contract must be marked as follows: THIS INVOICE CONSTITUTES THE FINAL INVOICE - UPON PAYMENT OF THIS INVOICE NO OTHER MONIES ARE DUE UNDER CONTRACT NUMBER (to be assigned upon contract award). 10) The percentage of completion for each CLIN identified; 11) The overall percentage and dollar amount previously billed, currently billed and unbilled, 12) Shipping and Payment Terms 13) Name, title, phone number, and mailing address of person to be notified in the event of a defective invoice. All information must be included in an invoice for it to constitute a proper invoice. All improper invoices will be rejected and will delay payment. 2. The Contractor shall forward invoices and any documentation via e-mail to: Shean.E.Mohammed@uscg.mil and Chelsea.C.Emmons@uscg.mil (the COR). 3. The COR shall review and verify invoices, sign the invoice and return the invoice to the Contractor. 4. The Contractor shall submit the Contractor Invoice Submission Form, a PDF file of the invoice, and any necessary documents for supplies or services via the U.S. Coast Guard Finance Center website at: ht tp: //ww w.fincen. uscg.mil /centralin v/central_inv_contr.cfm 5. The Contractor must select the correct Invoice Routing Code for timely invoice processing. The Invoice Routing Code for this contract is SFLC-1 Additional work verbally agreed to by the parties that has not yet been incorporated into the contract by modification shall not be included in an invoice. Payments will not be made for work for which a modification has not been properly executed. Invoices submitted for payment that includes such a request will be rejected. NOTE: 10% OF THE TOTAL CONTRACT PRICE WILL BE WITHHELD UNTIL ALL DELIVERABLES, REQUIRED BY THE CONTRACT, ARE RECEIVED AND ACCEPTED. FURTHER CONSIDERATIONS WITH INVOICING: In accordance with the Prompt Payment Act, for the purposes of determining a payment due date and the date on which interest will begin to accrue if a payment is late, a proper invoice shall be deemed to have been received: (1) On the later of: (i) For invoices that are mailed the date a proper invoice is actually received by the designated billing office and annotates the invoice with date of receipt at the time of receipt. (ii) For invoices electronically transmitted by the Contractor via web based submission, the date a transmission is received by the designated billing office, and receipt confirmation is provided to the designated recipient; or (iii) The seventh day after the date on which the property is actually delivered or performance of the (iv) services is actually completed; unless- a) The agency has actually accepted the property or services before the seventh day in which case the acceptance date shall substitute for the seventh day after the delivery date; or b) A longer acceptance period is specified in the contract, in which case the date of actual acceptance or the date on which such longer acceptance period ends shall substitute for the seventh day after the delivery date; (2) On the date placed on the invoice by the Contractor, when the agency fails to annotate the invoice with date of receipt of the invoice at the time of receipt (such invoice must be a proper invoice); or (3) On the date of delivery, when the contract specifies that the delivery ticket may serve as an invoice. (4) Web based submission by the Contractor and receipt confirmation does not reflect Government review or acceptance of the invoice. (5) For inquiries and payment status please visit: https://fincen.uscg.mil/secure/payment.htm The Data Universal Numbering System (DUNS) number is the primary identifier in System for Award Management (SAM), see FAR 52.232-33, Payment by Electronic Funds Transfer (JUL 2013). Contractors are located and identified in SAM by their DUNS number. Therefore, to facilitate payment, the DUNS number shall be recorded on every invoice submitted to the U.S. Coast Guard. All payments for partial performance rendered by the Government under this contract are based on the assumption that the Contractor will, in good faith, execute and honor all payment terms entered into between it, the Prime Contractor, and any subcontractor thereof in the performance of this contract. The Contractor hereby acknowledges the Government's right to reduce or suspend progress payments based on non-payment in accordance with any payment terms of the subcontract agreement. Any amount deemed not payable will be deducted from the Contractor's invoice. Deducted amounts may be resubmitted on the next invoice for reconsideration. FAR 52.209-2 PROHIBITION ON CONTACTING WITH INVERTED DOMESTIC CORPORATIONS - REPRESENTATION (NOV 2015) (a) Definitions. "Inverted domestic corporation" and "subsidiary" have the meaning given in the clause of this contract entitled Prohibition on Contracting with Inverted Domestic Corporations (52.209-10). (b) Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation, unless the exception at 9.108-2(b) applies or the requirement is waived in accordance with the procedures at 9.108-4. (c) ) Representation. The Offeror represents that- (1) It □ is, □ is not an inverted domestic corporation; and (2) It □ is, □ is not a subsidiary of an inverted domestic corporation. (End of provision) WELDING CERTIFICATIONS AND QUALIFICATIONS This solicitation may contain welding line items as either Definitive or Optional Items. With his/her quote the Contractor shall provide the necessary welding certifications and qualifications as required by the specification for the applicable work item(s), and SFLC Standard Specification 0740_STD. 52.209-11 Representation by Corporations Regarding Delinquent Tax (FEB 2016) Liability or a Felony Conviction under any Federal Law (a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that-- (1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or (2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government. (b) The Offeror represents that- (1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and (2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months. (End of provision) FAR 52.211-3 AVAILABILITY OF SPECIFICATIONS NOT LISTED IN THE GSA INDEX OF FEDERAL SPECIFICATIONS AND STANDARDS AND COMMERCIAL ITEMS DESCRIPTIONS (JUN 1988) a. Orders for U.S. Coast Guard specification reference drawings must be placed within 10 days of the solicitation issue date. To request drawings, contact the Contract Specialist listed herein. All requests should identify the solicitation number. U.S. Coast Guard specification reference drawings are available in CD-ROM format and are provided free of charge. The CD-ROM(s) contain WINDOWS compliant raster/vector formats (e.g. *.TIF, *.TIF (group4), *.DWG, and *.DWF, etc.). Drawing measurements should be verified by the Contractor prior to ordering materials. FAR 52.216-1 TYPE OF CONTRACT (APR 1984) This Request for Quotes (RFQ) is issued in accordance with FAR Part 12 Acquisition of Commercial Items and FAR Subpart 13.5 Simplified Procedures for Certain Commercial Items. The Government contemplates award of a firm-fixed-price contract resulting from this solicitation. FAR 52.215-20 ALT IV REQUIREMENTS FOR COST OR PRICING DATA OR INFORMATION OTHER THAN COST OR PRICING DATA (OCT 2010) (a) Submission of cost or pricing data is not required (b) If the contracting officer cannot determine price reasonableness either in the initial solicitation or in any change to the contract after award, the contracting officer will require submission information in sufficient detail in order to make such determination. The information may be as follows: REQUEST FOR INFORMAL COST BREAKDOWN In addition to placing your offer in the appropriate place in Schedule of Services and Prices, it is requested that you provide a breakdown of your costs, to include but not be limited to, those items identified in the sample format below: Trade, (i.e. laborers, rigger, etc.) Breakdown of labor grades by trade category Man-hours per trade, per labor grade Cost/hour/trade Supplies/materials (description & cost of each) Sub-total Pension Plans Overhead at a rate of % Profit at a rate of % Total for item FAR 52.237-1 SITE VISIT (APR 1984) This RFQ is for the dockside repairs of the USCGC TRUMP (WPB-1111) hereinafter referred to as "vessel". The vessel's homepier is located at 100 Trumbo Road, Key West, FL 33040 and available for a ship check. The point of contact for site surveys is MKC Andres Pomales, who can be reached on the vessel phone: 305-292-8760 or email Andres.Pomales@uscg.mil. The Contract Administrator is Shean Mohammed, Contract Specialist who can be reached at 757-628-4957 or Shean.E.Mohammed@uscg.mil. Offerors are urged and expected to inspect the site where services are to be performed and to satisfy themselves regarding all general and local conditions that may affect the cost of contract performance, to the extent that the information is reasonably obtainable. In no event shall failure to inspect the site constitute grounds for a claim after contract award. (ix) FAR 52.212-2 EVALUATION - COMMERCIAL ITEMS (OCT 2014) - VARIATION (a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The three (3) following factors shall be used to evaluate offers: FACTOR 1-PAST PERFORMANCE: The offeror shall submit no more than three (3) past performance references similar in size and scope relevant to the specification (construction, overhaul, repair and alteration of ships) within the last two (2) years. For each contract, list: a. Contract Number (if applicable) b. Name and address of the Government Agency or Commercial Entity c. Brief description of work/services provided and the relevance to the requirement herein d. Two (2) Points of Contact with current phone numbers and email addresses e. Date of Contract Award f. Dollar value of the contract (Original and Final) g. Type of service performed and whether Prime or Sub Contractor h. Period of Performance i. Ship Name, Hull Number j. Contract type (FFP, IDIQ, Requirement, Cost Type) If subcontracting arrangement is proposed, the above data must also be provided for each first tier subcontractor. If a joint effort or teaming arrangement is proposed, highlight previous experience with the proposed team or subcontractor. The past performance evaluation will take into account the guidelines outlined at FAR 15.305(a)(2) Past Performance Evaluation. The Contractor's past performance will be evaluated according to the following factors and questions: - Quality of Product or Service / Technical Did the customer get what was specified? Did the customer consider the final product high in quality? If warranty issues arose, were they promptly corrected? - Schedule Was the contract completed on time? If not, reason why not (growth work, Contractor delayed, government delayed?) - Business Relations / Management and Management Responsiveness How was the customer service? Was the Contractor committed to customer satisfaction? Would you use this company again (Why/Why not)? - Management of Key Personnel / Subcontractors Were subcontracts involved? Comments? In evaluating Contractors past performance, the government intends to also