U. S. ARMY ENGINEER DISTRICT, MOBILE, ATTN: CESAM-CT (PLANS ROOM NO. 1000A), P. O. BOX 2288 MOBILE ALABAMA 36628-0001, OR 109 ST. JOSEPH STREET MOBILE, AL 36602

Y -- ADDITION TO COMMAND AND CONTROL FACILITY MACDILL AFB, FLORIDA HILLSBOROUGH COUNTY, FLORIDA SOL DACA01-98-B-0030 DUE 041698 POC Contact Karen Johnson (334)690-2535 Contracting Officer, Edward M. Slana (Site Code W31XNJ) Asbestos removal and demolition of two existing single story wood frame buildings south of Building 501, construction of a two story, 51,500 SF steel frame office building on pile foundations, including installation of prewired work stations, and construction of associated asphalt parking areas and general sitework. Bidders, subcontractors and Dodge/Plan Rooms are encouraged to register on the Internet to receive one free CD-ROM. Registration on the Internet should minimize possible errors and delay in receiving the CD-ROM. Registration instructions are available ont he Internet at http://www.sam.usace.army.mil/sam/ct. Registration may also be completed by faxing to 334-694-4343, Attn: PlansRoom, CESAM. Telephonic requests will not be accepted. In either case, those registering are responsible for the accuracy of the information on the mailing list. Registration must include the firms physical address, telephone, fax number and a point of contact. Registration should be completed one week prior to issue date. All notifications of change to this solicitation shall be made through the Internet only. It is therefore the contractors responsibility to check the Internet address listed above daily, for any posted changes to this solicitation. Actual solicitation amendments will be issued either by fax, 3.5" diskette or CD-ROM. The plans and specifications will be issued on Compact Disc (CD-ROM) only and will be provided free of charge. Plans and Specifications will not be provided in a printed paper format; however, the Government reserves the right to revert to paper medium when it is determined to be in the Government's best interest. All bid forms, bid bonds, and other normal documents required for the bid submittal, including amendments to the bid submittal, shall be in paper medium. Electronic medium for the bid submittal documents will not be allowed. Bid documents are available on or about 16 March 1998. Estimated cost of work is between $5,000,000 to $10,000,000. Critical Path Method (Network Analysis System) Is Required. For this job, a small business is defined as having average annual receipts of less than $17,000,000 for the past three years. This solicitation included bid options which may not be awarded. Specific questions contracting questions related to this project may be answered by Mr. Alfred R. Denmark at 334-690-4188, Fax 334-690-2902. Refer questions on distribution of plans/specifications to plansroom at 334-690-2536/2535. Unrestricted. All responsibile sources may submit a bid which shall be (0054)

Loren Data Corp. http://www.ld.com (SYN# 0139 19980225\Y-0016.SOL)