Loren Data's SAM Daily™

SAMDAILY.US - ISSUE OF MAY 26, 2023 SAM #7850
SOLICITATION NOTICE

39 -- 45 TON WASHINGTON IRON WORKS PORTAL CRANE ELECTRICAL CONTROL REPLACEMENT

Notice Date

5/24/2023 9:08:20 AM
 

Notice Type

Combined Synopsis/Solicitation
 

NAICS

333923 — Overhead Traveling Crane, Hoist, and Monorail System Manufacturing
 

Contracting Office

FA4418 628 CONS PK JOINT BASE CHARLESTON SC 29404-5021 USA
 

ZIP Code

29404-5021
 

Solicitation Number

FA441823Q0003
 

Response Due

6/5/2023 9:00:00 AM
 

Archive Date

06/20/2023
 

Point of Contact

Taylor McDaniel, Phone: 8439634491, Terry G. Harrelson, Phone: 8439635158
 

E-Mail Address

taylor.mcdaniel.1@us.af.mil, terry.harrelson.1@us.af.mil
(taylor.mcdaniel.1@us.af.mil, terry.harrelson.1@us.af.mil)
 

Description

The Purpose of Amendment 2 is to: 1. Notify interested vendors that the question & answering period for this solicitation is now closed. 2. Provide Answers to Questions submitted as a result of the Pre-Proposal Site Visit held on Wednesday, 10 May 2023 (refer to Attachment No. 4). 3. Extend the Solicitation Closing Date to Monday, 05 Jun 2023 at 12:00 p.m. EST as a result of this Amendment. All other solicitation information remains unchanged and in full effect. The Purpose of Amendment 1 is to: 1. Remove the OSHA Maritime Certification as a technical evaluation factor from the Solicitation. 2. Combo paragraph viii) FAR 52.212-1, Instruction to Offerors � Commercial Products and Commercial Services (Mar 2023) has been revised to remove the submission of the OSHA Maritime Certification and to extend the notification for Site Visit attendance to 08 May 2023. 3. Combo paragraph ix) FAR 52.212-2, Evaluation � Commercial Products and Commercial Services (Nov 2021) has been revised to remove the technical evaluation factor of the OSHA Maritime Certification. 4. Remove reference to OSHA Maritime Certification from SoW paragraph 2.� SoW Revision 1 dated 5 May 2023 replaces the original solicitation SoW dated 20 April 2023. All other solicitation information remains unchanged and in full effect. ----------------------------------------------------------------------------------------------------------------------- Combined Synopsis � Solicitation for Commercial Items (IAW FAR 12.603(c)) i)� This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6 and 13.5 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation. Quotes are requested and a written solicitation will not be issued. ii)� This solicitation/synopsis reference number is FA441823Q0003 and is being issued as a Request for Quote (RFQ). iii)� This solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular 2023-02, effective 16 Mar 2023. iv)� This acquisition is unrestricted utilizing Full & Open Competition. The associated NAICS code is 333923 with a 1,250-employee size standard. v)� A list of line item number(s) and items, quantities, and units of measure can be found within the associated Pricing Worksheet (Attachment No. 3). Interested Offerors shall submit a quote in reference to both, the attached Statement of Work (SoW) (Attachment No. 1) and the attached associated Pricing Worksheet (Attachment No. 3). All responsible sources may submit a quotation, which shall be considered. vi)� This requirement is to replace the existing DC crane electrical and control system on a 1969 - 45 Ton Washington Iron Works Portal Crane located at Joint Base Charleston, Goose Creek, SC. The Contractor shall replace the DC control system and components for the Luffing Hoist, Main Hoist, Auxiliary Hoist, Rotate, and Gantry Travel. The Contractor shall refurbish existing DC motors or replace as needed for the Luffing Hoist, Main Hoist, Auxiliary Hoist, Rotate and Gantry Travel. The Contractor shall repair/replace operators cab flooring to support the installation of a new control chair to control all crane operations. The Contractor shall remove all old wiring and conduit and install new wiring and ridged watertight type conduit to support newly installed control systems and control chair. The Contractor shall replace all existing interior and exterior lights with environment appropriate LED light fixtures and replace the existing wiring transformer and associated components. The Contractor shall upgrade the cab with new AC/Heater Unit, power outlets, and wiring. The Contractor shall install a minimum of two (2) cameras in the machine house and monitoring system in operator�s cab. The Contractor shall perform all replacements and repairs in accordance with all applicable requirements and recommendations in accordance with (IAW) the requirements of the Original Equipment Manufacturer (OEM), American National Safety Institute (ANSI), American Society of Mechanical