MODIFICATION
70 -- COMPUTER, DIGITAL, IN REPAIR/MODIFICATION OF
- Notice Date
- 7/9/2021 1:41:11 PM
- Notice Type
- Solicitation
- NAICS
- 334111
— Electronic Computer Manufacturing
- Contracting Office
- NAVSUP WEAPON SYSTEMS SUPPORT MECH MECHANICSBURG PA 17050-0788 USA
- ZIP Code
- 17050-0788
- Solicitation Number
- N0010421QCB25
- Response Due
- 7/19/2021 1:30:00 PM
- Archive Date
- 07/19/2021
- Point of Contact
- Michael French, Phone: 7176057080
- E-Mail Address
-
michael.french1@navy.mil
(michael.french1@navy.mil)
- Small Business Set-Aside
- SBA Total Small Business Set-Aside (FAR 19.5)
- Description
- TEARDOWN, EVALUATE, REPAIR AND/OR MODIFY 0001 NSN 7HH 7021-01-548-0358 COMPUTER,DIGITAL 0001AA N00104-21-U-0483 SW3117 9 EA M/F: ""A"" CONDITION STOCK TP: 3 0001AB OPTION QTY UP TO 100% OF ITEM 0001 SOLICITATION NOTES: ** Accelerated delivery is encouraged and accepted before the delivery date(s) listed in the schedule. ** All freight is FOB Origin. This RFQ is for repair. The resultant award of this solicitation will be issued bilaterally, requiring the contractors written acceptance prior to execution.. Verify nomenclature, part number, and NSN prior to responding. Required Repair Turnaround Time (RTAT): 145 days Quotes not meeting the required RTAT may not be considered for award. Government source inspection is required. Please note freight is handled by Navy CAV or Proxy CAV as stated in NAVSUPWSSFA24 or NAVSUPWSSFA25. Your quote should include the following information for justification purposes: *Firm-fixed-price per unit:___________ *New unit price:__________ *New unit delivery lead-time:__________ *Inspection & Acceptance CAGE, if not at source:__________ *Facility/Subcontractor CAGE (where the asset should be shipped), if not at source:__________ *Delivery Vehicle (if Delivery Order requested) (if your company has a current� BOA/IDIQ, for example) :__________________ ALL PRICING IS FIRM. PLEASE CONSIDER THE FOLLOWING WHEN PROVIDING PRICE: Include repair price with all costs associated with receipt and complete repair of material that may be in unwhole condition, missing hardware, damaged, handling damage, missing parts and wear damage. The Contract Officer would like to exercise a 100% option quantity within 180-days of the effective date of the repair contract award. The contractor will provide the same delivery turnaround as the base line items. A modification willbe completed at the time the option is exercised and all current contract termsand conditions will apply to the option quantity. Please indicate if the Contracting Officer may exercise the 100% option quantity for the repair contract. Yes __ or No __ Please indicate the pricing for the option quantity. Price Each: $___________ IMPORTANT NOTE: Any asset for which the contractor does not meet the required RTAT will incur a price reduction per unit/per month the contractor is late - any delay determined to be excusable (e.g. Government Delay) will not result in a price reduction. If a price reduction is required due to unexcusable contractor delay, the Contracting Officer will implement the aforementioned price reduction via a ""reconciliation modification"" at the end of the contract performance. Price reductions made pursuant to this section shall not limit other remedies available to the Government for failure to meet required RTATs, including but not limited to the Government's right to terminate for default. In reference to the above important note, the contractor provides the followingprice reduction amount per unit per month the contractor does not meet the RTAT: $__________, up to a maximum of: $_________. INSPECTION AT ORIGIN ACCEPTANCE AT ORIGIN See solicitation for required clauses.
- Web Link
-
SAM.gov Permalink
(https://beta.sam.gov/opp/cfd663cc3176495097ae1d32de701cc4/view)
- Record
- SN06056244-F 20210711/210709230113 (samdaily.us)
- Source
-
SAM.gov Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's SAM Daily Index Page |