Bureau of Reclamation, Eastern Colorado Area Office, 11056 West County Road 18E, Loveland, CO 80537

61 -- FURNISH MATERIALS AND LABOR NECESSARY FO RINSTALLATION OF A NEW SINGLE-ENDED UNIT SUBSTATION SOL 00SQ6C022 DUE 012400 POC For technical questions, please call Erby Kenerson at 970-962-4324 Soliciation Notice 00SQ6C022 from Bureau Of Reclamation, 11056 West County Road 18E, Loveland CO 80537, ATTN: Kevin O'Connor, for materials and labor necessary for installation of a new Single-Ended Unit Substation located at our Pueblo Office (600 Reservoir Road, Pueblo CO 81003) is AMENDED AS FOLLOWS: A. The date for receipt of bids in the Loveland office Has NOT been extended. B. The Date for completion of the work IS Extended to June 30, 2000. C. The date change-over from permanent power to temporary power (existing Government furnished engine-generator) will be coordinated between the Bureau of Reclamation and the Contractor. This date will be dependent on water release requirements at the time that the contractor informs the Bureau of Reclamation that he is ready to start installation work. The date for providing a clearance on the existing unit substation may vary over a period of one to two weeks. D. Bids submitted to the Loveland office must be in accordance with this notice. Acknowledge receipt of this notice by mail telegram or fax (970)663-3212). If your bid has already been sent to the Loveland Office, acknowledge receipt of this notice in writing or by fax prior to closing date for receipt of bids (Jan 24, 2000). Failure to acknowledge this notice may result in rejection of your bid. E. If your bid has already been submitted and you want it returned for revision and resubmission, please advise the Contracting Officer (Kevin O'Connor) at this office at (970)962-4310. Posted 12/28/99 (W-SN411749). (0362)

Loren Data Corp. http://www.ld.com (SYN# 0127 19991230\61-0002.SOL)