SOLICITATION NOTICE
59 -- SHOCK MOUNTS, (HC144A)
- Notice Date
- 3/2/2021 12:26:19 PM
- Notice Type
- Combined Synopsis/Solicitation
- NAICS
- 336413
— Other Aircraft Parts and Auxiliary Equipment Manufacturing
- Contracting Office
- AVIATION LOGISTICS CENTER (ALC)(000 ELIZABETH CTY NC 27909 USA
- ZIP Code
- 27909
- Solicitation Number
- 70Z03821QW0000062
- Response Due
- 3/12/2021 6:00:00 AM
- Archive Date
- 03/27/2021
- Point of Contact
- Denise M Coley, Phone: 2523356562, Fax: 2523345427
- E-Mail Address
-
denise.m.coley@uscg.mil
(denise.m.coley@uscg.mil)
- Small Business Set-Aside
- SBA Total Small Business Set-Aside (FAR 19.5)
- Description
- Date: 3/02/2021 Year: 2021��������� Contracting Office Zip Code: 27909-5001 Classification Code: 16 - Aircraft Components & Accessories Contracting Office Address: USCG, ALC, MRS, Elizabeth City, NC� 27909-5001������������������ Subject: Aircraft Parts and Accessories Proposed Solicitation Number: 70Z03821QW0000062 Closing Response Date: 03/12/2021 Primary Point of Contact: Denise Coley Contract Award and Solicitation Number: To be assigned at time of award 70Z03821QW0000062 Contract Line Item Number(s): 3 Description: Aircraft Parts and Accessories Set-aside Status: TOTAL SBSA � � This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Federal Acquisition Regulation (FAR) Subpart 12.6, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotes are being requested and a written solicitation will not be issued.� This Request for Quote (RFQ) 70Z03821QW0000062 incorporates provisions and clauses in effect through Federal Acquisition Circular. The applicable North American Industry Classification Standard (NAICS) Code is 336413.� The small business size standard is 1,250 employees. This requirement consists of the following spare parts utilized on the HC144 USCG aircraft. All or none. NSN: 5975-01-526-8897, MOUNT SHOCK, P/N 96064-02, QTY 3 EACH. MFGCD: 81860 � NSN: 5975-01-526-8896, MOUNT SHOCK, P/N 96064-03, QTY 3 EACH. MFGCD: 81860 � NSN: 5975-01-526-8895, MOUNT SHOCK, P/N 96064-01, QTY 3 EACH. MFGCD: 81860 � � The Coast Guard does not own nor can provide the OEM�s Service Manuals, Service Bulletins, or Proprietary Data. The Aircraft OEM is FINMECCANICA S.PA. PIAZZA MONTE GRAPPA 4 ROME ITALY 00195, Cage Code A1512, and their domestic facility is BRUZZONE SHIPPING INC, 224 BUFFALO AVENUE, FREEPORT NY 11520, the cage code is A2142. A standard information packet and sole source justification document(s) as applicable is attached to this Special Notice of Intent to Award. �Anticipated award date is on or about MAR 15, 2021 with an anticipated required delivery date of all items on or before 12/31/2021. Point of contact for this intent to award notice is Ms. Denise M. Coley @252-335-6562, denise.m.coley@uscg.mil.� � Offerors should include the following:������� NSN, PART NUMBER, NOMENCLATURE, UNIT PRICE, EXTENDED PRICE, DISCOUNTS, DELIVERY TIME, WARRANTY (IF APPLICABLE), FOB POINT, CAGE CODE, DUNS NUMBER, BUSINESS SIZE, MINORITY CLASSIFICATION (IF APPLICABLE), FACTORY NEW. MUST STATE TRACEABLE TO THE OEM. � The United States Coast Guard (USCG) anticipates award of a Firm-Fixed Price Purchase Order to the Original Equipment Manufacturer (OEM), or a distributor that can provide documented traceability for the components.� The United States Coast Guard (USCG) anticipates award of a Firm-Fixed Price Purchase Order to the Original Equipment Manufacturer (OEM), or a distributor that can provide documented traceability for the components.� Award will be made to the offeror quoting the lowest price technically acceptable to the USCG.� All responsible sources may submit a quote which shall be considered by the USCG. Only new items are acceptable. Reconditioned or used items are not acceptable. Offerors must be able to provide necessary certification including traceability to the OEM and provide a Certificate of Conformance (COC) to ensure parts are in airworthy condition, suitable for installation on USCG aircraft.� Prospective vendors who are not the OEM must provide traceability for the materials.� Traceability means a clear, complete, documented, auditable paper trail which traces each step from an OEM or distributor to its current location.������� Required delivery schedule is 300 DAYS or less after receipt of order. The offerors shall propose a delivery schedule.� All requests for time extension shall be in writing and shall include substantiation of the need for such time extension in accordance with FAR 52.212-4 (f), Excusable delays. �If nonperformance is not covered by an excusable delay, the Contractor and the Contracting Officer shall negotiate consideration for the approval of the extended delivery date at which time a modification will be issued to reflect the consideration and extension.������
- Web Link
-
SAM.gov Permalink
(https://beta.sam.gov/opp/7cb50eb23c3142fc89f499f7b3c3ad68/view)
- Place of Performance
- Address: Elizabeth City, NC 27909, USA
- Zip Code: 27909
- Country: USA
- Zip Code: 27909
- Record
- SN05931085-F 20210304/210302230109 (samdaily.us)
- Source
-
SAM.gov Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's SAM Daily Index Page |