review US Coast Guard contracts within the Contractor Performance Assessment Reports (CPARS), Past Performance Information Reporting System (PPIRS and other existing past performance ratings on relevant completed contracts. General trends in a Contractor's performance will also be considered. FACTOR 2-TECHNICAL CAPABILITIES: Technical Acceptability will be evaluated to determine an overall rating of "acceptable" or "unacceptable." This will be determined by evaluating the ability of the offeror to provide a sound, compliant approach that meets all requirements listed in the Specification and demonstrates a thorough knowledge and understanding of the requirements. It is the contractor's responsibility to ensure that their quote clearly demonstrates their ability to perform these requirements. All offerors must provide the following minimum information and documentation with their quotes to be considered technically acceptable: Technical Approach - 1. Planning Document: Submit a written description of your strategy for ensuring that this contract ends on or before the date specified herein. This may include 1) a simple, hand-drawn Gantt chart showing proposed schedule/resources/completion-dates/float/major-milestones/etc. for the various tasks required to complete this contract and 2) a list of items that you believe may pose the most contract schedule risk and how you intend to mitigate or eliminate each risk. The planning document shall include at least: (a) Proposed schedule, resources, completion-dates, float, and major-milestones for the various tasks required to complete this contract and (b) Identify a list of items that may pose the most contract schedule risk and approach to mitigate or eliminate each risk. 2. Certification/Procedures for the following: (a) Welding Certifications/Procedures - Submit welding documentation (e.g. WPSs, welder certification and continuity records, etc.) in accordance with SFLC Standard Specification 0740_STD, specific to your internal or subcontracted staff for all welding work to be performed IAW specification. (b) Equipment Certifications Current certifications and inspections of heavy machinery (ie: Cranes, Forklifts, etc.) that will be used to complete this availability. 3. Material: (a) Material Source - List a proposed/potential source of supply for the contractor-furnished material (e.g. control pendant, electrical box, etc.) FACTOR 3-PRICE: Offeror's shall complete the Attachment (1) Schedule of Services. Price shall represent the best price in response to the request for quotes. The price shall be evaluated to determine fairness and reasonableness. **The Past Performance and Technical Capabilities, when combined, are more important than Price** (b) Award may be made without any type of discussions or negotiations. This is based on the Contracting Officer's determination after an evaluation has been completed on all offers. (x) FAR 52.212-3 - OFFEROR REPRESENTATIONS AND CERTIFICATIONS - COMMERCIAL ITEMS (JAN 2017) Alternate I (OCT 2014) The offeror shall complete only paragraphs (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) Web site located at http://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision. (a) ) Definitions. As used in this provision-- "Administrative merits determination" means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. "Arbitral award or decision" means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. "Civil judgment" means-- (1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction. (2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. "DOL Guidance" means the Department of Labor (DOL) Guidance entitled: "Guidance for Executive Order 13673, ‘Fair Pay and Safe Workplaces' ". The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces. "Economically disadvantaged women-owned small business (EDWOSB) concern" means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program. "Enforcement agency" means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are-- (1) Department of Labor Wage and Hour Division (WHD) for-- (i) The Fair Labor Standards Act; (ii) The Migrant and Seasonal Agricultural Worker Protection Act; (iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act; (v) 41 U.S.C. chapter 67, formerly known as the Service Contract Act; (vi) The Family and Medical Leave Act; and (vii) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors); (2) Department of Labor Occupational Safety and Health Administration (OSHA) for-- (i) The Occupational Safety and Health Act of 1970; and (ii) OSHA-approved State Plans; (4) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for- - (i) Section 503 of the Rehabilitation Act of 1973; (ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and (iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity); (5) National Labor Relations Board (NLRB) for the National Labor Relations Act; and (6) Equal Employment Opportunity Commission (EEOC) for-- (i) Title VII of the Civil Rights Act of 1964; (ii) The Americans with Disabilities Act of 1990; (iii) The Age Discrimination in Employment Act of 1967; and (iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act). "Forced or indentured child labor" means all work or service- (1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or (2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties. "Highest-level owner" means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner. "Immediate owner" means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees. "Inverted domestic corporation," means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c). "Labor compliance agreement" means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters. "Labor laws" means the following labor laws and E.O.s: (1) The Fair Labor Standards Act. (2) The Occupational Safety and Health Act (OSHA) of 1970. (3) The Migrant and Seasonal Agricultural Worker Protection Act. (4) The National Labor Relations Act. (5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act. (6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act. (7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity). (8) Section 503 of the Rehabilitation Act of 1973. (9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974. (10) The Family and Medical Leave Act. (11) Title VII of the Civil Rights Act of 1964. (12) The Americans with Disabilities Act of 1990. (13) The Age Discrimination in Employment Act of 1967. (14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors). (15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html). "Labor law decision" means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of "labor laws". "Manufactured end product" means any end product in product and service codes (PSCs) 1000- 9999, except- (1) PSC 5510, Lumber and Related Basic Wood Materials; (2) Product or Service Group (PSG) 87, Agricultural Supplies; (3) PSG 88, Live Animals; (4) PSG 89, Subsistence; (5) PSC 9410, Crude Grades of Plant Materials; (6) PSC 9430, Miscellaneous Crude Animal Products, Inedible; (7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products; (8) PSC 9610, Ores; (9) PSC 9620, Minerals, Natural and Synthetic; and (10) PSC 9630, Additive Metal Materials. "Place of manufacture" means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture. "Predecessor" means an entity that is replaced by a successor and includes any predecessors of the predecessor. "Restricted business operations" means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate- (1) Are conducted under contract directly and exclusively with the regional government of southern Sudan; (2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization; (3) Consist of providing goods or services to marginalized populations of Sudan; (4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization; (5) Consist of providing goods or services that are used only to promote health or education; or (6) Have been voluntarily suspended. Sensitive technology- (1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically- (i) To restrict the free flow of unbiased information in Iran; or (ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and (2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)). "Service-disabled veteran-owned small business concern"- (1) Means a small business concern- (i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and (ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran. (2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16). "Small business concern" means a concern, including its affiliates that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation. "Small disadvantaged business concern, consistent with 13 CFR 124.1002," means a small business concern under the size standard applicable to the acquisition, that-- (1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by-- (i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and (ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and (2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition. "Subsidiary" means an entity in which more than 50 percent of the entity is owned- (1) Directly by a parent corporation; or (2) Through another subsidiary of a parent corporation. "Successor" means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term "successor" does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances. "Veteran-owned small business concern" means a small business concern- (1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and (2) The management and daily business operations of which are controlled by one or more veterans. "Women-owned business concern" means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women. "Women-owned small business concern" means a small business concern -- (1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and (2) Whose management and daily business operations are controlled by one or more women. "Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127)," means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States. Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: "Administrative merits determination", "Arbitral award or decision", paragraph (2) of "Civil judgment", "DOL Guidance", "Enforcement agency", "Labor compliance agreement", "Labor laws", and "Labor law decision". The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. (b) (1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAMwebsite. (2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representation and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications-Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs. [Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.] (c) ) Offerors must complete the following representations when the resulting contract is to be performed in the United States or its outlying areas. Check all that apply. (1) Small business concern. The offeror represents as part of its offer that it [_] is, [_] is not a small business concern. (2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [_] is, [_] is not a veteran-owned small business concern. (3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it [_] is, [_] is not a service- disabled veteran-owned small business concern. (4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [_] is, [_] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002. (5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [_] is, [_] is not a women-owned small business concern. Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold. (6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that- (i) It [_] is, [_] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and (ii) It [_] is, [_] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture:.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation. (7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that- (i) It [_] is, [_] is not an EDWOSB concern, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and (ii) It [_] is, [_] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture:.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation. (8) Women-owned business concern (other than small business concern). [Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [_] is, a women-owned business concern. (9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price: (10) HUBZone small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that-- (i) It [_] is, [_] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and (ii) It [_] is, [_] is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture:.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation. (d) Representations required to implement provisions of Executive Order 11246 -- (1) Previous contracts and compliance. The offeror represents that -- (i) It [_] has, [_] has not, participated in a previous contract or subcontract subject to the Equal Opportunity clause of this solicitation; and (ii) It [_] has, [_] has not, filed all required compliance reports. (2) Affirmative Action Compliance. The offeror represents that -- (i) It [_] has developed and has on file, [_] has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 CFR parts 60-1 and 60-2), or (ii) It [_] has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor. (e) ) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made. (f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy American - Supplies, is included in this solicitation.) (1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of "domestic end product." The terms "commercially available off-the-shelf (COTS) item," "component," "domestic end product," "end product," "foreign end product," and "United States" are defined in the clause of this solicitation entitled "Buy American-Supplies." (2) Foreign End Products: LINE ITEM NO. COUNTRY OF ORIGIN [List as necessary] (3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. (g) (1) Buy American -- Free Trade Agreements -- Israeli Trade Act Certificate. (Applies only if the clause at FAR 52.225-3, Buy American -- Free Trade Agreements -- Israeli Trade Act, is included in this solicitation.) (i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms "Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product," "commercially available off-the-shelf (COTS) item," "component," "domestic end product," "end product," "foreign end product," "Free Trade Agreement country," "Free Trade Agreement country end product," "Israeli end product," and "United States" are defined in the clause of this solicitation entitled "Buy American--Free Trade Agreements--Israeli Trade Act." (ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act": Free Trade Agreement Country End Products (Other than Bahrainian, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products: [List as necessary] (iii) The offeror shall list those supplies that are foreign end products (other than those listed in paragraph (g)(1)(ii) or this provision) as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act." The offeror shall list as other foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of "domestic end product." Other Foreign End Products: LINE ITEM NO. COUNTRY OF ORIGIN [List as necessary] (iv) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. (2) Buy American-Free Trade Agreements-Israeli Trade Act Certificate, Alternate I. If Alternate I to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Canadian end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act": Canadian End Products: Line Item No.: [List as necessary] (3) Buy American-Free Trade Agreements-Israeli Trade Act Certificate, Alternate II. If Alternate II to the clause at FAR 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Canadian end products or Israeli end products as defined in the clause of this solicitation entitled "Buy American--Free Trade Agreements--Israeli Trade Act'': Canadian or Israeli End Products: Line Item No.: Country of Origin: [List as necessary] (4) Buy American-Free Trade Agreements-Israeli Trade Act Certificate, Alternate III. If Alternate III to the clause at 52.225-3 is included in this solicitation, substitute the following paragraph (g)(1)(ii) for paragraph (g)(1)(ii) of the basic provision: (g)(1)(ii) The offeror certifies that the following supplies are Free Trade Agreement country end products (other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian end products) or Israeli end products as defined in the clause of this solicitation entitled "Buy American-Free Trade Agreements-Israeli Trade Act": Free Trade Agreement Country End Products (Other than Bahrainian, Korean, Moroccan, Omani, Panamanian, or Peruvian End Products) or Israeli End Products: Line Item No.: Country of Origin: [List as necessary] (5) Trade Agreements Certificate. (Applies only if the clause at FAR 52.225-5, Trade Agreements, is included in this solicitation.) (i) The offeror certifies that each end product, except those listed in paragraph (g)(5)(ii) of this provision, is a U.S.-made or designated country end product as defined in the clause of this solicitation entitled "Trade Agreements." (ii) The offeror shall list as other end products those end products that are not U.S.-made or designated country end products. Other End Products Line Item No.: Country of Origin: [List as necessary] (iii) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25. For line items covered by the WTO GPA, the Government will evaluate offers of U.S.-made or designated country end products without regard to the restrictions of the Buy American statute. The Government will consider for award only offers of U.S.-made or designated country end products unless the Contracting Officer determines that there are no offers for such products or that the offers for such products are insufficient to fulfill the requirements of the solicitation. (h) Certification Regarding Responsibility Matters (Executive Order 12689). (Applies only if the contract value is expected to exceed the simplified acquisition threshold.) The offeror certifies, to the best of its knowledge and belief, that the offeror and/or any of its principals-- (1) [_] Are, [_] are not presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency; (2) [_] Have, [_] have not, within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a Federal, state or local government contract or subcontract; violation of Federal or state antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property; and (3) [_] Are, [_] are not presently indicted for, or otherwise criminally or civilly charged by a Government entity with, commission of any of these offenses enumerated in paragraph (h)(2) of this clause; and (4) [_] Have, [_] have not, within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied. (i) Taxes are considered delinquent if both of the following criteria apply: (A) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted. (B) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded. (ii) Examples. (A) The taxpayer has received a statutory notice of deficiency, under I.R.C. §6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appear rights. (B) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. §6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals Contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights. (C) The taxpayer has entered into an installment agreement pursuant to I.R.C. §6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment. (D) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. §362 (the Bankruptcy Code). (i) Certification Regarding Knowledge of Child Labor for Listed End Products (Executive Order 13126). [The Contracting Officer must list in paragraph (i)(1) any end products being acquired under this solicitation that are included in the List of Products Requiring Contractor Certification as to Forced or Indentured Child Labor, unless excluded at 22.1503(b).] (1) Listed End Product Listed End Product: Listed Countries of Origin: (2) Certification. [If the Contracting Officer has identified end products and countries of origin in paragraph (i)(1) of this provision, then the offeror must certify to either (i)(2)(i) or (i)(2)(ii) by checking the appropriate block.] [_] (i) The offeror will not supply any end product listed in paragraph (i)(1) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product. [_] (ii) The offeror may supply an end product listed in paragraph (i)(1) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product. The offeror certifies that is has made a good faith effort to determine whether forced or indentured child labor was used to mine, produce, or manufacture any such end product furnished under this contract. On the basis of those efforts, the offeror certifies that it is not aware of any such use of child labor. (j) Place of manufacture. (Does not apply unless the solicitation is predominantly for the acquisition of manufactured end products.) For statistical purposes only, the offeror shall indicate whether the place of manufacture of the end products it expects to provide in response to this solicitation is predominantly- (1) [_] In the United States (Check this box if the total anticipated price of offered end products manufactured in the United States exceeds the total anticipated price of offered end products manufactured outside the United States); or (2) [_] Outside the United States. (k) Certificates regarding exemptions from the application of the Service Contract Labor Standards. (Certification by the offeror as to its compliance with respect to the contract also constitutes its certification as to compliance by its subcontractor if it subcontracts out the exempt services.) [The contracting officer is to check a box to indicate if paragraph (k)(1) or (k)(2) applies.] (1) [_] Maintenance, calibration, or repair of certain equipment as described in FAR 22.1003-4(c)(1). The offeror [_] does [_] does not certify that- (i) The items of equipment to be serviced under this contract are used regularly for other than Governmental purposes and are sold or traded by the offeror (or subcontractor in the case of an exempt subcontract) in substantial quantities to the general public in the course of normal business operations; (ii) The services will be furnished at prices which are, or are based on, established catalog or