U. S. ARMY ENGINEER DISTRICT, MOBILE, ATTN: CESAM-CT (PLANS ROOM NO. 1000A), P. O. BOX 2288 MOBILE ALABAMA 36628-0001, OR 109 ST. JOSEPH STREET MOBILE AL 36602

Y -- REPAIR FILLSTANDS AND TANK 332 HOMESTEAD ARB, FL SOL DACA01-98-B-0008 DUE 010798 POC Contact Karen Johnson (334)690-2535 Contracting Officer, Edward M. Slana (Site Code W31XNJ) Base Bid work includes the rehabilitation/alteration of existing Truck Fillstands and JP-S Jet Fuel Storage Tank 332. Repairs at the Truck Fillstands include installation of new bottom loading arms, meter, and valving. The rehabilitation of Tank 332 includes the installation of a new fixed cone roof, and miscellaneous modifications to valves and piping. The existing tank shell, bottom, and foundation shall be reused. Bid Options include the installation of an internal floating pan and an electronic overfill protection system for Tank 332. Bid documents are available on or about 26 November 1997. Estimated cost of work is between $500,000 to $1,000,000. Bidders, subcontractors and Dodge/Plan Rooms are encouraged to register on the Internet to receive one free CD-ROM. Firm's physical address, telephone and facsimile number and name of point of contact must be provided to facilitate any overnight mailing required. Registration on the Internet should minimize possible errors and delay in receiving the CD- ROM. Registration on the Internet should minimize possible errors and delay in receiving the CD-ROM. Registration instructions are available on the Internet at http://www.sam.usace.army.mil/sam/ct. Registration may also be completed by faxing to 334-694-4343, Attn:PlansRoom, CESAM. Telephonic requests will not be accepted. In either case those registering are responsible for the accuracy of the information on the mailing list. Registration must include the firms physical address, telephone, fax number and a point of contact. Registration should be completed one week prior to the issue date. All notifications of changes to this solicitation shall be made through the internet only. It therefore the contractors responsibility to check the Internet address listed above daily, for any posted changes to this solicitation. Actual solicitation amendments will be issued either by fax, 3.5" diskette or CD-ROM. The plans and specifications will be issued on Compact Disc (CD-ROM) only and will be provided free of charge.Plans and specifications will not provided in a printed paper format; however, the Government reserves the right to revert to paper medium when is determined to be in the Government's best interest. All bid forms, bid bonds and other normal documents required for the bid submittal, including amendments to the bid submittal, shall be in paper medium. Electronic medium for the bid submittal documents will not be allowed. Critical Path Method (Network Analysis System) Is Not Required. For this job, a small business is defined as having average annual receipts of less than $17,000,000 for the past three years. This solicitation includes bid options which may not be awarded. Specific questions related to this project may be answered by Mr. Allen Harrison at (334)694-3624, Fax (334)690-2902. Refer questions on distribution of plans/specifications to plans room at 334-690-2535. Unrestricted. All responsible sources may (0311)

Loren Data Corp. http://www.ld.com (SYN# 0148 19971112\Y-0010.SOL)