Engineers (ASME) and Occupational Safety and Health Association (OSHA). vii)� FOB Destination � The place of performance is at Joint Base Charleston, Goose Creek, SC. Delivery/period of performance shall be based on contractor�s quoted delivery/performance period and established at time of award. If the contractor exceeds the established period of performance, the contractor will be responsible for renting/provided a land-based crane, barge crane, or combination of both in support of mission operations after the original contract completion date and the final completion date. � viii)� The provision at FAR 52.212?1, Instructions to Offerors � Commercial Products and Commercial Services (Mar 2023), applies to this acquisition and is amended as follows: (a)���A pre-proposal site visit will be conducted at Joint Base Charleston - Weapons Station�2567-2575 Red Bank Road Goose Creek, SC 29445 (Parking Lot across from Wharf Alpha), at 10:00 A.M. (EST) on 10 May 2023. Site Visit Attendees will meet at the Joint Base Charleston Weapons Station Visitor Center (Parking Lot), 1650 Red Bank Rd., Goose Creek, SC 29445. All prospective offerors are required to attend the Site Visit in order to be considered� eligible for award. Offerors are required to contact Taylor McDaniel, Contract Specialist, at (843) 963-4491, e-mail address taylor.mcdaniel.1@us.af.mil or Terry Harrelson, the Contracting Officer, at (843) 963-5158, e-mail address terry.harrelson.1@us.af.mil by COB 08 May 2023 if they plan to attend. Vendors are limited to no more than two representatives at the site visit.� Special arrangements will be required to gain access to the installation. Offerors are cautioned that Joint Base Charleston has visitor control procedures requiring individuals not affiliated with the installation to obtain a visitor pass prior to entrance. SOME DELAY SHOULD BE ANTICIPATED. Offerors should allow sufficient time to obtain a visitor pass (requiring valid driver�s license (REAL ID), social security card, vehicle registration, and proof of insurance). (b) Quotes must be complete, self?sufficient, and respond directly to the requirements of this solicitation.� Pricing shall be submitted utilizing the Pricing Worksheet Attachment No. 3. (c) The response shall consist of two (2) separate parts: Part I � Pricing Worksheet, and Part II Past Performance Information. (d) Only references for same or similar type contracts are desired. Offerors are to provide a list of no more than three (3), of the most relevant contracts performed for Federal agencies and commercial customers within the last five (5) years. Relevant contracts are considered crane electrical repairs/upgrades that are similar in nature to the electrical repair/upgrades listed within para v. ix)� FAR 52.212?2, Evaluation ? Commercial Products and Commercial Services (Nov 2021), applies to this acquisition and is amended as follows: (a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. (b) The following factors shall be used to evaluate offers in the following relative order of importance: �Price, and �Past Performance Past Performance is considered significantly more important than Price. (c) �Price��The Government will begin evaluating offers by adding the total price of CLIN�s (Pricing Worksheet Attachment No. 3) for the basic requirement to determine the total quoted price for each offer. Offerors will then be arranged according to price, from lowest priced offer to the highest priced offer. (d) �Past Performance��Next, the Government will begin evaluating Past Performance starting with the lowest priced offer. Evaluation of the offerors past performance is subjective and will result in a rating of (See table below) Substantial, Satisfactory, Neutral, Limited, or No Confidence. Offerors who do not have recent and relevant past performance relating to this requirement will receive a rating of Neutral Confidence. Rating� � � � � � � � � � � � � � � � � � � �Description Substantial Confidence -� � � � � Based on the offeror�s recent/relevant performance record, the Government has a high expectation the offeror will successfully perform the requirement. Satisfactory Confidence -� � � � �Based on the offeror�s recent/relevant performance record, the Government has a reasonable expectation the offeror will successfully perform the requirement. Neutral Confidence -� � � � � � � � No recent/relevant performance record is available, or the offeror�s performance record is so sparse, no meaningful confidence assessment rating can be reasonably assigned. The offeror may not be�� � � � � � � � � � � � � � � � � � � � � � � � � � � � � � � � � �evaluated favorably or unfavorably on the factor of past performance. Limited Confidence -� � � � � � � � Based on