market prices (see FAR 22.1003-4(c)(2)(ii)) for the maintenance, calibration, or repair of such equipment; and (iii) The compensation (wage and fringe benefits) plan for all service employees performing work under the contract will be the same as that used for these employees and equivalent employees servicing the same equipment of commercial customers. (2) [_] Certain services as described in FAR 22.1003-4(d)(1). The offeror [_] does [_] does not certify that- (i) The services under the contract are offered and sold regularly to non- Governmental customers, and are provided by the offeror (or subcontractor in the case of an exempt subcontract) to the general public in substantial quantities in the course of normal business operations; (ii) The contract services will be furnished at prices that are, or are based on, established catalog or market prices (see FAR 22.1003-4(d)(2)(iii)); (iii) Each service employee who will perform the services under the contract will spend only a small portion of his or her time (a monthly average of less than 20 percent of the available hours on an annualized basis, or less than 20 percent of available hours during the contract period if the contract period is less than a month) servicing the Government contract; and (iv) The compensation (wage and fringe benefits) plan for all service employees performing work under the contract is the same as that used for these employees and equivalent employees servicing commercial customers. (3) If paragraph (k)(1) or (k)(2) of this clause applies- (i) If the offeror does not certify to the conditions in paragraph (k)(1) or (k)(2) and the Contracting Officer did not attach a Service Contract Labor Standards wage determination to the solicitation, the offeror shall notify the Contracting Officer as soon as possible; and (ii) The Contracting Officer may not make an award to the offeror if the offeror fails to execute the certification in paragraph (k)(1) or (k)(2) of this clause or to contact the Contracting Officer as required in paragraph (k)(3)(i) of this clause. (l) Taxpayer identification number (TIN) (26 U.S.C. 6109, 31 U.S.C. 7701). (Not applicable if the offeror is required to provide this information to the SAM database to be eligible for award.) (1) All offerors must submit the information required in paragraphs (l)(3) through (l)(5) of this provision to comply with debt collection requirements of 31 U.S.C. 7701(c) and 3325(d), reporting requirements of 26 U.S.C. 6041, 6041A, and 6050M, and implementing regulations issued by the Internal Revenue Service (IRS). (2) The TIN may be used by the government to collect and report on any delinquent amounts arising out of the offeror's relationship with the Government (31 U.S.C. 7701(c)(3)). If the resulting contract is subject to the payment reporting requirements described in FAR 4.904, the TIN provided hereunder may be matched with IRS records to verify the accuracy of the offeror's TIN. (3) Taxpayer Identification Number (TIN). [_] TIN:. [_] TIN has been applied for. [_] TIN is not required because: [_] Offeror is a nonresident alien, foreign corporation, or foreign partnership that does not have income effectively connected with the conduct of a trade or business in the United States and does not have an office or place of business or a fiscal paying agent in the United States; [_] Offeror is an agency or instrumentality of a foreign government; [_] Offeror is an agency or instrumentality of the Federal Government; (4) Type of organization. [_] Sole proprietorship; [_] Partnership; [_] Corporate entity (not tax-exempt); [_] Corporate entity (tax-exempt); [_] Government entity (Federal, State, or local); [_] Foreign government; [_] International organization per 26 CFR 1.6049-4; [_] Other. (5) Common parent. [_] Offeror is not owned or controlled by a common parent: [_] Name and TIN of common parent: Name TIN (m) Restricted business operations in Sudan. By submission of its offer, the offeror certifies that the offeror does not conduct any restricted business operations in Sudan. (n) Prohibition on Contracting with Inverted Domestic Corporations- (1) Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation, unless the exception at 9.108-2(b) applies or the requirement is waived in accordance with the procedures at 9.108-4. (2) Representation. The offeror represents that- (i) It [ ] is, [ ] is not an inverted domestic corporation; and (ii) It [ ] is, [ ] is not a subsidiary of an inverted domestic corporation. (o) Prohibition on contracting with entities engaging in certain activities or transactions relating to Iran. (1) The offeror shall email questions concerning sensitive technology to the Department of State at CISADA106@state.gov. (2) Representation and Certification. Unless a waiver is granted or an exception applies as provided in paragraph (o)(3) of this provision, by submission of its offer, the offeror- (i) Represents, to the best of its knowledge and belief, that the offeror does not export any sensitive technology to the government of Iran or any entities or individuals owned or controlled by, or acting on behalf or at the direction of, the government of Iran; (ii) Certifies that the offeror, or any person owned or controlled by the offeror, does not engage in any activities for which sanctions may be imposed under section 5 of the Iran Sanctions Act; and (iii) Certifies that the offeror, and any person owned or controlled by the offeror, does not knowingly engage in any transaction that exceeds $3,500 with Iran's Revolutionary Guard Corps or any of its officials, agents, or affiliates, the property and interests in property of which are blocked pursuant to the International Emergency Economic Powers Act (50(U.S.C. 1701 et seq.) (see OFAC's Specially Designated Nationals and Blocked Persons List at http://www.treasury.gov/ofac/downloads/t11sdn.pdf). (3) The representation and certification requirements of paragraph (o)(2) of this provision do not apply if- (i) This solicitation includes a trade agreements certification (e.g., 52.212-3(g) or a comparable agency provision); and (ii) The offeror has certified that all the offered products to be supplied are designated country end products. (p) Ownership or Control of Offeror. (Applies in all solicitations when there is a requirement to be registered in SAM or a requirement to have a unique entity identifier in the solicitation. (1) The Offeror represents that it [ ] has or [ ] does not have an immediate owner. If the Offeror has more than one immediate owner (such as a joint venture), then the Offeror shall respond to paragraph (2) and if applicable, paragraph (3) of this provision for each participant in the joint venture. (2) If the Offeror indicates "has" in paragraph (p)(1) of this provision, enter the following information: Immediate owner CAGE code: Immediate owner legal name: (Do not use a "doing business as" name) Is the immediate owner owned or controlled by another entity: [ ] Yes or [ ] No. (3) If the Offeror indicates "yes" in paragraph (p)(2) of this provision, indicating that the immediate owner is owned or controlled by another entity, then enter the following information: Highest level owner CAGE code: Highest level owner legal name: (Do not use a "doing business as" name) (q) Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. (1) As required by section 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that- (i) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless and agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or (ii) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government. (2) The Offeror represents that-- (i) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and (ii) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months. (r) ) Predecessor of Offeror. (Applies in all solicitations that include the provision at 52.204-16, Commercial and Government Entity Code Reporting.) (1) The Offeror represents that it [ ] is or [ ] is not a successor to a predecessor that held a Federal contract or grant within the last three years. (2) If the Offeror has indicated "is" in paragraph (r)(1) of this provision, enter the following information for all predecessors that held a Federal contract or grant within the last three years (if more than one predecessor, list in reverse chronological order): Predecessor CAGE code (or mark "Unknown). Predecessor legal name:. (Do not use a "doing business as" name). (s) Representation regarding compliance with labor laws (Executive Order 13673). If the offeror is a joint venture that is not itself a separate legal entity, each concern participating in the joint venture shall separately comply with the requirements of this provision. (1)(i) For solicitations issued on or after October 25, 2016 through April 24, 2017: The Offeror [ ] does [ ] does not anticipate submitting an offer with an estimated contract value of greater than $50 million. (ii) For solicitations issued after April 24, 2017: The Offeror [ ] does [ ] does not anticipate submitting an offer with an estimated contract value of greater than $500,000. (2) If the Offeror checked ``does'' in paragraph (s)(1)(i) or (ii) of this provision, the Offeror represents to the best of the Offeror's knowledge and belief [Offeror to check appropriate block]: [ ](i) There has been no administrative merits determination, arbitral award or decision, or civil judgment for any labor law violation(s) rendered against the offeror (see definitions in paragraph (a) of this section) during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter; or [ ](ii) There has been an administrative merits determination, arbitral award or decision, or civil judgment for any labor law violation(s) rendered against the Offeror during the period beginning on October 25, 2015 to the date of the offer, or for three years preceding the date of the offer, whichever period is shorter. (3)(i) If the box at paragraph (s)(2)(ii) of this provision is checked and the Contracting Officer has initiated a responsibility determination and has requested additional information, the Offeror shall provide-- (A) The following information for each disclosed labor law decision in the System for Award Management (SAM) at www.sam.gov, unless the information is already current, accurate, and complete in SAM. This information will be publicly available in the Federal Awardee Performance and Integrity Information System (FAPIIS): (1) The labor law violated. (2) The case number, inspection number, charge number, docket number, or other unique identification number. (3) The date rendered. (4) The name of the court, arbitrator(s), agency, board, or commission that rendered the determination or decision; (B) The administrative merits determination, arbitral award or decision, or civil judgment document, to the Contracting Officer, if the Contracting Officer requires it; (C) In SAM, such additional information as the Offeror deems necessary to demonstrate its responsibility, including mitigating factors and remedial measures such as offeror actions taken to address the violations, labor compliance agreements, and