SOURCES SOUGHT
Z -- Design/Build Services for Security Upgrades to Entry/Security Building at Miami Job Corps Center
- Notice Date
- 8/17/2021 11:57:13 AM
- Notice Type
- Sources Sought
- NAICS
- 236220
— Commercial and Institutional Building Construction
- Contracting Office
- DEPARTMENT OF LABOR (OASAM) WASHINGTON DC 20210 USA
- ZIP Code
- 20210
- Solicitation Number
- 1605AE-21-N-00022
- Response Due
- 8/31/2021 11:00:00 AM
- Archive Date
- 09/15/2021
- Point of Contact
- Olivia J. Thorpe, Phone: 202-693-3578, Ronette C. McBean-Felder, Phone: 202-693-3878
- E-Mail Address
-
Thorpe.olivia@dol.gov, mcbeanfelder.ronette.c@dol.gov
(Thorpe.olivia@dol.gov, mcbeanfelder.ronette.c@dol.gov)
- Description
- The US�Department of Labor,�Office of Job Corps�Acquisition Services, has a requirement for a qualified�firm�to provide design/build services�that include, but are not limited to, an Entry/Security Building addition at the main Center entrance. THIS IS A SOURCES SOUGHT NOTICE.?�In accordance with Federal Acquisition Regulation (FAR) 10.002(b) (2) (i),�this notice is issued�for the purpose of�conducting�market research.? Market research�is being conducted�to determine if there are potential�businesses�with the�capacity�and experience to perform the required work.?�This�Notice is not to�be misconstrued�as an Invitation for Bid�or Request for Proposal.?�� There is no solicitation at this time. This request for capability information does not constitute a request for proposals; submission of any information in response to this market survey is purely voluntary; the government assumes no financial responsibility for any costs incurred.�� The�full�extent of the work will be described in the solicitation, which�may�follow�at a�later date.� However,�a summary of the services to�be performed�is provided as follows:� � The work involves design and construction services for security upgrades that include, but are not limited to, an Entry/Security Building addition at the main Center entrance, installation of ballistic fencing, steel wrought iron fencing, heavy gauge privacy screen/chain link fencing, motorized ballistic grade sliding gate, sliding gates and electrically operated arm gates, security cameras and audio equipment, and addition of a service vehicle entrance at the Miami Job Corps Center. �Design services for the project include field investigation to determine Entry/Security Building addition design, fence selection and foundation design, and preparation of construction documents for all new construction and security upgrades. The estimated price range�is�between $1,000,000 and 5,000,000.� Firms interested in this requirement�are requested�to submit a statement of qualifications.� Your�statement of qualifications shall�demonstrate the capacity of your firm�to perform the services described above,�and should include the following information:�� 1.� Previous projects of similar scope and value� A. Contractor has provided design-build services on two�(2)�or more major roofing system replacement projects located on operating facilities, high schools, college or similar campuses with a $1M and $5M constructed value within the last five�(5)�years.� B. Contractor has provided design-build services on two�(2)�or more HVAC replacement projects located on operating facilities, high schools, college or similar campuses with $1,000,000�to $5,000,000�constructed value within the last five years.� C. Contractor or roof installer is a manufacturer�s certified installer. �Contractor has previous experience on projects installing multiple roofing system types.���� Provide previous project examples that include the location of the project (Southwest United States), the project owner, a brief and concise description of the project scope, specialty design consultants employed, a comparison of the construction budget versus construction award value, and the final contract amount.� 2. Project Location� A. Contractor has completed three�(3)�or more projects in the Southwest United States in the last five years indicating familiarity with state and local codes, environmental conditions, economic conditions and experience/qualifications of local design consultants.� 3.���Project schedule, safety, and quality of work� A. Contractor has a proven record of excellent performance by completing projects on or ahead of time.�� Using the previous project examples include the Contract Award/NTP date, the original contract completion date, and the actual contract completion date for each project.��� B. Contractor has established Safety and Quality Control procedures and�protocols which�are consistently applied to all projects.��� 4.���Financial Capabilities� General Contractor is in sound financial standing with no claims or liens.� General Contractor has sufficient financial capacity to bond a project in the $1,000,000 to $5,000,000 range.� Provide aggregate and per project bonding capacity limits.��� Your project examples shall�include the location of the project, the project owner, a brief description of the services performed.� Your synopsis should also include the date of contract award, the original and final date of contract completion. Using the previous project examples indicate the�original contract price and�final contract value.��� The government will evaluate market information to ascertain potential market capacity to 1) provide services consistent in scope and scale with those described in this notice and otherwise anticipated;�and 2) secure and apply the full range of corporate financial, human capital, and technical resources required�to successfully perform�similar requirements.� Your�submission�should not exceed�10 pages.��Your response to this Notice,�is due no later than�August 31, 2021 by 2:00 PM EDT,�and submit it via email to Olivia J. Thorpe, Contract Specialist,�US�Department of Labor/OASAM/OSPE/JCAS,�A&E Construction,�Thorpe.olivia@dol.gov.� HUB Zone, small disabled veterans, small disadvantaged businesses,�8(a) businesses�and large businesses�are encouraged to submit.��NAICS Code for this requirement is�236220. Acknowledgment of�responses�will not be made, nor will respondents be notified�regarding�the results of the Government�s evaluation�of the information received.� The�determination to proceed with the acquisition is within the discretion of the Government.��Telephone inquiries�will not be accepted.��� Please be reminded that a prospective�Offeror�interested in obtaining a contract award with the Government�must be registered�in the Federal Government's System for Award Management (SAM) database.� Additional information regarding contractor registration�can be obtained�through the following website,�www.SAM.gov.�
- Web Link
-
SAM.gov Permalink
(https://beta.sam.gov/opp/d4eb6e0e504648c586191a53cf550bb3/view)
- Place of Performance
- Address: Miami Gardens, FL 33056, USA
- Zip Code: 33056
- Country: USA
- Zip Code: 33056
- Record
- SN06100989-F 20210819/210817230127 (samdaily.us)
- Source
-
SAM.gov Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's SAM Daily Index Page |