the offeror�s recent/relevant performance record, the Government has a low expectation the offeror will successfully perform the requirement. No Confidence -� � � � � � � � � � � �Based on the offeror�s recent/relevant performance record, the Government has no expectation the offeror will successfully perform the requirement. The Government will evaluate past performance for recency and relevancy. Recency is defined as performance of similar services within the past five (5) years from the issue date of the solicitation. Relevancy is defined as services of the same level of effort and magnitude such as 45 Ton Washington Iron Works portal crane electrical repairs/upgrades performed and similar dollar value, types of repairs/upgrades performed, and evidence supporting the ability to perform engineering services. If the lowest priced offer, receives a Substantial Performance Confidence Rating, that offer represents the best value for the Government and the evaluation process stops at this point; an award shall be made to that offeror without further consideration of any other offers. In the event the lowest priced offeror, does not receive a Substantial Performance Confidence Rating, the evaluation process will continue with the next lowest priced offeror until an offeror receives a Substantial Performance Confidence Rating or all offers are evaluated. In the event an offeror other than then lowest priced offeror receives a Substantial Performance Confidence Rating, the Contracting Officer will perform an integrated best value evaluation to determine the eventual awardee. The Government reserves the right to award to a Substantial Performance Confidence Rated offeror and reserves the right to award to other than the lowest priced offeror. The Government intends to award a contract without interchanges with respective offerors. The Government, however, does reserve the right to hold interchanges with one, some, none, or all offerors. x)� All offerors shall include a completed copy of FAR 52.212?3, Offeror Representations and Certifications ?- Commercial Products and Commercial Services (Dec 2022) or complete electronic annual representations and certifications at http://www.sam.gov. xi)� The clause at 52.212?4 Contract Terms and Conditions �Commercial Products and Commercial Services (Dec 2022), applies to this acquisition and is amended as follows: None. xii)� FAR 52.212?5 Contract Terms and Conditions Required to Implement Statutes or Executive Orders� Commercial Products and Commercial Services (Mar 2023), applies to this acquisition. The following additional FAR clauses cited within the clause are applicable to this acquisition: (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services: (1)��� �52.203?6, Restrictions on Subcontractor Sales to the Government (Jun 2020), with Alternate I (Nov 2021) (41 U.S.C. 4704 and 10 U.S.C. 2402). (4) ����52.204?10, Reporting Executive Compensation and First?Tier Subcontract Awards (Jun 2020) (Pub. L. 109?282) (31 U.S.C. 6101 note). (8)���� 52.209?6, Protecting the Government�s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Nov 2021) (31 U.S.C. 6101 note). (9) ����52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters�(Oct 2018)�(41�U.S.C.�2313). (12)�� 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a). (16)� �52.219?8, Utilization of Small Business Concerns (Oct 2022) (15�U.S.C.�637(d)(2) and (3)). (17)�� (i) 52.219-9, Small Business Subcontracting Plan (Oct 2022) (15 U.S.C. 637(d)(4)). (20)�� 52.219-16, Liquidated Damages-Subcontracting Plan (Sep 2021) (15 U.S.C. 637(d)(4)(F)(i)). (27)�� 52.222-3, Convict Labor (Jun 2003) (E.O.11755). (28)�� 52.222-19, Child Labor-Cooperation with Authorities and Remedies (Dec 2022) (E.O.13126). (29)�� 52.222-21, Prohibition of Segregated Facilities (Apr 2015). (30)�� (i) 52.222-26, Equal Opportunity (Sep 2016) (E.O.11246). (31)�� (i)�52.222-35, Equal Opportunity for Veterans�(Jun 2020)�(38�U.S.C.�4212). (32)�� (i) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) (29 U.S.C. 793). (33)�� 52.222-37, Employment Reports on Veterans (Jun 2020) (38�U.S.C.�4212). (34)�� 52.222-40, Notification of Employee Rights Under the National Labor Relations Act�(Dec 2010)�(E.O. 13496). (35)�� (i)�52.222-50, Combating Trafficking in Persons�(Nov 2021)�(22�U.S.C.�chapter�78 and E.O. 13627). (42) ��52.223-15, Energy Efficiency in Energy-Consuming Products (May 2020) (42 U.S.C. 8259b). (44) ��52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Jun 2020) (E.O. 13513). (48)�� (i) 52.225-1, Buy American-Supplies (Oct 2022) (41 U.S.C. chapter 83). (51)�� 52.225-13, Restrictions on Certain Foreign Purchases�(Feb 2021)�(E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). (56)�� 52.232-29, Terms for Financing of Purchases of Commercial Products and Commercial Services�(Nov 2021)�(41�U.S.C.