other steps taken to achieve compliance with labor laws. Offerors may provide explanatory text and upload documents. This information will not be made public unless the contractor determines that it wants the information to be made public; and (D) The information in paragraphs (s)(3)(i)(A) and (s)(3)(i)(C) of this provision to the Contracting Officer, if the Offeror meets an exception to SAM registration (see FAR 4.1102(a)). (ii)(A) The Contracting Officer will consider all information provided under (s)(3)(i) of this provision as part of making a responsibility determination. (B) A representation that any labor law decision(s) were rendered against the Offeror will not necessarily result in withholding of an award under this solicitation. Failure of the Offeror to furnish a representation or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible. (C) The representation in paragraph (s)(2) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous representation, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation in accordance with the procedures set forth in FAR 12.403. (4) The Offeror shall provide immediate written notice to the Contracting Officer if at any time prior to contract award the Offeror learns that its representation at paragraph (s)(2) of this provision is no longer accurate. (5) The representation in paragraph (s)(2) of this provision will be public information in the Federal Awardee Performance and Integrity Information System (FAPIIS). Note to paragraph (s): By a court order issued on October 24, 2016, this paragraph (s) is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. (t) Public Disclosure of Greenhouse Gas Emissions and Reduction Goals. Applies in all solicitations that require offerors to register in SAM (52.212-1(k)). (1) This representation shall be completed if the Offeror received $7.5 million or more in contract awards in the prior Federal fiscal year. The representation is optional if the Offeror received less than $7.5 million in Federal contract awards in the prior Federal fiscal year. (2) Representation. [Offeror to check applicable block(s) in paragraph (t)(2)(i) and (ii)]. (i) The Offeror (itself or through its immediate owner or highest-level owner) [ ] does, [ ] does not publicly disclose greenhouse gas emissions, i.e., makes available on a publicly accessible Web site the results of a greenhouse gas inventory, performed in accordance with an accounting standard with publicly available and consistently applied criteria, such as the Greenhouse Gas Protocol Corporate Standard. (ii) The Offeror (itself or through its immediate owner or highest-level owner) [ ] does, [ ] does not publicly disclose a quantitative greenhouse gas emissions reduction goal, i.e., make available on a publicly accessible Web site a target to reduce absolute emissions or emissions intensity by a specific quantity or percentage. (iii) A publicly accessible Web site includes the Offeror's own Web site or a recognized, third-party greenhouse gas emissions reporting program. (3) If the Offeror checked ``does'' in paragraphs (t)(2)(i) or (t)(2)(ii) of this provision, respectively, the Offeror shall provide the publicly accessible Web site(s) where greenhouse gas emissions and/or reduction goals are reported:. (u) (1) In accordance with section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions), Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with an entity that requires employees or subcontractors of such entity seeking to report waste, fraud, or abuse to sign internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting such waste, fraud, or abuse to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information. (2) The prohibition in paragraph (u)(1) of this provision does not contravene requirements applicable to Standard Form 312 (Classified Information Nondisclosure Agreement), Form 4414 (Sensitive Compartmented Information Nondisclosure Agreement), or any other form issued by a Federal department or agency governing the nondisclosure of classified information. (3) Representation. By submission of its offer, the Offeror represents that it will not require its employees or subcontractors to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting waste, fraud, or abuse related to the performance of a Government contract to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information (e.g., agency Office of the Inspector General). (End of Provision) Alternate I (Oct 2014). As prescribed in 12.301(b)(2), add the following paragraph (c)(11) to the basic provision: (11) (Complete if the offeror has represented itself as disadvantaged in paragraph (c)(4) of this provision.) [The offeror shall check the category in which its ownership falls]: Black American. Hispanic American. Native American (American Indians, Eskimos, Aleuts, or Native Hawaiians). Asian-Pacific American (persons with origins from Burma, Thailand, Malaysia, Indonesia, Singapore, Brunei, Japan, China, Taiwan, Laos, Cambodia (Kampuchea), Vietnam, Korea, The Philippines, Republic of Palau, Republic of the Marshall Islands, Federated States of Micronesia, the Commonwealth of the Northern Mariana Islands, Guam, Samoa, Macao, Hong Kong, Fiji, Tonga, Kiribati, Tuvalu, or Nauru). Subcontinent Asian (Asian-Indian) American (persons with origins from India, Pakistan, Bangladesh, Sri Lanka, Bhutan, the Maldives Islands, or Nepal). Individual/concern, other than one of the preceding. (xi) FAR 52.212-4 CONTRACT TERMS AND CONDITIONS - COMMERCIAL ITEMS (JAN 2017) ADDENDUM FAR 52.203-17 CONTRACTOR EMPLOYEE WHISTLEBLOWER RIGHTS AND REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS (APR 2014) (a) This contract and employees working on this contract will be subject to the whistleblower rights and remedies in the pilot program on Contractor employee whistleblower protections established at 41 U.S.C. 4712 by section 828 of the National Defense Authorization Act for Fiscal Year 2013 (Pub. L. 112-239) and FAR 3.908. (b) The Contractor shall inform its employees in writing, in the predominant language of the workforce, of employee whistleblower rights and protections under 41 U.S.C. 4712, as described in section 3.908 of the Federal Acquisition Regulation. (c) The Contractor shall insert the substance of this clause, including this paragraph (c), in all subcontracts over the simplified acquisition threshold. (End of clause) 52.204-21 - Basic Safeguarding of Covered Contractor Information Systems (Jun 2016) (a) Definitions. As used in this clause-- "Covered contractor information system" means an information system that is owned or operated by a contractor that processes, stores, or transmits Federal contract information. "Federal contract information" means information, not intended for public release, that is provided by or generated for the Government under a contract to develop or deliver a product or service to the Government, but not including information provided by the Government to the public (such as on public Web sites) or simple transactional information, such as necessary to process payments. "Information" means any communication or representation of knowledge such as facts, data, or opinions, in any medium or form, including textual, numerical, graphic, cartographic, narrative, or audiovisual (Committee on National Security Systems Instruction (CNSSI) 4009). "Information system" means a discrete set of information resources organized for the collection, processing, maintenance, use, sharing, dissemination, or disposition of information (44 U.S.C. 3502). "Safeguarding" means measures or controls that are prescribed to protect information systems. (b) Safeguarding requirements and procedures. (1) The Contractor shall apply the following basic safeguarding requirements and procedures to protect covered contractor information systems. Requirements and procedures for basic safeguarding of covered contractor information systems shall include, at a minimum, the following security controls: (i) Limit information system access to authorized users, processes acting on behalf of authorized users, or devices (including other information systems). (ii) Limit information system access to the types of transactions and functions that authorized users are permitted to execute. (iii) Verify and control/limit connections to and use of external information systems. (iv) Control information posted or processed on publicly accessible information systems. (v) Identify information system users, processes acting on behalf of users, or devices. (vi) Authenticate (or verify) the identities of those users, processes, or devices, as a prerequisite to allowing access to organizational information systems. (vii) Sanitize or destroy information system media containing Federal Contract Information before disposal or release for reuse. (viii) Limit physical access to organizational information systems, equipment, and the respective operating environments to authorized individuals. (ix) Escort visitors and monitor visitor activity; maintain audit logs of physical access; and control and manage physical access devices. (x) ) Monitor, control, and protect organizational communications (i.e., information transmitted or received by organizational information systems) at the external boundaries and key internal boundaries of the information systems. (xi) Implement subnetworks for publicly accessible system components that are physically or logically separated from internal networks. (xii) Identify, report, and correct information and information system flaws in a timely manner. (xiii) ) Provide protection from malicious code at appropriate locations within organizational information systems. (xiv) Update malicious code protection mechanisms when new releases are available. (xv) Perform periodic scans of the information system and real-time scans of files from external sources as files are downloaded, opened, or executed. (2) Other requirements. This clause does not relieve the Contractor of any other specific safeguarding requirements specified by Federal agencies and departments relating to covered contractor information systems generally or other Federal safeguarding requirements for controlled unclassified information (CUI) as established by Executive Order 13556. (c) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (c), in subcontracts under this contract (including subcontracts for the acquisition of commercial items, other than commercially available off-the-shelf items), in which the subcontractor may have Federal contract information residing in or transiting through its information system. (End of clause) VOLATILE ORGANIC COMPOUNDS (VOC) REGULATIONS (a) ) Contractors are required to comply with federal, state and local VOC compliance laws and regulations. Among other requirements, certain Contractors may also be required to operate pursuant to a Title V permit. The need for such a permit will depend on the provisions of the applicable state's "State Implementation Plan" (SIP) and the type/quantity of the Contractor's regulated emissions, including VOCs. Certain SIPs may also mandate certain Contractors to operate under the terms of a compliance plan intended to reduce VOC emissions. (b) Contractors, therefore, must submit the following to the designated Port Engineer not later than two weeks after contract award: 1) Copies of any federal, state or local permits required and applicable to the use or application of VOCs at Contractor's facility or offsite work places; 2) Copies of any compliance plans required and applicable to the use or application of VOCs at Contractor's facility or offsite work places. (c) If no federal, state or local permits or compliance plans are required and applicable to the use or application of VOCs at Contractor's facility or offsite workplaces, then Contractor shall submit to the designated Port Engineer a letter, notarized under oath, that such documents are not required. (d) Contractors will submit the following to the designated Port Engineer not later than two weeks after contract award: Data Sheets (MSDS) documents, certificates, specifications or any other manufacturing data verifying the VOC ratings of paints to be applied to the Cutter in accordance with SFLC Standard Spec 63000, Section 5.3.1. REQUIRED INSURANCE The Contractor shall, at its own expense, procure and maintain the following kinds of insurance with respect to performance under the contract. In accordance with HSAR 3052.228-70, Insurance (DEC 2003), the Contractor shall furnish the Contracting Officer with proof of insurance for the duration of the contract, including: 1. Ship Repairer's Liability - $500,000 per occurrence. 