Defense General Supply Center, 8000 Jeff Davis Hwy, Richmond, VA 23297-5312

66 -- PROCESSOR, INDUSTRIAL X-RAY. SOL SP0440-96-R-2156 DUE 081696 POC Contact: For copies of RFP/IFB solicitations (available atleast 15 days from announcement, phone or write DGSC Attn:DGSC-jjab Richmond VA 23297-5312 AC (804)279-3350. For copies of RFQ solicitations,contact: Mary Walker/ AX401/804-279-3663. Contracting Officer: Kreylon V. Crewe/804-279-4105. PR-NO: YPG96088000789 NSN 6635-01-395-9512, processor, industrial X-R 1. Solicitation number SP0411-96-R-2156 is changed to SP0440-96-R-2156. Closing date is re-established to 96 Aug 16, 2:00 P.M. Local time. 2. Required delivery date is updated to 30 Sep 1996 based on the assumption that an award will be made by 30 Aug 96. 3. Page 2 of the RFP is deleted in its entirety. 4. The following clauses are deleted from the RFP: F4-52.211-9G07, ''special project Code labels'' I5-52.203-5, ''covenant against contingent fees'' I7-52.203-7, ''anti kickback procedures'' section J-SF1411 and SF1448 L49a-52.215-16 5. The following clauses are added to the RFP: E15-quality assurance provisionqap 001 I19-52.208-1, ''required sources for Jewel bearings & related items'' I97 52.219-9, ''small Disadvantaged and women-owned small business subcontracting plan (with dscr NOTE)'' I102B-52.219-16, ''liquidated damages-subcontractingplani107-252.219-7003, ''small, small Disadvantaged andwomen-owned. Small business subcontracting plan'' I109-252.219-7005, ''incentive for subcontracting with small business, small Disadvantaged business, histori-Cally blacki140-252.225-7002, ''qualifying country sources assubcontractors'' I152-252.225-7025, ''foreign source restrictionsi157a-52.226-1, utilization of Indian organizations andindian-owned economic Enterprises'' I160-52.227-3, ''patent indemnity'' I162-52.227-9, refund of royalties'' section J-QAP 001 K7-52.208-2, Jewel bearing and related items certifi-Cate'' K15C-252.217-7026, ''identification of sources of supplyk25-52.223-1. ''clean air and water certificationk34-52.227-6, ''royalty information'' L49B (altii)-52.215-16, ''contract award'' L55-52.217-9003, ''manufacturing or production informa-mation'' M10F-52.215-9G05, ''automated best value Model'' 6. Clause L50a-''facsimile proposals'', the facsimile number is change to (804-279-6045). 7. All other terms and conditions of the basic RFP remain unchanged. Incorporate the following clausesf1B 52.211-11 liquidated damages-supplies, services or research and development (Apr 1984)(a) if the contractor fails to deliver the supplies or perform the services within the time speci fied in this contract, or any extension, the contractorshall, in place of actual damages, pay to the Government as fixed, agreed, and liquidated damages, for each calendar Day of delay the sum of (B) alternatively, if delivery of performance is sodelayed, the Government may terminate this contract in whole or in part under the default-fixed-pricesupply and service clause in this contract and in that event, the contractor shall be liable for fixed, agreed, and liquidated damages accuring until the time the Government may reasonable obtain delivery or performanceof similar suppkies or services. The liquidateddamages shall be in addition to excess costs under the termination clause.(C) the contractor shall not be charged with liquidateddamages when the delay in delivery or performance arises out of causes beyond the control and without the fault or negligence of the contractor as defined in thedefault-fixed-price suply and service clause in thecontract. F1BA 52.211-16 variation in quantity (Apr 1984)(a) a variation in quantity of any item called for by this contract will not be accepted unless the variationhas been caused by conditions of loading, shipping, orpacking, or allowances in manufacturing porcess, and then only to the extent, if any, specified in paragraph (B) below.(B) the permissible variation shall be limited to:0 % (percent) increase 0 % (percent) decrease this increase or decrease shall apply to the totalitem quantity for each destination for items all...(0214)

Loren Data Corp. http://www.ld.com (SYN# 0404 19960802\66-0003.SOL)