U. S. ARMY ENGINEER DISTRICT, MOBILE, ATTN: CESAM-CT (PLANS ROOM NO. 1000A), P. O. BOX 2288 MOBILE ALABAMA 36628-0001, OR 109 ST. JOSEPH STREET MOBILE AL 36602

Y -- REPLACE STEAM LINES -- PHASE III, FORT RUCKER, AL (DALE COUNTY, AL) SOL DACA01-98-B-0044 DUE 073098 POC Contact Karen Johnson, (334) 690-2535, Contracting Officer, Gene L. Curtis (Site Code W31XNJ) Provide Description of project: Replace steam lines of approximately 2,000 linear feet with associated site work including trench covers and connections into the various buildings supplied by the steam lines. Bidders, subcontractors and Dodge/Plan Rooms are encouraged to register on the Internet to receive one CD-ROM. Registration on the Internet should minimize possible errors and delay in receiving the CD-ROM. Registration instructions are available on the Internet at http://www.sam.usace.army.mil/sam/ct. Registration may also be completed by faxing to 334-694-4343, Attn: Plans Room, CESAM. Telephonic requests will not be accepted. In either case, those registering are responsible for the accuracy of the information on the mailing list. Registration must include the firms physical address, telephone, fax number and a point of contact. Registration should be completed one week prior to the issue date. All notifications of changes to this solicitation shall be made through the Internet only. It is therefore the contractors responsibility to check the Internet address listed above daily, for any posted changes to this solicitation. Actual solicitation amendments will be issued either by fax, 3.5" diskette or CD-ROM. The plans and specifications will be issued on Compact Disc (CD-ROM) only and will be provided free of charge. Plans and specifications will not be provided in a printed paper format; however, the Government reserves the right to revert to paper medium when it is determined to be in the Government's best interest. All bid forms, bid bonds, and other normal documents required for the bid submittal, including amendments to the bid submittal, shall be in paper medium. Electronic medium for the bid submittal documents will not be allowed. Critical Path Method (Network Analysis System) is required. For this job, a small business is defined as having average annual receipts of less than $17,000,000 for the past three years. Effective 1 July 1998, firms interested in construction contracts with the Mobile District, Corps of Engineers, must have "Internet Access"! Don't be left out, get it soon! For detailed information on this and other Mobile District Projects, (Bidding Instructions, Technical Inquiries, Points of Contact, Synopsis of Work, Plan Holders, Bid Results, etc.,) please visit our internet home page at http://www/sam/usace.army/mil/sam/ct. Specific questions related to this project may be answered by Mr. Thom Fultz at 334-690-3412 or Ms. Karen Williams, 334-690-2713, fax 334-690-2902. Refer questions on distribution of plans/specifications to plans room at 334-690-2535 (Karen Johnson). Bid documents are available on or about 30 Jun 1998. Estimated cost of work is between $1,000,000 and $5,000,000. Requests for plans and specifications shall indicate in writing whether firm will bid as a prime contractor or a subcontractor. All responsible sources may submit a bid which shall be (0152)

Loren Data Corp. http://www.ld.com (SYN# 0108 19980603\Y-0015.SOL)