2. Comprehensive General Liability - $500,000 per occurrence. 3. Full insurance coverage in accordance with the United States' Longshoremen's and Harbor Worker's Act. 4. Full insurance coverage in accordance with the State's Workmen's Compensation Law (or its equivalent) for all places of performance under this contract. The insurance certificate must provide the name of the US Coast Guard vessel and the contract and/or solicitation number as specifically insured. INDEMNIFICATION FOR ACCESS TO VESSELS Notwithstanding any provision in the "Access to Vessels" clause, or any other clause of the contract, the Contractor agrees to allow officers, employees, and associates of the Government, or other Prime Contractors with the Government and their Sub Contractors, and officers, employees, and associates of quoters on other contemplated work, admission to the Contractor's facilities and access to the vessel without any further request for indemnification from any party, which has not been previously included in the contract price. INSPECTIONS Except as specified elsewhere, the U.S. Coast Guard shall rely on the Contractor to accomplish all inspection and testing needed to ensure that the work conforms IAW the Specification, SFLC Standard Specifications contract quality requirements. Records of all inspection work by the Contractor shall be kept complete and available to the Government during the term of this contract and for such longer period as may be specified elsewhere in this contract. The name and telephone number of the U.S. Coast Guard Inspector will be provided after the award of a contract resulting from this solicitation. GROWTH WORK (a) The Contractor shall not perform growth work without the Contracting Officer's authorization. Growth work is work within the scope of the contract, which has not been previously priced as a pre-priced CLIN. The Contracting Officer reserves the right to contract for growth work on the basis of a negotiated, firm, fixed price, when it is in the best interest of the Government. If a firm-fixed price contract is awarded, and during the performance period a repair within scope is identified but the Contracting Officer and Contractor are unable to agree on the cost of the work, a bilateral modification may be incorporated into the contract using a Time and Materials modification for this specific repair. In this situation, FAR 52.212-4, Alternate I, will be incorporated. (b) The Contractor shall furnish a price breakdown directly to the Contracting Officer, itemized as required by the Contracting Officer, of any proposal submitted for a contract modification. Unless otherwise directed, the breakdown shall be submitted be IAW the example of the SFLC-PDM-024 form provided at the arrival conference permitting an analysis of all materials, labor, equipment, subcontract, overhead costs, and profit covering all work involved in the change. Any amount claimed for subcontracting shall be supported the subcontractor's separate form with the similar price breakdown. If the proposal includes a request for a time extension, justification shall be furnished with the proposal. (c) This clause is to be used in conjunction with the clause COMPOSITE LABOR RATE incorporated into this solicitation. **The Contractor is required to have and/or furnish all tools and equipment incidental to each bench trade. Supplies such as wiping rags, hacksaw blades, sandpaper, welding wire, helium, etc., are also to be furnished by the Contractor and shall be included in the Composite Labor Rate. Other materials are to be charged at regular rates and prices currently in effect and as agreed to by the Contracting Officer. Material shall be best commercial quality available except where a precise specification is indicated in which case the specification shall apply, e.g., MILSPEC, FEDERAL SPEC. DISCOVERIES AND CHANGES TO CONTRACT: Work requests can be transmitted electronically by using email. The bullets below display the process of how work requests are to be followed during the availability: Work Request Process will occur in the following order: 1. Condition Found Report (CFR)-Generated by the Contractor and provided to COR 2. Condition Report Reply(CRR)-Generated by the COR and provided to Contractor 3. Change Request (CR) and IGE are generated by the COR and forwarded to KO 4. COR provides copy of Change Request to the Contractor 5. Contractor's Proposal- Provided to the KO (ONLY) for the identified tasking on CR 6. Negotiations- If needed, take place to establish pricing 7. Approved Change Request- Forwarded to Contractor and COR by the KO 8. Modification to Contract- The KS/KO will issue a modification covering all CR's In order to determine price reasonableness: All change requests that list sub-contracting and/or material must have a written proposal from the sub-contractor or the company providing the material with complete, detailed information (listing number of hours/price per hour; each part/component & associated cost; and an estimated shipping cost). COMPOSITE LABOR RATE: The composite labor rate offered shall be the sole labor hour rate used to price the Prime Contractor's direct labor hours for contract changes, i.e. growth work. The Contractor shall not receive any compensation in addition to this rate for the Prime Contractor's direct labor associated with such changes under this contract. (a) The composite labor hour rate shall represent total compensation for the following: (1) direct labor wages and salaries; (2) all employee benefits including, but not limited to, paid leave, supplemental pay, insurance, retirement, savings, and legally required benefits; (3) other direct costs associated with transit time, delay, disruption, expendable supplies, and equipment; (4) all indirect costs such as overhead and general and administrative expense; (5) any port or association fees, rents, or other levies; (6) profit (fee); (7) all direct and indirect costs and profit associated with the following support functions: Supervision and Management Planning and Estimating Material Handling Housekeeping Engineering Transportation/Drivers Quality Assurance Contract Administration Security Testing (8) **all consumables (see paragraph c under Growth Work); (b) The composite labor hour rate will be applied to production labor hours only. Production labor hours include only those hours necessary and reasonable to perform direct production functions and do not include the hours expended on the support functions listed above. This exclusion of support function hours applies whether such support functions are normally charged directly or indirectly by the Contractor's accounting system. These support functions are to be priced into the composite labor rate quoted and shall not be separately compensated. (c) The Quantity of Composite Labor hours indicated in the Schedule of Supplies/Services is only an estimate and is an Optional Item pursuant to this solicitation. The Estimated Quantity represents the Government's best estimate of the total number of additional hours that may be required throughout the contract. The Government may elect to exceed this value at the prices stated in the schedule and its discretion during performance of the contract. The inclusion of this item does not obligate the Government to exercise the item nor entitle the Contractor to compensation if not exercised. MAINTAINING, REPORTING, AND DISPOSING OF GOVERNMENT PROPERTY IN THE PERFORMANCE OF A SHIP REPAIR CONTRACT 1. The Government Property Clause incorporated by reference delineates the Contractor's overall responsibility when taking possession of government property in performance of a contract. In performance of this contract the Contractor will be required to properly identify, track and control property within its possession. This includes, a) property furnished by the government (GFP) to the Contractor in conjunction with specific CLIN Items. These items and their values are listed in the specification, b) property that is pre-existing in a location that during the course of performance will be replaced or renewed. 2. The items listed in the specification, as government furnished property will be provided in the quantities designated. Government furnished property may be provided in person by an official Coast Guard employee, shipment via commercial carrier, etc. The Contractor shall sign for all govern ment furnish ed property using either a DD For m 1149, entitled, "Requisition and Invoice/S hippin g Document" or a DD Form 13 48, entitled, "Issu e Rele ase /Receipt Docu ment". A copy of the DD 1149 or D D 134 8 must be sent within 48 hours of receip t of property, to the designated Government Property Administrator. The name of the individual assigned as Property Administrator will be furnished to the Contractor at time of award. The Contractor shall not take receipt of property that is not listed in the specification, has not been previously identified as becoming part of the contract (via contract modification) or which otherwise cannot be identified. Such irregularities shall be immediately reported to the Property Administrator. 