U. S. ARMY ENGINEER DISTRICT, MOBILE, ATTN: CESAM-CT (PLANS ROOM NO. 1000A), P. O. BOX 2288 MOBILE ALABAMA 36628-0001, OR 109 ST. JOSEPH STREET MOBILE AL 36602

Z -- VARIOUS PROJECTS, HOWARD AIR FORCE BASE, REPUBLIC OF PANAMA SOL DACA01-96-B-0114 DUE 082996 POC Contact Ms. Karen Johnson, 334/690-2535; Contracting Officer, Edward M. Slana (Site Code W31XNJ) Various projects consisting of roof repair, repair of HVAC systems at various installations, renovations of a dormitory, construction of oil/water separators, construction of POL filter system, repair of electrical distribution system, repair of transformer vault, installation of a security system, and replacement of fire hydrants. Critical Path Method (Network Analysis System) is not required. Bid documents are available on or about 30 July 1996. Costs are as follows: Plans half size $24.00. Specifications $76.00. Estimated cost of work is between $1,000,000 and $5,000,000. ''In Country Contractors can purchase Plans and Specifications at the Central Latin America Area Office (Previously designated the Panama Area Office).'' ''Prime Contractors Proposing under this solicitation must be U.S. Firms, Panamanian Firms, or Joint Ventures between U.S. Firms and Panamanian Firms.'' Request for Plans and Specifications shall indicate in writing whether Firm will bid as a Prime contractor or a Subcontractor. Firm's physical address, telephone and facsimile numbers, and name of point of contact must also be provided to facilitate any overnight mailing required. All responsible sources may submit a bid which shall be considered. (0213)

Loren Data Corp. http://www.ld.com (SYN# 0202 19960801\Z-0020.SOL)