U. S. ARMY ENGINEER DISTRICT, MOBILE, ATTN: CESAM-CT (PLANS ROOM NO. 1000A), P. O. BOX 2288 MOBILE ALABAMA 36628-0001, OR 109 ST. JOSEPH STREET MOBILE AL 36602

Y -- IMPROVE FAMILY HOUSING, PHASE "A" HURLBURT FIELD, FLORIDA SOL DACA01-98-B-0003 DUE 110497 POC Contact Karen Johnson (334)690-2535 Contracting Officer, Edward Slana (Site Code W31XNJ) Work consists of performing asbestos and lead paint abatement with the following: selective demolition and disposal of building materials: new patio roofs and carports; removing and installing new doors, cabinets, trim and accessories; removing existing electrical wiring conduit, GFI receptacles and light fixtures and installing new electrical circuits (including telephone wiring) with consequent sheetrock installation, finishing and painting; removal and replacement of floor tile; new concrete side walks. Work must be accomplished with phased construction. Bid documents are available on or about 3 October 1997. Bidders, subcontractors and Dodge/Plan Rooms are encouraged to register on the Internet to receive one free CD-ROM. Registration on the Internet should minimize possible errors and delay in receiving the CD-ROM. Registration instruction are available on the Internet at http://www.sam.usace.army.mil/sam/ct. Registration may also be completed by faxing to 334-694-4343, Attn: PlansRoom, CESAM. Telephonic requests will not be accepted. In either case, those registering are responsible for the accuracy of the information on the mailing list. Registration must include the firms physical address, telephone, fax number and a point of contact. Registration should be completed one week prior to the issue date. All notifications of changes to this solicitation shall be made through the internet only. It is therefore the contractors responsibility to check the internet address listed above daily, for any posted changes to this solicitation. Actual solicitation amendments will be issued either by fax, 3.5" diskette or CD-ROM. The plans and specifications will be issued on Compact Disc (CD-ROM) only and will be provided free of charge. Plans and specifications will not be provided in a printed paper format; however, the Government reserves the right to revert to paper medium when it is determined to be in the Government's best interest. All bid forms, bid bonds, and other normal documents required for the bid submittal, including amendments to the bid submittal, shall be in paper medium. Electronic medium for the bid submittal documents will not be allowed. Critical path method (network analysis system) is required. This solicitation includes bid options which may not be awarded. Specific questions related to this project may be answered by Michelle Andrews at (334) 694-3816, Fax (334)690-2902. Refer questions on distribution of plans/specifications to plansroom at 334-690-2535. Unrestricted. All responsible sources may (0255)

Loren Data Corp. http://www.ld.com (SYN# 0140 19970916\Y-0008.SOL)