DEPT OF JUSTICE, FED PRISON INDUSTRIES, 320 1ST STREET NW - Material Mgt Branch, WASHINGTON, DC 20534-0001

71 -- WHOLE ROOM PROGRAM SOL 1PI-R-0622-97 DUE 113096 POC Contract Specialist, CAVANAUGH, TATEA, 202-508-3952, 202-347-9416 fax # UNICOR, Federal Prison Industries intends to enter into a five (5) Year Service Type Contract for the Dormitory and Quarters Furniture Project (Whole Room Project) to include the following: coordination of delivery, unpacking, assembly and placement of the product to conform with the room configuration, removal of all packing materials and final cleaning and inspection of the product. The contractor will negotiate installation with UNICOR on a project by project basis. The contractor must be capable of supplying the ancillary items for the room packages and demonstrate the ability to stage the deliveries and coordinate the installation of the room packages. The contractor shall provide the following ancillary items: Carpet, Draperies, Mini- blinds, Bedspreads, Wall Artwork, Silk Plants, Lighting, Appliances and Optional seating. The contractor shall demonstrate the ability to stage all of the UNICOR and contractor provided products required for the room packages and make deliveries of complete projects or incrementally as the customer requires. The contractor shall have the ability to provide warehousing if necessitated by a customer initiated delay of delivery caused by construction delays or other unforeseen complications. Period of Performance is date of award through five (5) years thereafter. Delivery acceptance is 90 days after receipt of each delivery order. No telephone request will be honored. Request for solicitation shall be submitted on company letterhead citing business size. Request for solicitation should be sent to: Tatea R. Cavanaugh, Contracting Officer. All(0295)

Loren Data Corp. http://www.ld.com (SYN# 0227 19961022\71-0001.SOL)