SOURCES SOUGHT
13 -- Initiator Delay Cartridge (JL56/JL57)
- Notice Date
- 1/26/2026 7:04:47 AM
- Notice Type
- Sources Sought
- NAICS
- 325920
— Explosives Manufacturing
- Contracting Office
- W6QK ACC-RI ROCK ISLAND IL 61299-0000 USA
- ZIP Code
- 61299-0000
- Solicitation Number
- W519TC-26SS073
- Response Due
- 2/9/2026 10:00:00 AM
- Archive Date
- 02/24/2026
- Point of Contact
- Caitlyn Smith, Emily Kundel
- E-Mail Address
-
caitlyn.l.smith3.civ@army.mil, emily.a.kundel.civ@army.mil
(caitlyn.l.smith3.civ@army.mil, emily.a.kundel.civ@army.mil)
- Small Business Set-Aside
- NONE No Set aside used
- Description
- The U.S. Army Contracting Command � Rock Island, on behalf of Project Manager, Close Combat Systems (PM-CCS), is issuing a Sources Sought notice to identify capable sources for the production and delivery of the following items. Item NSN: Part Number DODIC Initiator Delay, Cartridge Actuator Initiator 1377-01-723-6642 855330-06 JL56 Initiator Delay, Cartridge Actuator Initiator 1377-01-723-6646 855330-01 JL57 Data List/Part Numbers/Drawing Numbers: ITEM DATA/PART/DRAWING NUMBER REVISION REVISION DATE Initiator Delay, Cartridge Actuator Initiator JL56, PIN 855330-06 - - Initiator Delay, Cartridge Actuator Initiator JL57, PIN 855330-01 - - Specifications: ITEM Specifications REVISION REVISION DATE Initiator Delay, Cartridge Actuator Initiator ANSI/ASQ Z1.4 - October 2013 Initiator Delay, Cartridge Actuator Initiator ANSI/ASQ Z1.4 - October 2013 ITEM DESCRIPTIONS: JL56: this delay initiator is made of aluminum and stainless steel 6.07 inches long and 1.63 inches wide. It contains a percussion primer containing Lead Styphnate/Tetrazene proprietary explosive mix RDM Boron/Potassium Nitrate and HES 8028.6. JL57: this delay initiator is made of aluminum and stainless steel and is approximately 6.07 inches long 1.63 inches wide. It contains a percussion primer containing Lead Styphnate/Tetrazene, RDM, Boron/Potassium Nitrate, HES 8028.6 and a proprietary explosive mix. CRITICAL PROCESSES/SKILLS: The manufacture of this item requires skills, which include, but are not limited to: Radiographic and Radiographers, Radiographic equipment Critical processes and skills vary depending on the family of items, but may include experience with propellant manufacturing and casting, energetic material and/or explosive handling and loading, welding, machining, bridgewire and electrical circuitry, and shock wave propagation. An acceptable vendor must be able to display the skills of its employees and established expertise in completing essential operations of manufacturing the Initiator Delay, Cartridge Actuator Initiator. Respondents to this Sources Sought must have or have the ability to obtain the available skills required to perform all production and testing operations necessary to deliver conforming end items to the U.S. Government. These skills must be available with sufficient experience and proficiency to produce these items in a timely and efficient manner. A respondent must also have or have the ability to obtain the appropriate radiographic equipment and radiographic skills required to support quality production limitations. Any significant lead times with equipment or materials associated with production of these items should also be noted. RESPONSES: Interested companies who consider themselves capable of manufacturing the Initiator Delay, Cartridge Actuator Initiator are invited to indicate their interest by providing the U.S. Government with the following information: A brief summary of the company�s capabilities (a description of the facilities, personnel experience, quality system, and past manufacturing experience) and capacity. If a respondent does not have adequate resources (facilities, technical, manufacturing, personnel, etc.) available, then it must be able to demonstrate its ability to obtain those resources without significant delay. Identify and include a brief summary of any potential key sub-tier vendors or subcontractors and identify key components or processes that would be subcontracted. Identify minimum and maximum monthly production quantities and identify the available capacity considering any other known production. Identify your company�s size status for the identified NAICS code in the response. Due to the current global supply chain and other factors, respondents are asked to identify any components or materials that may be subject to price volatility or scarcity and address what their firm is doing to mitigate risk related to obtaining materials, price impacts, and production stability. The NAICS code for these items is 325920 with a business size standard of 750 employees. As noted above, please indicate your business size and socio-economic status in your response. Also be sure to provide the company name, address, point of contact, phone number, e-mail address, taxpayer identification number, DUNS number, and CAGE Code. Contractors must be registered in the System for Award Management (SAM) database prior to award, during performance, and through final payment of any contract resulting from a planned solicitation for these items. Contractors may obtain information on SAM registration by visiting: https://www.acquisition.gov. This sources sought announcement is for information and planning purposes only and shall not be construed as a Request for Proposal or as an obligation on the part of the U.S. Government. The U.S. Government does not intend to award a contract on the basis of this sources sought announcement or otherwise pay for information solicited. Industry responses to this sources sought will not represent binding offers, and the U.S. Government cannot accept an industry response to form a binding contract. The U.S. Government intends to use any information submitted in response to this request to develop an acquisition strategy for future requirements of this item. To be eligible for contracts with the U.S. Government, Contractors must be registered in the System for Award Management (SAM) database prior to award, during performance, and through final payment of any contract resulting from a planned solicitation for these items. Contractors may obtain information on SAM registration by visiting: https://www.acquisition.gov. All interested companies are highly encouraged to get registered in SAM immediately. The U.S. Government will hold all information submitted in a confidential status. All submissions are requested electronically no later than 09 February 2026 in order to be considered in the development of the acquisition strategy for these items. Send all responses to Ms. Caitlyn Smith at caitlyn.l.smith3.civ@army.mil, Ms. Meghan Newman at meghan.p.newman.civ@army.mil, and Ms. Emily Kundel at emily.a.kundel.civ@army.mil. Responses to this sources sought announcement should reference in the subject: Sources Sought W519TC-26-SS073 Response. Points of Contact: Caitlyn Smith, Contract Specialist Phone: (520) 693-0085 Email: caitlyn.l.smith3.civ@army.mil Army Contracting Command � Rock Island Rock Island, IL 61299-8000 Meghan Newman, Contract Specialist Phone: (520) 851-5892 Email: meghan.p.newman.civ@army.mil Army Contracting Command � Rock Island Rock Island, IL 61299-8000 Emily Kundel, Contracting Officer Phone: (571) 588-8585 Email: emily.a.kundel.civ@army.mil Army Contracting Command � Rock Island Rock Island, IL 61299-8000
- Web Link
-
SAM.gov Permalink
(https://sam.gov/workspace/contract/opp/4ad775db6e214df28511e413ce27839a/view)
- Place of Performance
- Address: USA
- Country: USA
- Country: USA
- Record
- SN07697167-F 20260128/260126230038 (samdaily.us)
- Source
-
SAM.gov Link to This Notice
(may not be valid after Archive Date)
| FSG Index | This Issue's Index | Today's SAM Daily Index Page |