�4505,�10 U.S.C. 3805).� � � � � (57)�� 52.232-30, Installment Payments for Commercial Products and Commercial Services�(Nov 2021)�(41�U.S.C.�4505,�10 U.S.C. 3805). (58) ���52.232-33, Payment by Electronic Funds Transfer-System for Award Management (Oct2018) (31 U.S.C. 3332). (62) ���52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C. 637(d)(13)). (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services: (1)� � � 52.222-41, Service Contract Labor Standards�(Aug 2018)�(41�U.S.C.�chapter67). (2)� � � 52.222-42, Statement of Equivalent Rates for Federal Hires�(May 2014)�(29�U.S.C.�206 and 41�U.S.C.�chapter�67). (4)� � � 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (May 2014) (29 U.S.C.206 and 41 U.S.C. chapter 67). (7)� � � 52.222-55, Minimum Wages for Contractor Workers Under Executive Order 14026�(Jan 2022). (8)� � � 52.222-62, Paid Sick Leave Under Executive Order 13706�(Jan 2022)�(E.O. 13706). xiii)� The following additional clauses are applicable to this procurement (Full?text of clauses and provisions may be accessed electronically at this website: https://www.acquisition.gov): 52.204?7, System for Award Management (Oct 2018). 52.204-13, System for Award Management Maintenance (Oct 2018). 52.204?16, Commercial and Government Entity Code Reporting (Aug 2020). 52.204?18, Commercial and Government Entity Code Maintenance (Aug 2020). 52.223-5, Pollution Prevention and Right-to-Know Information (May 2011). 52.232?40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023). 52.237-1, Site Visit (Apr 1984). 52.237?2, Protection of Government Buildings, Equipment, and Vegetation (Apr 1984). 252.203?7000, Requirements Relating to Compensation of Former DoD Officials (Sep 2011). 252.203?7002, Requirement to Inform Employees of Whistleblower Rights (Dec 2022). 252.203?7005, Representation Relating to Compensation of Former DoD Officials (Sep 2022). 252.204?7006, Billing Instructions (Oct 2005). 252.204?7008, Compliance with Safeguarding Covered Defense Information Controls (Oct 2016). 252.204?7012, Safeguarding Covered Defense Information and Cyber Incident Reporting (Jan 2023). 252.204?7015, Notice of Authorized Disclosure of Information for Litigation Support (Jan 2023). 252.204-7017, Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services-Representation (May 2021). 252.204-7018, Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services (Jan 2023). 252.223?7008, Prohibition of Hexavalent Chromium (Jan 2023). 252.225?7001, Buy American and Balance of Payments Program (Jan 2023). 252.225?7002, Qualifying Country Sources as Subcontractors (Mar 2022). 252.225-7052, Restrictions on the Acquisition of Certain Magnets, Tantalum and Tungsten (Jan 2023). 252.225-7055, Representation Regarding Business Operations with Maduro Regime (May 2022). 252.225-7056, Prohibition Regarding Business Operations with the Maduro Regime (Jan 2023). 252.225-7060, Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region (Jan 2023). 252.226-7001, Utilization of Indian Organizations, Indian-Owned, Economic Enterprises, and Native Hawaiian Small Business Concerns (Jan 2023). 252.232?7003, Electronic Submission of Payment Requests and Receiving Reports (Dec 2018). 252.232?7010, Levies on Contract Payments (Dec 2006). 252.243?7002, Requests for Equitable Adjustment (Dec 2022). 252.244?7000, Subcontracts for Commercial Items (Jan 2023). 252.244-7001, Contractor Purchasing System Administration Alternate 1 (May 2014). 252.246-7007, Contractor Counterfeit Electronic Part Detection and Avoidance System (Jan 2023). 252.246-7008, Sources of Electronic Parts (Jan 2023). 252.247-7023, Transportation of Supplies by Sea (Jan 2023). 52.204?22, Alternative Line Item Proposal (Jan 2017). (a) The Government recognizes that the line items established in this solicitation may not conform to the Offeror�s practices. Failure to correct these issues can result in difficulties in acceptance of deliverables and processing payments. Therefore, the Offeror is invited to propose alternative line items for which bids, proposals, or quotes are requested in this solicitation to ensure that the resulting contract is economically and administratively advantageous to the Government and the Offeror. (b) The Offeror may submit one or more additional proposals with alternative line items, provided that alternative line items are consistent with subpart 4.10 of the Federal Acquisition Regulation. However, acceptance of an alternative proposal is a unilateral decision made solely at the discretion of the Government. Offers that do not comply with the line items specified in this solicitation may be determined to be nonresponsive or