MODIFICATION
Z -- GREEN RIVER CANAL FISH SCREEN
- Notice Date
- 9/14/2018
- Notice Type
- Modification/Amendment
- NAICS
- 237990
— Other Heavy and Civil Engineering Construction
- Contracting Office
- Bureau of Reclamation Upper Colorado Region Regional Office 125 South State Street, Room 8100 Salt Lake City UT 84138 US
- ZIP Code
- 00000
- Solicitation Number
- 140R4018R0028
- Response Due
- 9/17/2018
- Archive Date
- 9/30/2018
- Point of Contact
- Stanard, Michael
- Small Business Set-Aside
- Total Small Business
- Description
- The purpose of this Amendment 00005 is as follows: 1. Notify vendors that the contract award will be incrementally funded. Reclamation intends on obligating $2.5 million upon award and obligate the remaining award balance of funds after the end of fiscal year 2018 (September 30, 2018). 2. Incorporate clause WBR 1452.232-80 -- LIMITATION OF FUNDS (FIXED-PRICE CONTRACT)--BUREAU OF RECLAMATION (Sept. 2003) to the end of Section I ¿ Contract Clauses as follows: (a) Pursuant to Section 12 of the Reclamation Project Act of 1939 (43 U.S.C. 388) incremental funding for this contract will be made available in accordance with this clause. This statute permits the Secretary of the Interior to enter into contracts which will cover such periods as the Secretary may consider necessary but in which liability of the United States shall be contingent upon appropriations being made therefore. For purposes of this clause, the term "appropriations" includes the Bureau of Reclamation ¿s subsequent allocation of funds for this contract. (b) Incremental funding in the amount of $2,500,000.00 is presently available for payment and allotted under this contract. This present funding allotment is contemplated to cover the work to be performed through December 2018. A schedule for anticipated future funding allotments is as follows. This information is for planning purposes only and may not be fully representative of the funds actually allotted under this contract: FISCAL YEAR FUNDING AMOUNT On award of contract $2,500,000.00 October ¿ November 2018 ¿ Remaining balance of contract award. (c) For work identified in paragraph (b) of this clause, the Contractor agrees to perform up to the point at which the total amount payable by the Government, including reimbursement in the event of termination of specified work for the Government's convenience, approximates the total amount currently allotted to the contract. The Contractor shall not be obligated to continue performance of this work beyond that point. The Government shall not be obligated in any event to reimburse the Contractor in excess of the amount allotted to the contract for this work notwithstanding any contrary provisions of the Termination for Convenience of the Government clause of this contract. (d) Notwithstanding the date specified in paragraph (b) of this clause, the Contractor shall notify the Contracting Officer in writing at least sixty days prior to the date when, in the Contractor's best judgment, the work will reach the point at which the total amount payable by the Government, including any cost for termination for convenience, will approximate 75 percent of the total amount then allotted to the contract for performance of work identified in paragraph (b) of this clause. The notification shall state (1) the estimated date when that point will be reached and (2) an estimate of additional funding, if any, needed to continue performance of the work up to the next scheduled date for allotment of funds identified in paragraph (b) of this clause, or to a mutually agreed upon substitute date. The notification shall also advise the Contracting Officer of the estimated amount of additional funds that will be required for the timely performance of work funded pursuant to this clause, for a subsequent period as may be specified in the allotment schedule in paragraph (b) of this clause, or otherwise agreed to by the parties. If after such notification additional funds are not allotted by the date identified in the Contractor's notification, or by an agreed substitute date, the Contracting Officer shall terminate any work for which additional funds have not been allotted, pursuant to the Termination for Convenience of the Government clause of this contract. (e) When additional funds are allotted for continued performance of the work identified in paragraph (b) of this clause, the parties will agree as to the period of contract performance which will be covered by the funds. The provisions of paragraph (c) through (e) of this clause will apply in like manner to the additional allotted funds and agreed substitute date, and the contract will be modified accordingly through revision of paragraph (b) of this clause. The Contracting Officer is the only person authorized to provide notice, communication, or other form of representation to increase or decrease the amount of funds allotted by the Government to this contract. If agreement cannot be reached, the Contracting Officer will make a final decision as to the period of contract performance that will be covered by the funds. This decision may be appealed by the Contractor under the Disputes clause of the contract. (f) If, solely by reason of failure of the Government to allot additional funds in amounts sufficient for timely performance of the work identified in paragraph (b) of this clause, the Contractor incurs additional costs or is delayed in the performance of the work under this contract and if additional funds are allotted, an equitable adjustment will be made in the price or prices (including appropriate target, billing, and ceiling prices where applicable) of work, or in the time of delivery, or both. Failure to agree to any such equitable adjustment hereunder shall be a dispute concerning a question of fact within the meaning of the Disputes clause of this contract. (g) The Government may at any time prior to termination allot additional funds for the performance of the work identified in paragraph (b) of this clause. (h) The termination provisions of this clause do not limit the rights of the Government under the Default clause of this contract. The provisions of this clause are limited to the work and allotment of funds as set forth in paragraph (b) of this clause. This clause is inapplicable once the contract is fully funded except with regard to the rights or obligations of the parties concerning equitable adjustments negotiated under paragraphs (e) or (f) of this clause. (i) Change orders shall not be considered authorization to exceed the amount allotted by the Government as specified in paragraph (b) of this clause unless the amount is increased by inclusion of a statement contained in the change order. (j) Nothing in this clause affects the right of the Government to terminate this contract pursuant to the Termination for Convenience of the Government clause of this contract. (End of clause) 2. Due to system limitations, section 13. E of this SF30 is missing a check mark and statement of number of copies. The box needing a check mark states, "is required to sign this document and return the original + 1 copies to the issuing office." Contractors are required to acknowledge receipt of each amendment to this solicitation by signing the SF30 and providing a copy of this amendment with their final proposal. See clause L.23 WBR 1452.215-81 General Proposal Instructions. 3. Nothing follows.
- Web Link
-
FBO.gov Permalink
(https://www.fbo.gov/notices/9876c45ec65ea6248b4cdcb23f2f997b)
- Place of Performance
- Address: Reclamation Office 445 West Gunnison Ave Ste 221 Grand Junction CO 81501 USA
- Zip Code: 81501
- Zip Code: 81501
- Record
- SN05089528-W 20180916/180914230710-9876c45ec65ea6248b4cdcb23f2f997b (fbodaily.com)
- Source
-
FedBizOpps Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's FBO Daily Index Page |