3. The Contractor shall complete the report provided herein, entitled, "Government Property Report". This report is intended as a living document whereby relevant fields shall be filled in, maintained and kept current at all times. All property described in paragraph 1 (a and b) above shall be reported on the report. At contract completion the Contractor and the Property Administrator shall ensure that all fields are appropriately completed. A signature block is provided at the end of the report for both parties to attest to the report's accuracy and completeness. The Government Property Report shall clearly delineate the complete track that all Government property took over the course of the contract. This completed report must accompany the Contractor's final invoice. Final payment may be delayed, without penalty of interest, until such time as the report is received. A separate copy of the completed report and any final DD 1149s or DD 1348s executed, as a result of carrying out disposition instructions shall be provided to the Property Administrator. 4. Pursuant to the Government Property Clause the authority to render disposition instructions of Government property associated with this contract is delegated to the Property Administrator. The Contractor shall comply with all instructions in the contract for the return of government property to the Coast Guard. This includes government property taken off the vessel (shafts, propellers, etc.), government property returned to the vessel (special tools, etc.) or surplus government property not used during performance of the contract. CONTRACTING OFFICER'S AUTHORITY No oral or written statement of any person other than the Contracting Officer will in any manner or degree modify or otherwise affect the terms of this contract. The Contracting Officer is the only person authorized to approve changes in any of the requirements under this contract, and, notwithstanding any provisions contained elsewhere in this contract, said authority remains solely with the Contracting Officer. In the event the Contractor effects any such change at the direction of any person other than the Contracting Officer, the change will be considered to have been made without authority and no adjustment will be made in the contract price to cover any increase in cost incurred as a result thereof. CONTRACTOR PERFORMANCE EVALUATION (a) GENERAL: The U.S. Coast Guard Surface Forces Logistic Center (SFLC) will monitor and evaluate the successful offeror's past performance of this contract and prepare a Contractor Performance Assessment Report (CPAR) in accordance with FAR Part 42.15. All information contained in this assessment may be used, within the limitations of FAR 42.15, by the government for future source selections and in accordance with FAR 15.304, when past performance is an evaluation factor for award. (b) NOTIFICATION: Upon completion of the contract, the Contractor will be notified of the assessment. The Contractor will be allowed 30 days to respond to the SLFC's assessment of its performance entered into CPARS. The Contractor's response, if any, will be made part of the CPAR system at https://www.cpars.csd.disa.mil. (c) INFORMATION: Information included in the CPAR may include, but is not limited to, the Contractor's record of conforming to contract requirements and to standards of good workmanship; the Contractor's record of forecasting and controlling costs; the Contractor's adherence to contract schedules, including the administrative aspects of performance; the Contractor's history of reasonable and cooperative behavior and commitment to customer satisfaction; the Contractor's record of integrity and business ethics, and generally, the Contractor's business-like concern for the interest of the customer. (d) RELEASE OF DATA: CPARS information is considered business sensitive and will not be released except: (1) to other Federal procurement activities which request it; (2) when SFLC must release pursuant to a Freedom of Information Act (FOIA) request; or (3) when prior written consent is requested and obtained from the Contractor. CONTRACT DEFICIENCY REPORT The Contracting Officer or Contracting Officer's Representative (COR) may issue a Contract Deficiency Report (CDR), SFLC-PDM-29. The Contractor shall respond in writing within 24 hours of receipt, unless otherwise approved by the Contracting Officer, to the COR. The COR will comment on the Contractor's response and will forward the Deficiency Report and comments to the Contracting Officer, with a copy to the Contractor and Availability Program Manager. The Contracting Officer will render a final determination and provide it to the Contractor and COR in writing. HSAR 3052.217-100 Guarantee (USCG). JUN 2006 (a) In the event any work performed or materials furnished by the contractor prove defective or deficient within 60 days from the date of redelivery of the vessel(s), the Contractor, as directed by the Contracting Officer and at its own expense, shall correct and repair the deficiency to the satisfaction of the Contracting Officer. (b) If the Contractor or any subcontractor has a guarantee for work performed or materials furnished that exceeds the 60 day period, the Government shall be entitled to rely upon the longer guarantee until its expiration. (c) ) With respect to any individual work item identified as incomplete at the time of redelivery of the vessel(s), the guarantee period shall run from the date the item is completed. (d) If practicable, the Government shall give the Contractor an opportunity to correct the deficiency. (1) If the Contracting Officer determines it is not practicable or is otherwise not advisable to return the vessel(s) to the Contractor, or the Contractor fails to proceed with the repairs promptly, the Contracting Officer may direct that the repairs be performed elsewhere, at the Contractor's expense. (2) If correction and repairs are performed by other than the Contractor, the Contracting Officer may discharge the Contractor's liability by making an equitable deduction in the price of the contract. (e) The Contractor's liability shall extend for an additional 60-day guarantee period on those defects or deficiencies that the Contractor corrected. (f) At the option of the Contracting officer, defects and deficiencies may be left uncorrected. In that event, the Contractor and Contracting Officer shall negotiate an equitable reduction in the contract price. Failure to agree upon an equitable reduction shall constitute a dispute under the Disputes clause of this contract. (End of clause) HSAR 3052.223-70 REMOVAL OR DISPOSAL OF HAZARDOUS SUBSTANCES - APPLICABLE LICENSES AND PERMITS (JUN 2006) The Contractor shall have all licenses and permits required by Federal, state, and local laws to perform hazardous substance(s) removal or disposal services. If the Contractor does not currently possess these documents, it shall obtain all requisite licenses and permits within ["insert days"] days after date of award. The Contractor shall provide evidence of said documents to the Contracting Officer or designated Government representative prior to commencement of work under the contract. (End of clause) FAR 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998) This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: http://www.arnet.gov/far/index.html HSAR 3052.212-70 CONTRACT TERMS AND CONDITIONS APPLICABLE TO DHS ACQUISITION OF COMMERCIAL ITEMS (SEP 2012) The Contractor agrees to comply with any provision or clause that is incorporated herein by reference to implement agency policy applicable to acquisition of commercial items or components. The provision or clause in effect based on the applicable regulation cited on the date the solicitation is issued applies unless otherwise stated herein. The following provisions and clauses are incorporated by reference: FAR 52.204-19 Incorporation by Reference of Representations and Certifications (DEC 2014) FAR 52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law (FEB 2016) FAR 52.223-3 Hazardous Material Identification and Material Safety Data (JAN 1997) Alternate I (JUL 1995) FAR 52.223-12 Refrigeration Equipment and Air Conditioners (MAY 1995) FAR 52.232-18 Availability of Funds (APR 1984) FAR 52.242-2 Production Progress Reports (APR 1991) FAR 52.245-1 Government Property (APR 2012) FAR 52.245-9 Use and Charges (APR 2012) FAR 52.232-40 Providing Accelerated Payments to Small Business Subcontractors (DEC 2013) FAR 52.252-6 Authorized Deviations in Clauses (APR 1984) HSAR 3052.204-71 Contractor Employee Access HSAR 3052.205-70 Advertisement, Publicizing Awards, and Releases HSAR 3052.211-70 Index for Specifications (DEC 2003) HSAR 3052.217-90 Delivery and Shifting of Vessel (DEC 2003) HSAR 3052.217-91 Performance (USCG) HSAR 3052.217-92 Inspection and Manner of Doing Work (USCG) HSAR 3052.217-93 Subcontracts (USCG) HSAR 3052.217-95 Liability and Insurance (USCG) HSAR 3052.217-96 Title (USCG) HSAR 3052.217-97 Discharge of Liens (USCG) HSAR 3052.217-98 Delays (USCG) HSAR 3052.217-99 Department of Labor Safety and Health Regulations for Ship Repair (USCG) HSAR 3052.217-100 Guarantee HSAR 3052.222-70 Strikes or Picketing Affecting Timely Completion of the Contract Work (DEC 2003) HSAR 3052.222-71 Strikes or Picketing Affecting Access to a DHS Facility (DEC 2003) HSAR 3052.223-90 Accident and Fire Reporting (DEC 2003) HSAR 3052.242-72 Contracting Officer's Technical Representative (End of FAR 52.212-4 Addendum) (xii) FAR 52.212-5 - CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUS OR EXECUTIVE ORDERS - COMMERCIAL ITEMS (JAN 2017) (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (2) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015) (3) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553). (4) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77, 108-78 (19 U.S.C. 3805 note)). (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402). (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509). (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub L. 111-5) (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009). _X (4) 52.204-10, Reporting Executive compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-282) (31 U.S.C. 6101 note). (5) [Reserved] (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111- 117, section 743 of Div. C). (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C). _X (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Oct 2015) (31 U.S.C. 6101 note). _X (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313). (10) [Reserved] (11) (i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a). (ii) Alternate I (Nov 2011) of 52.219-3. (12) (i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a). (ii) Alternate I (Jan 2011) of 52.219-4. (13) [Reserved] _X (14) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644). (ii) Alternate I (Nov 2011). (iii) Alternate II (Nov 2011). (15) (i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644). (ii) Alternate I (Oct 1995) of 52.219-7. (iii) Alternate II (Mar 2004) of 52.219-7. (16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)). (17) (i) 52.219-9, Small Business Subcontracting Plan (Jan 2017) (15 U.S.C. 637 (d)(4)). (ii) Alternate I (Nov 2016) of 52.219-9. (iii) Alternate II (Nov 2016) of 52.219-9. (iv) Alternate III (Nov 2016) of 52.219-9. (v) Alternate IV (Nov 2016) of 52.219-9. (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)). (19) 52.219-14, Limitations on Subcontracting (Jan 2017) (15 U.S.C. 637(a)(14)). (20) 52.219-16, Liquidated Damages-Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)). (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set- Aside (Nov 2011) (15 U.S.C. 657f). _X (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)). (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)). (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)). _X (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755). _X (26) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126). _X (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). _X (28) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246). (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212). _X (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). (31) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212). (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). _X (33) (i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627). (ii) Alternate I (Mar 2015) of 52.222-50, (22 U.S.C. chapter 78 and E.O. 13627). (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (E. O. 