unacceptable. (End of provision) 52.204?24, Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment (Nov 2021). The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it ""does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument"" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services�Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications-Commercial Products or Commercial Services. The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it ""does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services"" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3. (a) Definitions. As used in this provision� Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (b) Prohibition. (1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to� (i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or (ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles. (2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to� (i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or (ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles. (c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for ""covered telecommunications equipment or services"". (d) Representation. The Offeror represents that� (1) It ? will, ? will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds ""will"" in paragraph (d)(1) of this section; and (2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that� It ? does, ? does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds ""does"" in paragraph (d)(2) of this section. (e) Disclosures. (1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded ""will"" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer: (i) For covered equipment� (A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known); (B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and (C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision. (ii) For covered services� (A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or (B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision. (2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded ""does"" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer: (i) For covered equipment� (A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known); (B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and (C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision. (ii) For covered services� (A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or (B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision. (End of provision) 52.209-7, Information Regarding Responsibility Matters (Oct 2018). (a) Definitions. As used in this provision� Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables. Federal contracts and grants with total value greater than $10,000,000 means� (1) The total value of all current, active contracts and grants, including all priced options; and (2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules). Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions). (b) The offeror ? has ? does not have current active Federal contracts and grants with total value greater than $10,000,000. (c) If the offeror checked ""has"" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information: (1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions: (i) In a criminal proceeding, a conviction. (ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more. (iii) In an administrative proceeding, a finding of fault and liability that results in� (A) The payment of a monetary fine or penalty of $5,000 or more; or (B) The payment of a reimbursement, restitution, or damages in excess of $100,000. (iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision. (2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence. (d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7). (End of provision) 52.211-11, Liquidated Damages�Supplies, Services, or Research and Development (Sep 2000) (a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $166.55 per calendar day of delay plus the amount to rent a land-based crane, barge crane, or combination of both in support mission operations scheduled after the contract completion date. (b) If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause. (c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract. (End of clause) 52.222?42, Statement of Equivalent Rates for Federal Hires (May 2014) In ...
 

Web Link

SAM.gov Permalink
(https://sam.gov/opp/24153dddb5434c26a760ad5614412443/view)
 

Place of Performance

Address: Goose Creek, SC 29445, USA

Zip Code: 29445

Country: USA
 

Record

SN06693292-F 20230526/230524230117 (samdaily.us)
 

Source

SAM.gov Link to This Notice
(may not be valid after Archive Date)

---

| FSG Index  |  This Issue's Index  |  Today's SAM Daily Index Page |