U. S. ARMY ENGINEER DISTRICT, MOBILE, ATTN: CESAM-CT (PLANS ROOM NO. 1000A), P. O. BOX 2288 MOBILE ALABAMA 36628-0001, OR 109 ST. JOSEPH STREET MOBILE AL 36602

Y -- CONSTRUCTION OF STAGEFIELD AIR TRAFFIC CONTROL TOWERS, FT. RUCKER, ALABAMA SOL DACA01-97-B-0071 DUE 091097 POC Contact Karen Johnson (334)690-2535 Contracting Officer, Gene L. Curtis (Site Code W31XNJ) Construct Air Traffic Towers at various sites near Ft. Rucker. The towers will be steel framed with metal wall panels, rigid insulation and range in height from 30 to 50 feet. These towers will replace open framed towers to be removed and disposed of. Bid documents are available on or about 8 August 1997. Cost for Plans and Specifications for this job are free of charge. Estimated cost of work is between $1,000,000 to $5,000,000. Requests for Plans and Specifications shall indicate in writing whether firm will bid as a prime contractor or a subcontractor. Bidders, subcontractors and Dodge/Plan Rooms are encouraged to register on the Internet to receive one free CD-ROM. Registration on the Internet should minimize possible errors and delay in receiving the CD-ROM. Registration on the Internet should minimize possible errors and delay in receiving the CD-ROM. Registration instructions are available on the Internet at http://www.sam.usace.army.mil/sam/ct. Registration may also be completed by faxing to 334-694-4343, Attn: PlansRoom, CESAM. Telephonic requests will not be accepted. In either case, those registering are responsible for the accuracy of the information on the mailing list. Registration must include the firms physical address, telephone, fax number and a point of contact. Registration should be completed one week prior to the issue date. All notifications of changes to this solicitation shall be made through the Internet only. It is therefore the contractors responsibility to check the Internet address listed above daily, for any posted changes to this solicitation. Actual solicitation amendments will be issued either by fax, 3.5" diskette or CD-ROM. The plans and specifications will be issued on Compact Disc (CD-ROM) only and will be provided free of charge. Plans and specifications will not be provided in a printed paper format; however, the Government reserves the right to revert to paper medium when it is determined to be in the Government's best interest. All bid forms, bid bonds, and other normal documents required for the bid submittal, including amendments to the bid submittal, shall be in paper medium. Electronic medium for the bid submittal documents will not be allowed. Critical Path Method (Network Analysis System) Is Required. For this job, a small business is defined as having average annual receipts of less than $17,000,000 for the past three years. This solicitation included bid options which may not awarded. Specific questions related to this project may be answered by Shirley Hooker at 334-694-3791, fax 334-690-2700. Refer questions on distribution of plans/specifications to PlansRoom at 334-690- 2535. Unrestricted. All responsible sources may submit a bid which shall (0205)

Loren Data Corp. http://www.ld.com (SYN# 0180 19970728\Y-0034.SOL)