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.) (35) 52.222-59, Compliance with Labor Laws (Executive Order 13673) (Oct 2016). (Applies at $50 million for solicitations and resultant contracts issued from October 25, 2016 through April 24, 2017; applies at $500,000 for solicitations and resultant contracts issued after April 24, 2017). Note to paragraph (b)(35): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. _X (36) 52.222-60, Paycheck Transparency (Executive Order 13673) (Oct 2016). (37) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA- Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.) (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.) (38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O.13693). (39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun 2016) (E.O. 13693). (40) (i) 52.223-13, Acquisition of EPEAT® -Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514 (ii) Alternate I (Oct 2015) of 52.223-13. (41) (i) 52.223-14, Acquisition of EPEAT® -Registered Television (Jun 2014) (E.O.s 13423 and 13514). (ii) Alternate I (Jun 2014) of 52.223-14. (42) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b). (43) (i) 52.223-16, Acquisition of EPEAT® -Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514). (ii) Alternate I (Jun 2014) of 52.223-16. _X (44) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011) (E.O. 13513). (45) 52.223-20, Aerosols (Jun 2016) (E.O. 13693). (46) 52.223-21, Foams (Jun 2016) (E.O. 13696). (47) (i) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a). (ii) Alternate I (Jan 2017) of 52.224-3. (48) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83). (49) (i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43). (ii) Alternate I (May 2014) of 52.225-3. (iii) Alternate II (May 2014) of 52.225-3. (iv) Alternate III (May 2014) of 52.225-3. (50) 52.225-5, Trade Agreements (Oct 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note). _X (51) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150). (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150). (55) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505), 10 U.S.C. 2307(f)). (56) 52.232-30, Installment Payments for Commercial Items (Jan 2017) (41 U.S.C. 4505, 10 U.S.C. 2307(f)). _X (57) 52.232-33, Payment by Electronic Funds Transfer- System for Award Management (Jul 2013) (31 U.S.C. 3332). (58) 52.232-34, Payment by Electronic Funds Transfer-Other Than System for Award Management (Jul 2013) (31 U.S.C. 3332). (59) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332). (60) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a). (61) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C. 637(d)(12)). (62) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). (ii) Alternate I (Apr 2003) of 52.247-64. (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items: [Contracting Officer check as appropriate.] (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495) (2) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67.). (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (Multiple Year and Option Contracts) (May 2014) (29 U.S.C.206 and 41 U.S.C. chapter 67). (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67). _X (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-- Requirements (May 2014) (41 U.S.C. chapter 67). (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67). (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015) (E.O. 13658). (9) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706). (10) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). (11) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). (12) 52.237-11, Accepting and Dispensing of $1 Coin (Sep 2008) (31 U.S.C. 5112(p)(1)). (d) Comptroller General Examination of Record The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation. (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract. (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. (e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509). (ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (iii) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (iv) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph (1) of FAR clause 52.222-17. (v) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). (vi) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246). (vii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212). (viii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). (ix) 222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212). (x) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (xi) ) 52.222-41, Service Contract Labor Standards (May 2014), (41 U.S.C. chapter 67). (xii) (A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627). (B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 E.O. 13627). (xiii) ) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67.) (xiv) ) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67) (xv) 52.222-54, Employment Eligibility Verification (Oct 2015) (E. O. 12989). (xvi) ) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015). (xvii) ) 52.222-59, Compliance with Labor Laws (Executive Order 13673) (Oct 2016) (Applies at $50 million for solicitations and resultant contracts issued from October 25, 2016 through April 24, 2017; applies at $500,000 for solicitations and resultant contracts issued after April 24, 2017). Note to paragraph (e)(1)(xvii): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. (xviii) ) 52.222-60, Paycheck Transparency (Executive Order 13673) (Oct 2016). (xix) 222-62, Paid sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706). (xx) (A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a). (B) Alternate I (Jan 2017) of 52.224-3. (xxi) i) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). (xxii) i) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) ) of FAR clause 52.226-6. (xxiii) ii) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. (2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations. (End of Clause) Alternate I (Feb 2000). As prescribed in 12.301(b)(4)(i), delete paragraph (d) from the basic clause, redesignate paragraph (e) as paragraph (d), and revise the reference to "paragraphs (a), (b), (c), or (d) of this clause" in the redesignated paragraph (d) to read "paragraphs (a), (b), and (c) ) of this clause". Alternate II (JAN 2017). As prescribed in 12.301(b)(4)(ii), substitute the following paragraphs (d)(1) and (e)(1) for paragraphs (d)(1) and (e)(1) of the basic clause as follows: (d) (1) The Comptroller General of the United States, an appropriate Inspector General appointed under section 3 or 8G of the Inspector General Act of 1978 (5 U.S.C. App.), or an authorized representative of either of the foregoing officials shall have access to and right to- (i) Examine any of the Contractor's or any subcontractors' records that pertain to, and involve transactions relating to, this contract; and (ii) Interview any officer or employee regarding such transactions. (e) (1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), and (c), of this clause, the Contractor is not required to flow down any FAR clause in a subcontract for commercial items, other than- (i) Paragraph (d) of this clause. This paragraph flows down to all subcontracts, except the authority of the Inspector General under paragraph (d)(1)(ii) does not flow down; and (ii) Those clauses listed in this paragraph (e)(1). Unless otherwise indicated below, the extent of the flow down shall be as required by the clause- (A) ) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509). (B) ) 52.203-15, Whistleblower Protections Under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111- 5). (C) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. (D) ) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). (E) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246). (F) ) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212). (G) ) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). (H) ) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. (I) ) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67). (J) (1) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627). (2) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 E.O. 13627). (K) ) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67). (L) ) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67). (M) 52.222-54, Employment Eligibility Verification (Oct 2015) (Executive Order 12989). (N) ) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015). (O) ) 52.222-59, Compliance with Labor Laws (Executive Order 13673), (Oct 2016). Note to paragraph (e)(1)(ii)(O): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction. (P) 52.222-60, Paycheck Transparency (Executive Order 13673) (Oct 2016). (Q) ) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). (R) 52.222-62, Paid sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706). (S) (1) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552). (2) Alternate I (Jan 2017) of 52.224-3 (T) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6. (T) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. (xiii) N/A (xiv) N/A (xv) QUOTATION DUE DATE: Quotations must arrive no later than 08 November 2017 at 11:00 a.m. EST. Quotations may be sent via electronic mail (e-mail) to Shean.E.Mohammed@uscg.mil or via mail to: US Coast Guard SLFC/CPD1/PBPL Attn: Shean Mohammed 300 East Main Street, Suite 600 Norfolk, VA 23510 (xvi) Any question regarding this solicitation may be sent to Shean Mohammed at Shean.E.Mohammed@uscg.mil
Web Link: FBO.gov Permalink
(https://www.fbo.gov/spg/DHS/USCG/COUSCGMLCA/HSCG80-18-Q-P45020/listing.html)
Place of Performance: Address: 100 Trumbo Road, Key West, Florida, 33040, United States; Zip Code: 33040
Record: SN04717080-W 20171020/171018231410-9c7f3948cd899646b0733a15e5dfbec3 (fbodaily.com)
Source: FedBizOpps Link to This Notice
(may not be valid after Archive Date)

| FSG Index | This Issue's Index | Today's FBO Daily Index Page |

Loren Data's SAM Daily™

J -- USCGC TRUMP WPC-1111 DOCKSIDE REPAIRS - SPECS