SAMDaily.us | SRCSGT | Y | Patient Waiting and Parking Lot Improvements at Fort Yates Hospital

SAMDAILY.US - ISSUE OF APRIL 02, 2023 SAM #7796
SOURCES SOUGHT

Y -- Patient Waiting and Parking Lot Improvements at Fort Yates Hospital

Notice Date: 3/31/2023 3:10:15 PM
Notice Type: Sources Sought
NAICS: 236220 — Commercial and Institutional Building Construction
Contracting Office: DIV OF ENGINEERING SVCS - DALLAS DALLAS TX 75202 USA
ZIP Code: 75202
Solicitation Number: 75H70123R00051
Response Due: 5/1/2023 12:00:00 PM
Archive Date: 07/30/2023
Point of Contact: Jeffrey Haubenreiser, Phone: 2147678588, Andrew Hart, Phone: 2066152453
E-Mail Address: jeffrey.haubenreiser@ihs.gov, andrew.hart@ihs.gov
(jeffrey.haubenreiser@ihs.gov, andrew.hart@ihs.gov)
Description: Sources Sought for Patient Waiting and Parking Lot Improvements at Fort Yates Hospital Solicitation Number�75H70123R00051 The Indian Health Service (IHS) is conducting a SOURCES SOUGHT/REQUEST FOR INFORMATION as outlined in FAR 15.201(c)(3) to gain knowledge of interest, capabilities, and qualifications of firms especially small businesses including: Native American/Indian-Owned Businesses, 8(a) Certified Small Businesses, Historically Underutilized Business Zones (HUB-Zone) Small Businesses, Women Owned Small Businesses, Service Disabled Veteran-Owned Small Businesses (SDVOSB), Small Disadvantaged Businesses (SDB), and Veteran Owned Small Businesses. This notice is intended strictly for Market Research to determine if a 100% Set Aside for Indian Economic Enterprise (IEE) Firms or if a 100% Set Aside for Small business concerns can fulfill the requirements set forth in this request for information (RFI). Interested firms are requested to reply to this announcement with a submittal as described below. NO PROPOSALS ARE BEING REQUESTED OR ACCEPTED WITH THIS RFI. THIS IS NOT A SOLICITATION FOR PROPOSALS.� Respondents will NOT be notified of the results of this notice.� No reimbursement will be made for any costs associated with providing information in response to this notice or any follow-up information requested. Market Research is being performed pursuant to Federal Acquisition Regulation (FAR) Part 10 to identify businesses capable of performing the functions described herein. LOCATION OF PROJECT:�� Indian Health Service �� Fort Yates Hospital �� 10 Standing Rock Avenue �� Fort Yates, ND 58538 TERO is applicable. CONSTRUCTION DURATION:� Period of Performance is 365 calendar days after issuance of a Notice to Proceed. SET-ASIDE: The appropriate set-aside will be finalized based on the results of this sources sought.� It is anticipated that this project will be procured as a 100% Small Business set-aside under North American Industry Classification System (NAICS) code 236220 Commercial and Institutional Building Construction with a size standard of $45 million. �The applicable Product Service Code (PSC) is Y1DA Construction of Hospitals and Infirmaries. For information concerning NAICS and SBA size standards, go to https://www.sba.gov. SUMMARY OF SCOPE This project includes full interior demolition, remodel and addition including Mechanical, Electrical, Plumbing and other work to expand the patient waiting area. Additionally, work will include the full demolition and replacement of the parking lot, drives and associated flatwork. In accordance with FAR 36.204, Disclosure of the Magnitude of Construction Projects, the anticipated project magnitude is between $1 million and $5 million. RESPONSES � SUBMITTAL Responses to this notice must be emailed to Jeffrey Haubenreiser at jeffrey.haubenreiser@ihs.gov and must be received no later than 2:00 pm Central Time on May 1, 2023.� Interested firms shall submit Attachment 3: Sources Sought Submittal (SS) Questionnaire to provide the required information.� Responses shall include: Company Information: Company name, website, physical address, SAM UEI code Point of Contact: Contact name, phone number, and E-mail address �If a solicitation is issued, will your firm/company be submitting a proposal?� Indicate Yes or No �Type of Business: Native American-owned (IEE/ISBEE)**, SBA certified 8(a), SBA Certified HUB Zone, Service Disabled Veteran-Owned Small Businesses (SDVOSB), Women Owned Small Business (WOSB), and/or Small Businesses (SB). For more information on the definitions or requirements for these small business programs, refer to http://www.sba.gov. **For Indian owned business, the contractor shall: Complete and submit Attachment 1: IHS IEE Representation Form (Jan 2022) Submit the controlling enterprise�s Tribal enrollment/certificate of Degree of Indian Blood documentation. Please note that there shall be no personally identifiable information (PII), such as social security numbers, included in the documentation submitted. Any PII shall be redacted prior to submission. The contractor shall complete and submit Attachment 2: IEE Self-Performance Worksheet. Per the definition of an IEE (HHSAR 326.601), �the Indians or Indian Tribes must, together, receive at least a majority of the earnings from the contract�; therefore, IEEs shall demonstrate the ability to allocate at least the majority of the earnings to one or more Indians or Indian Tribal entities. Bond Capacity: Information on the firm's bonding capability - specifically identify single and aggregate bonding capacities Experience Submission Requirements: Submit up to three (3) narratives on the questionnaire describing projects completed by your firm within the last six (6) years that are similar to the work that will be required under this project.� Firms shall include the following information: Indicate whether Prime Contractor or Subcontractor for each project submitted; Dates of construction for each project submitted; Contract value, location, completion date, and complexity of job for each project submitted; Indicate whether the project is a federal, state, tribal or other for each project submitted; and Project references/Agency point of contact (telephone number and email address) for each project submitted. All information received in response to this source sought that is marked proprietary will be handled accordingly.� Documents and/or information other than what is requested will not be reviewed.� Information submitted beyond what is requested will not be considered. QUESTIONS: Questions regarding this sources sought may be emailed to Jeffrey Haubenreiser at jeffrey.haubenreiser@ihs.gov NOTE: Registration in the System for Award Management (SAM) database is mandatory to be considered for award.� Offerors may obtain information on registration and annual confirmation requirements via the internet at www.sam.gov.� Contractors are encouraged to complete SAM registration as soon as possible; the government may not delay award for the purpose of allowing a contractor additional time to register in SAM. This notice is for informational purposes only and is NOT a request for submission of offers. No other information is available until issuance of the solicitation itself. No bidder list is maintained. All potential offerors should register with www.sam.gov if interested in this forthcoming acquisition.� Upon issuance of the solicitation, all responsible sources may submit a bid, proposal, or quotation which shall be considered by the agency.
Web Link: SAM.gov Permalink
(https://sam.gov/opp/e2e1f6c319c24fac8ec4f2e393b65e1b/view)
Place of Performance: Address: Fort Yates, ND 58538, USA; Zip Code: 58538; Country: USA
Record: SN06637258-F 20230402/230331230112 (samdaily.us)
Source: SAM.gov Link to This Notice
(may not be valid after Archive Date)

| FSG Index | This Issue's Index | Today's SAM Daily Index Page |

Loren Data's SAM Daily™

Y -- Patient Waiting and Parking Lot Improvements at Fort Yates Hospital