Federal Aviation Administration, Acquisition Mgmt. Branch, Eastern Region, Fitzgerald Federal Bldg. 111, JFK Airport, Jamaica, NY 11430

Y -- RUNWAY 22L HIGH INTENSITY APPROACH LIGHTING SYSTEM (ALSF-2) SOL DTFA05-97-R-50847 POC Carol Tringali (718) 553-3089 Contracting Officer E-MAIL: Federal Aviation Administration, CBDAEA_at_AEA50@mail.hq.faa.gov. This Screening Information Request (SIR) is to pre-qualify offerors for the Runway 22L High Intensity Approach Lighting System (ALSF-2) project at JFK International Airport, Jamaica, New York. Offerors will be evaluated in accordance with the evaluation criteria as stated below in descending order of importance. Offerors who receive an evaluation percentage rating of 70% or above will receive the Request for Offer (RFO) estimated to be issued on or about February 20, 1997. All responses to this SIR must be received by February 17, 1997. KD-001- Technical Capability: The technical proposal must clearly demonstrate that the offeror has the technical capability to install, test and put into service the proposed JFK Runway 22L High Intensity Approach Lighting System (ALSF-2). The proposal should demonstrate technical capability in the following areas: 1. Airport lighting projects. 2. Timber pile and/or marine/harbor pier/walkway structures. 3. Electrical (industrial-type) high voltage (HV) equipment installation and testing of the following: A. HV Switchgear 2400V/4160V 3 phase systems. B. Constant Current Regulators 2400V/4160V 3 Phase. C. Transformers. D. Three phase electrical distribution systems. E. Isolation transformers and connectors. 4. Electrical and Electronic equipment installation and testing of the following: A. Earth grounding systems. B. Lighting protection systems C. Electronic components in conjunction with HV equipment D. Medium voltage electrical distribution systems. E. Tests of high voltage cables (to 15kV). F. Tests of low voltage cables (600V). G. Low voltage control wiring. 5. Installation and testing of the following types of Mechanical/Electrical equipment: A. Large engine/generators 175kW/200kW. B. Aboveground fuel storage tanks (AST). 6. Installation of the following heavy construction work. A. Reinforced concrete foundations. B. Concrete-encased electrical ductbank distribution systems. C. Electrical underground manholes and vaults. D. Trenching and cable installation. KD-002- Past Performance- Offerors shall submit the following information as part of their proposal for both the offeror and proposed major subcontractors: A. A list of the last 10 contracts and subcontracts completed during the past three years and all contracts and subcontracts currently in process. Contracts listed may include those entered into by the federal government, agencies of state and local governments, and commercial customers. Offerors that are newly formed entities without prior contracts should list contracts and subcontracts as required above for all key personnel. Include the following information for each contract and subcontract: 1. Name of contracting activity 2. Contract number 3. Contract type 4. Total contract value 5. Contract work 6. Contracting Officer and telephone 7. Program manager and telephone 8. List of major subcontractors B. The offeror may provide information on problems encountered on the contracts and subcontracts identified in A above and corrective actions taken to resolve those problems. Offerors should not provide general information on their performance on the identified contracts. C. Each offeror will be evaluated on his/her performance under existing and prior contracts for similar products or services. Performance information will be used for both responsibility determinations and as an evaluation factor against which offerors' relative rankings will be compared to assure best value to the government. The government will focus on information that demonstrates quality of performance relative to the size and complexity of the procurement under consideration. Past performance will be evaluated as follows: A. Quality of product or service- compliance with contract requirements- accuracy of report-technical excellence. B. Timeliness of performance- met interim milestones- reliable- responsive to technical direction- completed on time, including wrap-up and contract administration- no liquidated damages assessed. C. Cost control- within budget- current accurate and complete billings- relationship of negotiated costs to actuals- cost efficiencies. D. Customer satisfaction- satisfaction of end users and with the contractors service. (0030)

Loren Data Corp. http://www.ld.com (SYN# 0141 19970203\Y-0003.SOL)