Engineering Services -- Dallas, 1301 Young Street, Room 1071, Dallas, Texas 75202-5433

Y -- CONSTRUCTION MANAGER/PRIME GENERAL CONTRACTOR FOR THE CONSTRUCTION OF A NEW FOUR CORNERS REGIONAL HEALTH CENTER, RED MESA, ARIZONA SOL RFP/161-99-0026 DUE 062700 POC Gerald Inglett, R.A., Project Manager, (214) 767-3898. Barry J. Prince, Contracting Officer, (214) 767-6613. PRESOLICITATION NOTICE: The Indian Health Service (IHS), Engineering Services Dallas (ES-D) is solicitating proposals from qualified firms to act as the Construction Manager/General Prime Contractor (CM/GPC) for the construction of a new Four Corners Regional Health Center and Staff Quarters at Red Mesa, Arizona. This new Health Center facility will be approximately 10,600 gross square meters. The Staff Quarters will have 93 Living Units. The estimated construction dollar magnitude for the Health Center is between $20-$25 million. The estimated construction dollar magnitude for the Staff Quarters is between $15-$20 million (pending funds available). The Standard Industrial Code (SIC) is 1542 and the business size standard is $17 Million. This solicitation will not be set aside for small business and is being made under the Small Business Competitiveness Demonstration Program. The estimated construction period is two years. A Performance Bond (100%) and Payment Bond ($2.5 M) will be required of the selected contractor prior to issuance of the Notice to Proceed for Part 2 of this project. For estimating purposes the contractor's insurance bonding provider should consider the Maximum Estimated Amount available at this time for this project to be $2.5 M. Actual bonding requirements will be established when the final Guaranteed Maximum Price is established. THIS ACQUISITION IS FOR FULL AND OPEN COMPETITION FOR ALL INTERESTED PARTIES. Joint Ventures will be considered. SCOPE OF WORK: The selected contractor will serve as the Prime Contractor and will be a member of the construction team consisting of the A&E Design Firm, the Contractor, and the Government for the construction of the New Four Corners Regional Health Center and Staff Housing Facilities at Red Mesa, Arizona. The contract will be in two parts: Part 1: As a team member the CM / GPC will provide consultative and other services during the design phase of the project. Review and make recommendations on plans and specifications as they have been and are being developed with emphasis on keeping the cost of the project within budgetary limitations; assist in the development of a total project cost estimate, broken down by specialities, leading to the development of an acceptable guaranteed maximum project price, make recommendations on value engineering type changes, assist in preparing the construction schedule and other associated tasks for construction of this new facility. Part 2: The selected CM/GPC must provide all management, supervision, labor, materials, supplies and equipment, transportation and must plan, schedule, coordinate and assure effective performance of all construction to meet the project requirements; bid or negotiate and award all subcontracts; perform general condition items; provide quality assurance inspections; and assume the responsibility for completing the project within the Guaranteed Maximum Price and in compliance with the developed design specifications, drawings and the provisions of the contract. METHOD OF SELECTION: Competitive formal sources selection procedures will be used in accordance with Part 15 of the Federal Acquisitation Regulations (FAR). The qualifications submitted by each firm will be reviewed and evaluated for the most highly qualified firm. When responding to this announcement, firms should FULLY ADDRESS their capability and qualifications with regard to each of the following evaluations factors. The top ranked firms recommended for interview will be evaluated and recommended solely on their written responses to this announcement. Prime contractors assembling a team are cautioned that the evaluation will be based on the team, not just the prime firm. Interested offerors may request an OFFEROR QUALIFICATION STATEMENT package from this office by submitting their request in writing to Barry J. Prince, Contracting Officer, at facsimile telephone number (214) 767-5194. THE OFFEROR QUALIFICATION STATEMENT IS THE ONLY FORM OF SUBMITTAL THAT WILL BE ACCEPTED BY THE CONTRACTING OFFICER. Any additional material submitted (over and beyond the OFFEROR QUALIFICATION STATEMENT) will not be evaluated and will be returned to the Offeror. TECHNICAL EVALUATION FACTORS: The evaluation factors are listed in descending order of priority with evaluation factors #1 & #2 being of equal point value and #4 & #5 of equal point value. The offeror must demonstrate its experience and professional ability in the following areas: (1) CONSTRUCTION MANAGEMENT EXPERIENCE: Experience as a CM/GPC of similar size and general scope of this project, i.e., health centers, hospitals and assorted housing over the past 3 years; (2) MANAGEMENT PLANNING & ACCOUNTING EXPERIENCE: Proposed management plan including cost management ability, accounting system which will be utilized and critical path scheduling experience on similar type and size projects; (3) EXPERIENCE OF CONSTRUCTION MANAGER'S PROFESSIONAL STAFF ASSIGNED TO THIS PROJECT: The CM/GPC proposed staff (Key personnel) for this project, including professional experience, qualifications, education and training, i.e., Project Manager, Superintendent, Estimator, Quality Control Supervisor, etc; (4) PAST PERFORMANCE ON GOVERNMENT PROJECTS: Past performance on contracts with Government agencies including Indian organizations, tribes, agencies, i.e., Indian Health Service and Bureau of Indian Affairs; (5) ENGINEERING & ARCHITECTURAL EXPERIENCE: Technical Engineering/Value Engineering /Architectural experience in the design of health centers, hospitals and assorted housing over the past 3 years. Interested Offerors shall submit their OFFEROR QUALIFICATION STATEMENT FORM to Barry J. Prince, Contracting Officer, Indian Health Service, Engineering Services -- Dallas, 1301 Young Street, Suite 1071, Dallas Texas 75202-5433. ALL OFFEROR QUALIFICATION STATEMENTS MUST BE received by the Contracting Officer no later than 4:30 P.M., CST, Tuesday, June 27, 2000. Posted 05/02/00 (W-SN450390). (0123)

Loren Data Corp. http://www.ld.com (SYN# 0093 20000504\Y-0001.SOL)